settlement agreement and release -...
TRANSCRIPT
SETTLEMENT AGREEMENT AND RELEASE
This Settlement Agreement and Release is made and entered into as of the 19 dayof March, 2013 ("Effective Date") by and between Project SEED, LLC, LabHolding LLC, Shaheen Sadeghi (collectively, "Project SEED"), and the City ofPortland, acting by and through the Portland Development Commission and thePortland Development Commission (collectively, "PDC"). Project SEED andPDC are collectively referred to as the "Parties."
DEFINITIONS
As used in this Settlement Agreement and Release:
1. "Centennial Mills" means the 4.75 acre site located at 1362 NW NaitoParkway in Northwest Portland known as Centennial Mills.
2. "Centennial Mills Project" means the potential development of CentennialMills by Project SEED.
3. "Contractor Agreements" means all contracts entered into by ProjectSEED or any of its affiliates, including without limitation, its architects,engineers, and contractors, (such as Meyer Sherer & Rockcastle, LTD)concerning or related to the Centennial Mills Project. A list of allContractor Agreements, agreed to by the Parties, is included in Exhibit 1attached hereto.
4. "kVQrk Product" means all documents, drawings, photographs, models, orother materials, whether electronic, hard-copy, or in other medium,including, but not limited to, CAD drawings, narratives, or designdrawings, generated in connection with the Centennial Mills Projectexcept for any marketing, branding, cultural, or programming itemsdeveloped by Project SEED. A list of all Work Product, agreed to by theParties, is included in Exhibit 1 attached hereto.
RECITALS
1. Whereas, PDC acquired Centennial Mills before 2007;
2. Whereas, pursuant to Grant Agreement number 38555-08 dated May 5,2008 ("Grant 1"), PDC granted to Lab Holding LLC $40,000;
3. Whereas, pursuant to a Memorandum of Understanding dated August 18,2008, as amended (the "MOU"), the Parties explored the potentialdevelopment of Centennial Mills;
4. Whereas, pursuant to Predevelopment Loan Agreement number 38567-08dated September 15, 2008 ("Loan 1") and related PredevelopmentPromissory Note of Borrower ("Note 1"), PDC loaned Project SEED, LLC$170,142.60;
5. Whereas, pursuant to Predevelopment Grant Agreement number 38568-08dated September 15, 2008 ("Grant 2"), PDC granted Project SEED, LLC$170,142.60;
6. Whereas, pursuant to Predevelopment Loan Agreement number 38620-09dated January 25, 2010 ("Loan 2") and related PredevelopmentPromissory Note of Borrower ("Note 2"), PDC loaned Project SEED, LLC$100,000.00;
. Whereas, on November 16, 2011, Project SEED, LLC filed a complaintagainst PDC in the Circuit Court for the State of Oregon, MultnomahCounty, alleging various causes of action, which Project SEED, LLCamended on March 26, 2012, in response to which PDC was poised to filecounterclaims under the loan and grant agreements against Project SEED,LLC (collectively the "Lawsuit");
8. Whereas, the Parties now wish to fully and finally resolve all theirdisputes:
AGREEMENT AND RELEASE
Now, therefore, for good and valuable consideration, the sufficiency of which ishereby acknowledged, the Parties do hereby expressly agree as follows:
1. Payment
Upon receipt of all Work Product and Contractor Agreements as described below,PDC hereby agrees to pay Project SEED Two Hundred Thousand Dollars($200,000.00) (the "Payment").
2. Dismissal
Upon execution and delivery hereof by PDC to Project SEED and receipt of theentire Payment, Project SEED will file a Notice of Voluntary Dismissal WithPrejudice, in the form attached hereto as Exhibit 2, dismissing with prejudice allclaims asserted in Project SEED's Amended Complaint, and with the Partiesbearing their own attorney fees, costs and expenses.
3. Transfer and Assignment of Contractor Agreements and WorkProduct
To the extent permitted by law and the respective agreements, Project SEEDhereby agrees to assign, convey, and transfer, and to cause its affiliates to assign,convey and transfer all their interest, right, title, privilege, benefit, and remediesin, to, and under the Contractor Agreements to PDC.
To the extent permitted by law and the related agreements, Project SEED herebyagrees to assign, convey, and transfer, and to cause its affiliates to assign, conveyand transfer all their interest, right, title, privilege, benefit, and remedies in or tothe Work Product to PDC.
PDC does not assume any of Project SEED's obligations under the ContractorAgreements, including, without limitation, any obligation to pay for the workdone pursuant thereto, provided however, PDC bears sole responsibility to pay forany work that PDC directs to be performed pursuant to the assigned ContractorAgreements.
