request for proposal (rfp no. rfp-17/tpia …
TRANSCRIPT
Page 1 of 37 (RFP-17/TPIA-PM/DHBVN/2017-18 )
REQUEST FOR PROPOSAL
(RFP NO. RFP-17/TPIA-PM/DHBVN/2017-18)
FOR
Appointment of Third Party Inspecting Agency for Quality Assurance, Inspection & Monitoring of Projects in DHBVN.
VOLUME-I
Indroduction and Terms of Reference
Page 2 of 37 (RFP-17/TPIA-PM/DHBVN/2017-18 )
VOLUME-I
General Conditions of Contracrt
Page 3 of 37 (RFP-17/TPIA-PM/DHBVN/2017-18 )
INDEX
VOLUME-I SECTION DESCPRITION
I INVITATION FOR BID
II INTRODUCTION AND TREMS OF REFERENCE
III ANNEXUURES
IV BIDDER RESPONSE FORMS
Page 4 of 37 (RFP-17/TPIA-PM/DHBVN/2017-18 )
SECTION – I
INVITATION FOR BID
(IFB)
DAKSHIN HARYANA BIJLI VITRAN NIGAM
NECESSARY TERMS AND CONDITIONS FOR BIDDERS AGAINST NOTICE INVITING TENDER RFP No. RFP-17/TPIA-PM/DHBVN/2017-18
Sr. No.
Description Bidder response Agreed/ Disagreed
1. Invitation of Bid, Section-I, Volume-1 2. Introduction And Trems Of Reference, Section-II, Volume-1I 3. Annexuures, Section-III, Volume-I 4. BIDDER RESPONSE FORMS, Section-IV, Volume-I 5. Price proposal, Volume-II 6. Payment guideline for etendering, Volume.-3 7. Annexure-x-Quality_Assurance Plan, Volume.-4 8. Labour Regulations (PWD B&R tender), Volume.-5
SECTION – II
INTRODUCTION AND TREMS OF REFERENCE
INTRODUCTION AND TREMS OF REFERENCE (ITR)
1. Background
Dakshin Haryana Bijli Vitran Nigam (DHBVN) is a Govt. of Haryana undertaking registered
under the Companies Act-1956. DHBVN inherited the distribution business of erstwhile
Haryana State Electricity Board in pursuance to second transfer scheme notified by the
Govt. of Haryana on July 1, 1999. It commenced its operations on July 1, 1999 for the
Power Distribution and Retail Supply Business in the Southern Parts of Haryana covering
the ten districts of Hisar, Fatehabad, Bhiwani, Sirsa, Faridabad, Palwal, Gurgaon, Mewat,
Rewari and Narnaul.
2. OBJECTIVES of appointing Third Party Inspecting Agency
The main objective of appointing Third Party Inspecting Agency
• Implementation of HVDS (High Voltage Distribution System) and relocation of consumer meters
is to ensure quality of
projects executed by the turnkey contractors engaged by the DHBVN during the process of
execution or on completion. The Inspecting Agency is required to inspect quality of material,
work man ship of the project, standards being followed by the turnkey contractors Generally
following type of works are being carried out by DHBVN to upgrade or strengthen its
distribution network:
• Construction of new 11 kV Feeders and LT feeders.
• Bifurcation/Augmentation & Strengthening of 11 kV Feeders and LT feeders.
• Construction of new 33/11 kV 10 MVA substation (Including Civil Works) and 33KV Lines
• Augmentation of 33 kV S/Stn and 33KV Lines
3. Scope of Work
A. Quality monitoring of turnkey projects under jurisdiction of DHBVN at site of the work on behalf of Nigam.
B. The Inspecting agency shall carry out the following tasks:-
I. To carry out the field inspection at site to check quality of work, work man ship and
standards as per Nigam specifications, relevant electricity rules for the projects
executed under the turnkey modality on behalf of DHBVN, any other duty assigned by
the Nigam not limited to the activities mentioned such as issue of satisfactory
completion certificate of the work, verification of final bills submitted by the turnkey
contractors if so assigned, verification of final quantity of material utilized at the site etc.
II. All tool and tackles required for inspecting the work will be arranged and transported at
site by the firm at own cost and expenses on receipt of information from nodal officer of
the turnkey project for carrying out the inspection every time till the completion of the
project.
III. Inspection will be carried out and information/Report will be submitted to the Nigam
within 15 days after receiving notice/information from the Nigam. The date of
inspection will be intimated to the Nigam & turnkey contractor before departing for
inspection.
The work wise number of Man days and inspection stages are as defined.