Project SEED will deliver the Work Product and Contractor Agreements listed inExhibit 1 as item numbers 1-3, 6-8, 11-13, and 16-38 to PDC.
Each party will bear its own costs and expenses incurred in assigning, delivering,transferring, or obtaining Work Product and the Contractor Agreements.
The Parties agree that PDC may contact third parties directly regarding ContractorAgreements or Work Product, or to obtain Work Product directly from those thirdparties.
PDC acknowledges that the Work Product is provided by Project Seed in "As Is""Where Is" condition and acknowledges that neither Project SEED nor itsaffiliates have made any warranty or representation with respect to the accuracy,contents, or condition thereof, the suitability of the Work Product for any purpose,or PDC's or any other party's right to use or rely on the Work Product for anypurpose, all of which warranties and representations are expressly disclaimed.Nothing in this paragraph is intended to limit the assignments made by thisSettlement Agreement or the rights conveyed by those assignments, includingPDC's ability to use and rely on the Work Product to the same extent ProjectSEED could use and rely on that Work Product, provided however, Project SEEDbears no responsibility to ensure that the third parties accept and comply with theassignments provided for herein.
4. Limitation on Public Statements and Non-Disparagement
Aside from the "Press Statement" attached hereto as Exhibit 3:
PDC (including PDC board members) will limit its public statements concerningthe Centennial Mills Project, this Settlement Agreement and Release, ProjectSEED, LLC, Lab Holding LLC, or Mr. Sadeghi to refuting the allegations inProject SEED's Amended Complaint and only in response to specific inquiriesabout those allegations, or to making disclosures required by law, includingdisclosures under ORS 192.420, et seq.
Project SEED will limit its public statements concerning the Centennial MillsProject, this Settlement Agreement and Release and PDC to responding to anypublic statement made by PDC or its affiliates regarding Project SEED, LLC, LabHolding LLC, Mr. Sadeghi, the Centennial Mills Project, the allegations in ProjectSEED's Amended Complaint or this Settlement Agreement and Release(excluding those comments of PDC in the attached Press Statement).
The Parties agree not to engage in any public conduct or communication that isintended to disparage, or that could be objectively and reasonably construed as
3
disparaging the Centennial Mills Project, this Settlement Agreement and Releaseor each other.
5. Mutual Release
5.1 Effective upon dismissal of the Lawsuit, receipt of the entire Paymentand receipt of the Work Product, as described above, the Parties, onbehalf of themselves and their respective present and former agents,employees, officers, directors, commissioners, members, managers,partners, joint venturers, attorneys, insurers, predecessors, successors,and assigns, and each of them absolutely, forever and fully, generallyand specifically release and discharge each of the other Parties andtheir respective present and former agents, employees, officers,directors, commissioners, members, managers, partners, jointventurers, attorneys, insurers, predecessors, successors, and assigns,and each of them, from any and all claims, rights, debts, liabilities,demands, obligations, duties, promises, costs, expenses (including, butnot limited to, attorney fees and costs), liens, subrogation rights,indemnification rights, damages, actions, and causes of action, of anykind whatsoever, whether based upon contract, tort, statute, or anyother legal or equitable theory of recovery, and whether known orunknown, suspected or unsuspected, fixed or contingent, matured orunmatured, which relate to or arise out of the Centennial Mills Project,including, but not limited to those relating to or arising out of theMOU, Loan 1, Loan 2, Note 1, Note 2, Grant 1, Grant 2, theContractor Agreements, the Work Product, and any and all claims(including counterclaims) that were brought, or could have beenbrought, in the Lawsuit, except those arising under this SettlementAgreement and Release.
5.2 Loan 1, Loan 2, Grant 1 and Grant 2 are deemed paid in full. Note 1and Note 2 are hereby cancelled and deemed paid in full. The originalNote 1 and Note 2 shall be delivered to Project SEED at the timePayment is made.
6. No Admission of Liability
This Settlement Agreement and Release pertains to disputed claims and does notconstitute an admission of liability on the part of any of the Parties, all liabilityhaving been denied, at all relevant times, and which continues to be denied.
7. After-Acquired Facts
The Parties expressly agree to assume the risk of possible discovery of additionalor different facts, and the Parties agree that this Settlement Agreement andRelease shall be and remain effective in all respects, regardless of such additionalor different discovered facts, or any change in circumstances.
8. Advice of Counsel
In executing this Settlement Agreement and Release, each Party heretoacknowledges that it has consulted with and had the advice of counsel of its ownchoosing in negotiations for and preparation of this Settlement Agreement andRelease and was fully advised by counsel with respect to all rights which areaffected by this Settlement Agreement and Release. Each Party heretoacknowledges that its counsel played a role in drafting this Settlement Agreementand Release and that this Settlement Agreement and Release shall be construedneutrally as if jointly drafted by all Parties, and shall not be construed in favor ofor against any Party based on the origin of the language used. The language in allparts of this Settlement Agreement and Release shall in all cases be construed as awhole according to its fair meaning and not strictly for or against any of theParties.