1. 10 KM of 33 kV line
Sr. No. Stages Man Days (in Number) 1. Erection of poles with fittings 1.5 2. Erection of complete line 2 3. Final inspection before CEI along
with measurement validation after removal of defects in stage 2
3
2. 10 KM of 11 kV line
Sr. No. Stages Man Days (in Number) 1. Erection of poles with fittings 1.5 2. Erection of complete line 2 3. Final inspection before CEI along
with measurement validation after removal of defects in stage 2
3
3. 10 Nos. DT S/Station
Sr. No. Stages Man Days (in Number) 1. Installation of complete DT S/stn. 0.5 2. Final inspection before CEI along
with measurement validation after removal of defects in stage 1
1
4. Augmentation 10 KM of 33 kV line
Sr. No. Stages Man Days (in Number) 1. Erection of complete line 1.5 2. Final inspection before CEI along
with measurement validation after removal of defects in stage 1
2
5. Augmentation 10 KM of 11 kV line
Sr. No. Stages Man Days (in Number) 1. Erection of complete line 1.5 2. Final inspection before CEI along
with measurement validation after removal of defects in stage 1
2.0
6. Construction of one no. 33 kV Sub-Station (with one no. 33/11kV power
Transformer) including civil works Sr. No. Stages Man Days (in Number)
1. After 10% construction 1 2. After 90% Construction 2 3. Final inspection before CEI along
with measurement validation after removal of defects in stage 2
2
7. LVDS including meter relocation per 100 consumer
Sr. No. Stages Man Days (in Number)
1. Erection of complete work 1.5 2. Final inspection before CEI along
with measurement validation after removal of defects in stage 1
1.5
8. Any other type of work not included under the above categories:
Sr. No.
Stages Man Days (in Number)
a. For works below Rs 10.00 lacs value 1. Erection of complete work 1 2. Final inspection before CEI along with
measurement validation after removal of defects in stage 1
2
b. For works between Rs 10.00 to 25.00 lacs value 1. Erection of complete work 2.0 2. Final inspection before CEI along with
measurement validation after removal of defects in stage 1
3.0
c. For works between Rs 25.00 to 50.00 lacs value 1. Erection of complete work 2.5 2. Final inspection before CEI along with
measurement validation after removal of defects in stage 1
4
d. For works between Rs 50.00 to 100.00 lacs value 1. Erection of complete work 4 2. Final inspection before CEI along with
measurement validation after removal of defects in stage 1
6.5
e. For works between Rs 01.00 to 2.00 crores value 1. Erection of complete work 4.5 2. Final inspection before CEI along with 8.5
4. Physical Area of Work
Any where under the jurisdiction of dakshin haryana bijli vitran nigam.
4.1. Pre-Bid Conference
4.1.1. The pre-bid conference will be held on date mentioned in RFP. The bidder may
request for clarification or changes in the tender documents by submitting the
issues in writing befor one working day before the pre-bid conference date. The
issues would be discussed in presence of all the prospective bidders, who wish
to be present on the pre-bid conference.
4.1.2. After thorough discussions held during the pre-bid conference, the dhbvn shall
prepare record notes of discussions, if required, and upload the same on the
website for information of the bidders.
4.1.3. The dhbvn may modify the tender documents by issuing addendum as a result
of a request or clarification discussed during the pre-bid conference.
4.2. Submission of bids
4.2.1. Bids must be submitted in two parts namely ‘proof of eligibility’ and ‘financial
proposal’. Both ‘proof of eligibility’ and financial proposal would be submitted
together on the date of submission of tenders mentioned earlier. Only those
bidders whose eligibility proofs are found complete in all respect and fulfil the
requisite criteria shall be called for the opening of the financial proposal.
5.
5.1.1 The bidder should have minimum experience of 5 years in Quality assurance,
inspection & monitoring of turnkey projects for electric power
distribution/transmission projects. During these 5 years the bidder should
experiance of the single contract of at least two year for quality assurance,
inspection & monitoring of turnkey projects with at least one Govt. owned
Discoms / SEB’s /Power Departments / CPSUs.
Pre Qualification Criteria and Proof of Eligibility 5.1 The bidders are required to fulfil the following essential conditions of eligibility criteria
for its technical and financial evaluation of bid proposal and shall furnish adequate form,
statements and documentary evidence/certificates in proof of the same:
measurement validation after removal of defects in stage 1
f. For works beyond Rs 02.00 crores value, the no. of mandays shall be calculated on the basis of a. to e. above.
The bidder shall submit experience and performance certificates from the owners
for the works completed by them in the past in support of the above
requirements and other relevant documents to support the credentials,
experience, turnover etc.
5.1.2 Previous Performance of the bidder with Power utilities of Haryana during last
five years must be satisfactory if the bidder has worked with these utilities. Self
certification is required to be submitted by the firm. Any wrong declaration may
lead termination of the contract at any stage without prior notice and blacklisting
the bidder for at least three year.
5.1.3 The Bidder should submit the earnest money deposit (EMD) and the tender
purchase fees as mentioned in the tender documents in shape of Demand Draft
payable at Hisar in favour of DGM/F&A/MM, DHBVN, Hisar.
5.1.4 The Bidder should be a registered legal entity duly incorporated under the
relevant laws.
5.1.5 They should be a registered legal entity and should possess ISO-9001
certificate. Bidder shall have adequately qualified and experienced engineers
with capability of executing such type of assignments. The project in charge
should possess minimum Bachelor of Electrical Engineering degree or its
equivalent with a minimum relevant post qualification experience on similar jobs
of 8 years in the power distribution sector and shall be assisted by at least ten
engineers having educational qualification Bachelor of Electrical Engineering
degree or its equivalent with a minimum relevant post qualification experience
on similar jobs of 5 years in the power distribution sector. The the project in
charge and inspecting Engineers should possess minimum Bachelor of
Electrical Engineering degree with minimum 60% of marks with a minimum
relevant post qualification experience as mentioned above on similar jobs and
will not be more than 65 years of age at the time of last date of submission of
bid.
5.1.6 Bidders have to supply minim 11 nos. CVs (1 no for project in-charge and 10
no. for inspecting engineers) duly dated signed by the concerned engineer and
should not be later then last date of submission of bid and same must be duly
attested by the authorized signatory of the firm. Also submit the proof regarding
date of joining the firm. Generally, no change in the manpower is allowed,
however, in unavoidable circumstances, can be replaced with a person having
equal or better qualification and experience.
5.2 FINANCIAL QUALIFICATION REQUIREMENTS: 5.2.1 Min. annual turnover of Rs.5 cr. in any of the last three financial years.
5.2.2 Min. cumulative turnover of Rs. 12 cr. in last Three years.
5.3 The bidder shall furnish following documents/details with its bid: 5.3.1 Documentary evidence/certificates as a proof of meeting the QR.
5.3.2 The complete annual reports together with Audited statement of
accounts of the firm company for last three years (separate),
immediately preceding the date of submission of bid.
5.3.3 Information regarding any litigation, current or during the last
two years, in which the Bidder is involved, the parties
concerned and disputed amount.
5.3.4 The declaration by the firm on NJSP that it is not blacklisted by any
State/Center Govt or Agency and shall be liable for the
consequences of wrong declaration. The bidder should submit along
with the Bid no blacklisting certificate for the past three years.
5.3.5 Copies of original documents defining the constitution or legal
status, place of registration and principal place of business, written
power of attorney of the signatory of the Bidder to commit the Bid.
5.3.6 Bidders who do not meet the above criteria shall not be evaluated
further in the bidding process. A Bidder shall be disqualified if it is
determined by DHBVN at any stage of bidding process that the Bidder
has made misleading or false representation in the form, statements
and attachments in the proof of the qualification requirements. The
bidders shall also be disqualified if it fails to continue to satisfy the
Qualifying Criteria during any stage of the evaluation process.
Supplementary information or documentation regarding qualifications
may be sought from the Bidders at any time and must be so provided
within a reasonable time frame as stipulated by the Client.
6. Financial proposal The bidder shall submit the financial offer in the format, in separate sealed envelope,
as per Annexure attached. In preparing the financial proposal, bidders are expected
to take into account the requirements Financial Proposal, bidders and conditions
outlined in the tender documents.
7. EVALUATION Methodology
7.1 The ‘proof of eligibility’ shall be opened immediately after the deadline for bid
submission.
7.2 At the time of opening, the DHBVN representatives will carry out a preliminary
examination to ensure that they are complete, whether the EMD and the processing
fees have been submitted, whether the documents have been properly signed, and
whether the documents are generally in order. In case EMD or the tender purchase
fees is not received with the tender, the bid will be rejected out rightly and the tender
will not be opened.
7.3 Bidding company having not furnished the entire requisite within the stipulated time
period shall be rejected.
7.4 The DHBVN will open the financial bids of technically qualified bidders, on a pre-
decided date, in the O/o CE/P&D in the presence of bidders or their authorised
representatives who choose to be present. In case the opening date happens to be
or is declared a holiday, the bid shall be opened on the next working day at the same
place and time unless notified otherwise.