9. Choice of Law
This Settlement Agreement and Release is made and entered into in the State ofOregon and shall in all respects be interpreted, enforced, and governed under thelaws of the State of Oregon as if entirely performed within the State or Oregon.Oregon law shall apply without regard to any conflict of laws.
10. Entire Agreement; Modification
This Settlement Agreement and Release is the entire agreement between theParties with respect to the subject matter hereof. It includes all of the terms,promises, and representations made by the Parties, and it supersedes any earlierwritten or oral agreements between the Parties. Modifications to this SettlementAgreement and Release must be made in writing and signed by both Parties.
11. Authority
Each of the Parties represents, warrants, and covenants that it has the power tosettle and release fully and completely all of the Released Claims. The Partieshave not assigned, subrogated, or in any other way transferred to anyone else anyportion of the Released Claims they have or had against each other.
12. Review of Agreement
The Parties certify that they have read all of this Settlement Agreement andRelease and fully understand all of the same.
13. Cooperation in Implementation
The Parties agree to cooperate and diligently perform any further acts, and willexecute and deliver any documents, that from time to time may be reasonablynecessary or otherwise reasonably required to consummate, evidence, confirm,and/or carry out the intent and provisions of this Settlement Agreement andRelease, all without undue delay or expense and without further consideration.
Project SEED, LLC Lab Holding LLC
d e /,t. /3Date: Date:
„14. Counterparts and Facsimile/PDF
This Settlement Agreement and Release may be executed in counterparts and viafacsimile or electronically via .pdf with the same force and effect as if executed inone complete document.
15. Severability
If any clause or provision of this Settlement Agreement and Release is held to beillegal, invalid, or unenforceable under any law applicable to the terms hereof,then the remainder of this Settlement Agreement and Release shall not be affectedthereby.
16. Binding Effect
This Settlement Agreement and Release shall be binding upon and inure to thebenefit of the Parties and their respective representatives, successors, and assigns.
Shaheen Sadeghi
6C:WSERSiRRSVAPPDATA:LOCAL1MICROSOFT\WINDOWS\TEMPORA
City of Portland, acting by and through Portland Development Commissionthe
, Portland Develo Oment Commission
By: Z- / C---.
Executive D'rect r
Date: 7 (q i?
By: /
Executive Director
Approved as to Form: Approved as to Form:
• Attorney for Portland DevelopmentCommission
Date: 3 - /*-/ 3
Attorney for Portland DevelopmentCommission
Date: ?
Exh
ibit
1Ag
reed
Lis
t of C
ontra
ctor
Agr
eem
ents
and
Wor
k Pr
oduc
t
No. C
onsu
ltant
/Age
ncy
Con
tract
or A
gree
men
ts/W
ork
Prod
uct
LAB
Team
Dire
ctor
y2
BD
SPr
edev
elop
men
t Con
fere
nce
Sum
mar
y3
BDS
Des
ign
Adv
ise
Req
uest
Res
pons
e4
CH
RIS
TIE
WH
ITE
Gre
enw
ay R
evie
w A
naly
sis
5 D
IRT
Des
ign
Doc
umen
ts6
FIS
HE
RIE
STe
ch M
emo
re: R
iver
Wor
k7
FLO
WIN
G S
OLU
TIO
NS
NM
FS M
emo
FLO
WIN
G S
OLU
TIO
NS
Wat
ersi
de Im
pact
Eva
luat
ion
Rep
ort
9 G
BS
Eco
-Cha
rret
te R
epor
t10
GB
SL
eed
Ass
essm
ent
(Sch
emat
ic D
esig
n)11 G
BS
Pro
posa
l12
GE
OD
ES
IGN
Con
trac
t13
GE
OD
ES
IGN
Pre
limin
ary
Geo
tech
Rep
ort
14
GLU
MA
CM
echa
nica
l & E
lect
rica
l Nar
rati
ve (
Sch
emat
ic D
esig
n)15
Gre
enw
orks
Des
ign
Doc
umen
ts16
HA
RT
CR
OW
SE
RD
ata
Gap
s R
epor
t•17
HE
RIT
AG
E C
ON
SU
LTIN
G G
RO
UP
His
toric
Ince
ntiv
e M
emo
18 H
ER
ITA
GE
CO
NS
ULT
ING
GR
OU
P P
ropo
sal
19 I
NT
EG
RA
App
rais
al20
KP
FF
Con
cept
ual S
truc