7.5 DHBVN reserves the right to negotiate both the scope of work and financial
proposals with the successful bidders.
8. Award of contract
8.1 The contract will be awarded following the negotiations and agreement shall be
signed between the selected bidders and DHBVN. In case there is a single bidder to
the assignment, then it shall be the DHBVN sole decision to go ahead with the
bidding or not. Any decision made by the DHBVN in this regard shall be considered
as final.
8.2 Within fifteen (15) days of the Notification of the Award the successful Bidder shall
sign and date the contract and return it to the awarding authority. In case the
successful Bidder fails to submit the Contract Agreement duly signed within 15 days
from the date of LoA, the LoA shall be withdrawn and the EMD shall be forfeited.
8.3 The successful bidder shall be required to enter into a contract and deposit a
performance bank guarantee (in the attached Performa) or submit a D.D./Bankers
Cheque worth Rs. 5 lakh towards faithful performance of the contract payable at
Hisar and drawn on a Nationalized Bank in favour of ‘DGM/F&A/PD&C, DHBVN,
Hisar’ within 15 days from the date of issue of LoA, which shall be refunded without
any interest after successful completion of the contract. Security in any other form
shall not be accepted.
8.4 The Bank charges, if any, shall be to the account of the Bidder.
8.5 In case the performance bank guarantee or DD in lieu of performance security is not
submitted within 15 days of the date of LoA
i. The issue of the work order/contract shall be withheld by the concerned authority till
the receipt of Performance Bank Guarantee or DD/Bankers Cheque in lieu of
performance security.
ii. Penalty @ 0.35% per week or part thereof of the value of the BG would be charged
from the due date of submission, till the BG or DD in lieu of performance security is
not submitted by the firm.
iii. In case the Performance Bank Guarantee or DD/Bankers Cheque in lieu of the
Performance Security is not submitted within 45 days from the date of issue of issue
of LoA or the date if any as stipulated by the tender inviting authority, the DHBVN
reserves the right to cancel the LoA, forfeit the earnest money deposited by the
bidder and initiate the action for allotment to L-2 firm at L-1 rate or below.
iv. However before the expiry of above mentioned 45 days, the consultinf agency may
seek approval for grant of additional 1 month (maximum) on payment of the entire
penalty amount for 45 days as mentioned above. The grant of one month will not
entitle the firm to claim the extension during of duration of assignment.
Note: - BG would be issued by any scheduled bank in branch situated in Hisar. 8.6 All payments will be made only after successful completion of the assignment as per
the terms of the agreement/contract signed between the Consultant and the DHBVN.
8.7 All establishment charges will be inclusive and no extra charges will be paid by
DHBVN.
9. Contract Period
The contract period shall be 24 months from the date of LoA.
10. Drop Dead
DHBVN may, at any stage and in its sole discretion discontinue this
assignment and terminate the services of the consultant by giving a 15 days notice in
advance.
11. Terms of Payment
11.1 The invoices against the inspection of material / execution of works carried shall be
raised directly to the concerned office which issues the letter of Inspection
Authorization. The payment shall be made on 30th day of submission of the bill and
requisite documents to the executing office by the inspecting agency after attending
the discrepancies/shortcomings, if any pointed out by the Engineer-in-
charge/Executing office.
11.2 A rebate of 0.35 percent per week or part thereof shall be availed off by the Nigam if
payment is made earlier than the period specified above.
11.3 The delay in payments to the inspecting agency beyond the stipulated period
indicated in the bid document, unless supported by cogent reasons and approved by
a higher authority, would attract penal interest on the defaulting amount @ Rs. 0.15/-
per one thousand per day of delay beyond the stipulated.
12. Taxes and Duties
a. The final payment under this Clause shall be made only after satisfactory
completion of the activities mentioned in the Scope of Work.
b. If any excess payment has been made by the DHBVN due to difference in
price agreed and Inspecting Agency’s invoice, the amount will be deducted
from the bills of Inspecting Agency
c. The Inspecting Agency and the personnel shall pay all kind of taxes, duties,
fees, levies and other impositions levied under the existing, amended or
enacted laws during life of this contract and the Nigam shall perform such
duties in regard to the deduction of such tax as may be lawfully imposed.
d. The TDS will be deducted from the due payment as per applicable rates at the
time of payment.
e. Payment of taxes/duties shall not be made separately in any case. However,
service tax will be paid by DHBVN as per applicable rates at the time of
payment.
13. Confidential Information
The Inspecting Agency and the personnel of any of them shall not either during the
term or within two (2) years after the expiration of this contract, disclose any
proprietary or confidential information relating to the Project, the Services, this
Contract or the Owner’s business or operations without the prior written consent of
the owner.
14. Subcontracting
No sub contracting, consortium or joint venture is permitted.
15. Settlement of Disputes
a. If any dispute or difference of any kind whatsoever will arise between the consultant
and the DHBVN in connection with or arising out of the Contract, the parties will
make every effort to resolve amicably such dispute of difference by mutual
consultation.
b. If after thirty (30) days the parties have failed to resolve their dispute or difference by
such mutual consultation, then either party may give notice to the other, of its
intention to commence arbitration, as hereinafter provided, as to the matter in
dispute, and no arbitration in respect of the matter may be commenced unless such
notice is given.
16. Arbitration
All matter questions, disputes, differences and /or claims arising out of and/or
concerning and/or in connection and/or in consequences or relating to this
contract/agreement whether or not obligations of either or both parties under this
contract to subsisting of the time of such dispute and whether or not this
contract/agreement has been terminated or purported to be terminated or completed,
shall be referred to the sole arbitration of the MD, DHBVN or an officer appointed by
the M.D. DHBVN or his nominee .The award of the Arbitrator shall be final and
binding on the parties to this contract. The Arbitrator may from time to time may
enlarge the time for making the award with the consent of the parties to the
agreement.
17. Failure to execute the contract and effecting recoveries
17.1 Short listed Bidder failing to execute the order placed on them to the
satisfaction of the DHBVN under terms and conditions set forth therein or
failing to complete the contract, will be liable to make good the loss sustained
by the DHBVN consequent to the placing of fresh orders elsewhere at higher
rate i.e. the difference between the original prices and prices at which fresh
contract has been placed.
17.2 Any loss or penalty, arising due to non-fulfilment of this contract or any other
contract, will be adjusted after encashment of the performance bank guarantee
or any other amount due to the short listed Bidder from the DHBVN from this
contract as well as from other contract
17.3 The inspecting agency will complete the assignment within 10 days of receipt of
the information form authorizing DHBVN office through Fax/e-mail or any other
communication media. The inspection report should reach to the concerned
office issuing the Letter of Authorisation of Inspection within 15 days from the
date of authorisation. If the assignment is not carried out and report is not
received within the specified period or delayed, penalty @ Rs. 10,000/- per
week or part thereof during first 2 weeks or part thereof will be charged. A
penalty of Rs 25,000/- per week or part thereof will be levied for not carrying
out any job assigned or carried out after a delay of 2 weeks. If the delayed
assignments exceeds equal to or more than twenty and ten or more
assignments are not carried out during the contract period of two years, an
amount equal to 10% of total payment made during the period will be deducted
from the Contract Performance Guarantee or from the due payment. This will
be in addition to the normal penalty.
17.4 DHBVN reserve right to cross check the material and site inspected by the third
party inspecting agency. If pseudo inspection is noticed or quality of material
inspected by the inspecting agency is found of poor quality and results are not
within permissible limit as specified in the specification/relevant ISS/Electricity
rules then on first default a penalty of Rs. 0.5 lacs, on second default a penalty
of Rs.1.0 lakh and on third default contract be terminated and contract
performance Guarantee submitted by the firm will be forfeited and case for
black listing of firm may be initiated. Any terms and condition not mentioned in
the document will be applicable as per procurement manual of the Nigam and
amendments thereof which is available at the Web-Site www.dhbvn.com.
17.5 Any terms and condition not mentioned in the document will be applicable as
per procurement manual of the Nigam and amendments thereof which is
available at the Web-Site www.dhbvn.com .
18.
The e-tendering sytem has been introduced in DHBVN through the portal
Important Instructions to Bidders for e-tender:
https://haryanaeprocurement.gov.in. The existing instructions to the bidders are for the offline mode of submission of tenders. But, with the introduction of e-tendering mode, the procedures as laid down below shall be followed. In the event of contradiction between the existing ITR for offline mode and following instructions for e-tendering, the procedures of e-tendering shall govern.
1.
All the bidders intending to participate in the tenders processed online are required to get registered on the centralized e - Procurement Portal i.e.
Registration of bidders on eProcurement Portal:-
https://haryanaeprocurement.gov.in. Please visit the website for more details. 2.
2.1 The Bids submitted online should be encrypted and signed electronically with a Digital Certificate to establish the identity of the bidder bidding online. These Digital Certificates are issued by an Approved Certifying Authority, by the Controller of Certifying Authorities, Government of India.