tura
l Con
ditio
ns R
epor
t21
KP
FF
Exi
stin
g B
uild
ing
Tes
ting
Pro
gram
s22
KPFF
Sche
mat
ic D
esig
n St
ruct
ural
Nar
rativ
e 12
/15/
0923
KP
FF
Stru
ctur
al C
ondi
tions
Stu
dy 1
1/15
/08
24 K
PF
FTi
mbe
r Pili
ng R
epor
t25
KP
FF
Tim
ber P
iling
Stu
dy 1
2/16
/08
1 :8
KPFF
MA
RIT
IME
MU
SEU
MM
SC
MSR
MSR
MSR
MSR
Opt
ira/D
EAO
ptira
/DEA
Ota
kSE
RAST
ANTE
CHST
ANTE
CH
War
ehou
se D
. Roo
f Mem
oM
emo
of In
tere
st! P
rogr
amTe
chni
cal C
onsu
ltant
Nar
rativ
esC
ontr
act
Des
ign
docu
men
tsD
ue D
ilige
nce
Mtg
Mem
oG
reen
way
Sch
emat
ic S
olut
ions
Lase
r sca
n su
rvey
/x-r
ays
As-
built
dra
win
gsB
athy
met
ry S
urve
yLa
nd U
se R
evie
w M
emo
Envi
ronm
enta
l Dat
a G
ap R
epor
tPr
opos
al
26
27
28
29
30
31
32
33
34
35
36
37
38
EXHIBIT 2
IN THE CIRCUIT COURT FOR THE STATE OF OREGON
FOR THE COUNTY OF MULTNOMAH
Case No. 1111-15004
NOTICE OF VOLUNTARYDISMISSAL WITHPREJUDICE
PROJECT SEED, LLC, an Oregonlimited liability company,
Plaintiff,
V.
CITY OF PORTLAND, a municipalcorporation acting by and through thePortland Development Commission, andPORTLAND DEVELOPMENTCOMMISSION,
Defendants.
1 Pursuant to ORCP 54 A(1) Plaintiff hereby voluntarily dismisses this case
2 with prejudice and requests that this Court enter judgment accordingly, with each
3 party to bear its own costs.
2
DATED: March , 2013 Respectfully submitted,
By:3 Renee R. Stineman, OSB # 9946104 [email protected] Brian R. Talcott, OSB #9653716 [email protected] Dunn Carney Allen Higgins & Tongue LLP8 851 SW Sixth Avenue, Suite 15009 Portland OR 97204-1357
10 Phone: 503.224.644011 Fax: 503.224.732412 Attorneys for Plaintiff
13
Page 2—NOTICE OF VOLUNTARY DISMISSAL
CERTIFICATE OF SERVICE
CERTIFICATE OF SERVICE
I hereby certify that on March , 2013 I served a true and correct copy of the foregoingNOTICE OF VOLUNTARY DISMISSAL by:
U.S. Postal Service;
• Facsimile Service
Electronic Mail;
E Arranging for Hand Delivery
111 Federal Express.
addressed to the following named persons at their last-known address stated below:
James T. McDermott, OSB # [email protected] P. A. Connelly, OSB #[email protected] JANIK LLP101 SW Main Street, Suite 1100Portland, Oregon 97204503.228.2525 (phone)503.295.1058 (fax)Attorneys for Defendants
DATED: March , 2013 DUNN CARNEY ALLEN HIGGINS & TONGUE
• LLP
EXHIBIT 3
PROPOSED PRESS STATEMENT
The Portland Development Commission announced today that Project SEED, LLC has agreed todismiss the remaining portion of its $1.7 million lawsuit regarding the proposed redevelopmentof the Centennial Mills site. The PDC had prevailed in the Multnomah County Circuit Court,which validated PDC's use of non-binding memoranda of understanding (MOUs). ProjectSEED had planned to appeal the Circuit Court's ruling to the Oregon Court of Appeals. Toavoid the lengthy appellate process and the legal costs associated with it, and to get immediateaccess to all of Project SEED's documents and extensive work product concerning theCentennial Mills site, the PDC has agreed to pay $200,000 to Project SEED.
PDC Executive Director Patrick Quinton said:
"I am pleased that the Court has upheld the validity of PDC's non-binding MOUs andacknowledged our ability to revise a development plan to best serve the citizens of Portland. Iam also pleased that the PDC can avoid an appeal and receive Project SEED's extensive workproduct now. I believe this resolution is in the best interest of Portland's taxpayers. The PDC iseager to move forward with its efforts to redevelop the historic Centennial Mills site."
Project SEED President Shaheen Sadeghi said:
"We still believe in our project concept. However, we are pleased to settle this case as we wouldlike to move forward and concentrate our efforts on our new projects."