2.2 A Digital Certificate is issued upon receipt of mandatory identity (i.e. Applicant’s PAN Card) and Address proofs and verification form duly attested by the Bank Manager / Post Master / Gazetted Officer. Only upon the receipt of the required documents, a digital certificate can be issued. For more details please visit the website – https://haryanaeprocurement.gov.in.
2.3 The bidders may obtain Class-II or III digital signature certificate from any Certifying Authority or Sub-certifying Authority authorized by the Controller of Certifying Authorities or may obtain information and application format and documents required for the issue of digital certificate from:
M/s Nextenders (India) Pvt. Ltd. O/o. DS&D Haryana, SCO – 09, IInd Floor,
Obtaining a Digital Certificate:
Sector – 16, Panchkula – 134108 E - mail: [email protected] Help Desk: 1800-180-2097 (Toll Free Number) 2.4 Bid for a particular tender must be submitted online using the digital certificate
(Encryption & Signing), which is used to encrypt the data and sign the hash during the stage of bid preparation & hash submission. In case, during the process of a particular tender, the user loses his digital certificate (due to virus attack, hardware problem, operating system or any other problem) he will not be able to submit the bid online. Hence, the users are advised to keep a backup of the certificate and also keep the copies at safe place under proper security (for its use in case of emergencies).
2.5 In case of online tendering, if the digital certificate issued to the authorized user of a firm is used for signing and submitting a bid, it will be considered equivalent to a no-objection certificate/power of attorney /lawful authorization to that User. The firm has to authorize a specific individual through an authorization certificate signed by all partners to use the digital certificate as per Indian Information Technology Act 2000. Unless the certificates are revoked, it will be assumed to represent adequate authority of the user to bid on behalf of the firm in the department tenders as per Information Technology Act 2000. The digital signature of this authorized user will be binding on the firm.
2.6 In case of any change in the authorization, it shall be the responsibility of management / partners of the firm to inform the certifying authority about the change and to obtain the digital signatures of the new person / user on behalf of the firm / company. The procedure for application of a digital certificate however will remain the same for the new user.
2.7 The same procedure holds true for the authorized users in a private/Public limited company. In this case, the authorization certificate will have to be signed by the directors of the company.
3
Tender document can be downloaded online. Bidders are required to pay the tender documents fees online using the electronic payments gateway service. For online payments guidelines, please refer to the Home page of the e-tendering Portal
Opening of an Electronic Payment Account:
http://haryanaeprocurement.gov.in. 4
In order to bid online on the portal Pre-requisites for online bidding:
http://haryanaeprocurement.gov.in , the user machine must be updated with the latest Java. The link for downloading latest java applet is available on the Home page of the e-tendering Portal.
5
The bidders can view the detailed NIT and the time schedule (Key Dates) for all the tenders floated through the single portal eProcurement system on the Home Page at
Online Viewing of Detailed Notice Inviting Tenders:
http://haryanaeprocurement.gov.in.
6
The tender documents can be downloaded free of cost from the e-Procurement portal Download of Tender Documents:
http://haryanaeprocurement.gov.in. 7 Key Dates:
The bidders are strictly advised to follow dates and times as indicated in the online Notice Inviting Tenders. The date and time shall be binding on all bidders. All online activities are time tracked and the system enforces time locks that ensure that no activity or transaction can take place outside the start and end dates and the time of the stage as defined in the online Notice Inviting Tenders.
8
(A) If bidder fails to complete the Online Bid Preparation & Submission stage on the stipulated date and time, his/hers bid will be considered as bid not submitted, and hence not appear during tender opening stage.
Bid Preparation (Technical & Financial) Online Payment of Tender Document Fee, eService fee, EMD fees and Submission of Bid Seal (Hash) of online Bids:
8.1 The online payment for Tender document fee, eService Fee & EMD can be done
using the secure electronic payment gateway. The Payment for Tender Document Fee and eService Fee can be made by eligible bidders/ contractors online directly through Debit Cards & Internet Banking Accounts and the Payment for EMD can be made online directly through RTGS / NEFT.
The secure electronic payments gateway is an online interface between contractors and Debit card / online payment authorization networks.
8.2 The bidders shall upload their technical offer containing documents , qualifying
criteria, and all other terms and conditions except the rates (price bid). The bidders shall quote the prices in price bid format. 8.3 Submission of bids will be preceded by submission of the digitally signed & sealed
bid (Hash) as stated in the time schedule (Key Dates) of the Tender. NOTE:-
(B) Bidders participating in online tenders shall check the validity of his/her Digital Signature Certificate before participating in the online Tenders at the portal http://haryanaeprocurement.gov.in.
(C) For help manual please refer to the ‘Home Page’ of the e-Procurement website at https://haryanaeprocurement.gov.in, and click on the available link ‘System Requirement” to download the file.
SECTION – III
ANNEXURES
Annexure I Proof of eligibility (i) Details of EMD and tender fees submitted (DD/Cheque no. and date) as per the
requirements mentioned in the tender documents.
(ii) Proof of Organization as a legal entity under relevant laws.
(iii) FINANCIAL STATEMENTS OF THE LAST THREE FINANCIAL YEARS FOR BIDDER-
bidders are required to attach Balance sheet and Profit & Loss statement of last three
years. (IV) Proof/Citation of experience and performance.
(v) Declaration by the firm that it is not black listed by any Govt. or Agency for past three
years and also have no litigation during the period.
(vi) Approach and Methodology as per format.
(vii) Technical and Financial proposals.
(viii) List of cities where the firm has its offices
(ix) Format of Manpower Details – Sr. No. Manpower Details work
experience (years)
Qualification Key Projects Describing the skill set of Team member
Annexure-II RELEVANT EXPERIENCE OF TEAM, PROPOSED TEAM STRUCTURE AND STAFFING SCHEDULE In this section the Bidders should elaborate the team structure proposed, relevant
experience of team and staffing schedule for the Services covered under the Proposal. The
format to be used for submitting CVs of the team members is attached along with a format
to be used for Staffing Schedule Format to be used for submitting Curriculum Vitae (CV) of
Team Members
1. Proposed Position [only one candidate shall be nominated for each position]:
2. Name of Firm [Insert name of firm proposing the staff]:
3. Name of Staff [Insert full name]:
4. Date of Birth: Nationality: 5. Education[Indicate college/university and other specialized education of staff
member, giving names of institutions, degrees obtained, and dates of obtainment]:
6. Membership of Professional Associations: 7. Other Training [Indicate significant training since degrees]:
8. Countries of Work Experience: [List countries where staff has worked in the last ten
years]:
9. Languages [For each language indicate proficiency: good, fair, or poor in speaking,
reading, and writing]:
10. Employment Record [Starting with present position, list in reverse order every
employment held by staff member since graduation, giving for each employment (see
format here below): dates of employment, name of employing organization, positions held.]:
From [Year]: To [Year]:
Employer:
Positions held:
11. Detailed Tasks Assigned
[List all tasks to be performed
under this assignment]
12. Work Undertaken that Best Illustrates
Capability to Handle the Tasks Assigned
[Among the assignments in which the staff
has been involved, indicate the following
information for those assignments that
best illustrate staff capability to handle
the tasks listed under point 11.]
Name of assignment or project: Year:
Location:
Client:
Main project features:
Positions held:
Activities performed:
(Signature of staff member)
13. Declaration:
I,--------------------- being authorized signatory of the firm, certify that this CV correctly
describes qualifications and experience of Sh-------------------. I understand that any
misstatement described herein may lead to disqualification of firm at any stage.
Date: (Authorized Signatory of the firm)
Annexure III Format for Bank Guarantee PROFORMA OF BANK GUARANTEE FOR CONTRACT PERFORMANCE (To be stamped in accordance with stamp Act)
Ref: ………………………. Bank Guarantee No………………
Dated …………………………...
To
The Chief Engineer/P&D,
DHBVN,Vidyut Sadan,
Vidyut Nagar,
Hisar-125005.
Dear Sirs,
In consideration of DHBVN (hereinafter referred to as the ‘Owner’ which expression
shall unless repugnant to the context or meaning thereof include its successors,
administrators and assigns) having awarded to M/S ……………… with its registered/Head
office at ………………………(herein after referred to as the Contractor which expression
shall unless repugnant to the context or meaning thereof, include its successors,
administrators, executors and assigns ), a Contract by issue of Owner’s Letter of Award
No.………………………..dated ……………and the same having been unequivocally
accepted by the Contractor, resulting in a Contact bearing
No.…………………Dated…………………Valued at ………………………..
for………………………(Scope of Contract) and the Contractor having agreed to provide a
Contract Performance Guarantee for the faithful performance of the entire Contract equivalent
to ……………….. of the said value of the Contract to the Owner.
We …………………………………………………………………………(Name and Address of
the Bank ).
Having its Head Office at ……………………(hereinafter referred to as the ‘Bank’ which
expression shall, unless repugnant to the context or meaning thereof, include its successors,
administrators, executors and assigns) do hereby guarantee and undertake to pay the
Owner, on demand any and all monies payable by the Contractor to the extent
of………………………….. as aforesaid at any time upto
………………………..(days/month/year) without any demur, reservation, contest recourse or
protest and/or without any reference to the Contractor.
Any such demand made by the owner on the Bank shall be conclusive and binding
notwithstanding any difference between the owner and the Contractor or any dispute
pending before any Court, Tribunal, Arbitrator or any authority. The Bank undertakes not to
revoke his guarantee during its currency without previous consent of the Owner and further
agrees that the guarantee herein contained shall continue to be enforceable till the Owner
discharges this guarantee.
The Owner shall have the fullest liberty without affecting in any way the liability of the Bank
under this guarantee, from time to time to extend the time for performance of the contract by
the Contractor. The Owner shall have the fullest liberty, without affecting this guarantee to
postpone from time to time the exercise of any powers vested in them or any right which they
might have against the Contractor, and to exercise the same at any time in any manner and
either to enforce or to for bear to enforce any covenants, contained or implied, in the
Contract between the Owner and the Contractor or any other course or remedy or security
available to the owner. The Bank shall not be released or its obligations under these
presents by any exercise by the Owner of its liberty without reference in the matters
aforesaid or any of them or by reason of any other Act of omission or commission on the part
of the Owner or any other indulgences shown by the Owner or by any other matter or thing
whatsoever which under law would but for this provision have the effect of relieving the Bank.
The Bank also agrees that the Owner at its option shall be entitled to enforce this a
guarantee against the Bank as a principal debtor, in the first instance without proceeding
against the Contractor and notwithstanding any security or other guarantees the owner may
have in relation to the Contractor’s liabilities.
Notwithstanding any thing contained herein above our liability under this guarantee is
restricted to……………………….And it shall remain in force upto and including……..and
shall be extended from time to time for such period as may be desired by M/S
…………………………………. On whose behalf this guarantee has been given.
Dated this…………………….Day of……………………2015 at…………………..
WITNESS
……………………….. …………………………….
(Signature) (Signature )
……………………….. ……………………………..
(Name) (Name)
……………………………..
(Official Address) (Designation with Bank Stamp) Attorney as per Power Of Attorney No:.……………………. Date:………………. Note:
The stamp papers of appropriate value shall be purchased in the name of issuing Bank.
Annexure lV Contract agreement This CONTRACT (hereinafter called the "Contract") is made on ___day of ____ by and
between Dakshin Haryana Bijli Vitran Utilities Ltd. (hereinafter referred as the “Client”)
having its principal place of business at Vidyut Sadan, Vidyut Nagar, Hisar, 122025 and
_______________ (hereinafter referred as the “Inspecting Agency” and abbreviated
as_______ having its principal office located at ________________________.
WHEREAS
(a) The Client has requested the Inspecting Agency to provide certain services for DHBVN
as defined in the bid document no._____ dated _____ and through letter of Award bearing
DHBVN reference vide memo number _________ dated __________ and confirmation of
the same by Inspecting Agency vide letter dated ________.
(b) The Inspecting Agency, having represented to the Client vide their bid that they have the
required professional skills, and personnel and technical resources, have agreed to provide
the Services on the terms and conditions set forth in this Contract.
NOW THEREFORE the parties hereto hereby agree as follows:
1. The following documents attached hereto shall be deemed to form an integral part of this
Contract:
(a) The tender document and its subsequent addendums (if any) which shall include the
(b) The client’s letter of award to the Inspecting Agency
(c) The consultant’s acceptance letter against the letter of award.
2. The mutual rights and obligations of the Client and the Inspecting Agency shall be as set
forth in the Contract; in particular:
(a) The Inspecting Agency shall carry out the Services in accordance with the provisions of
the Contract; and
(b) The Client shall make payments to the Inspecting Agency in accordance with the provisions of the Contract.
IN WITNESS WHEREOF, the Parties hereto have caused this Contract to be signed in their
respective names as of the day and year first above written.
FOR THE CLIENT FOR THE INSPECTING AGENCY
Signed by Signed by
Title: Title:
SECTION – IV
BIDDER RESPONSE FORMS
BIDDER RESPONSE FORMS Form No F-1: BID Submission Sheet From: <Bidder> To: DHBVN ______________ _______ _____________________ _____________________ _____________________ _____________________ _____________________ _____________________ _____________________ Sir, Appointment for Inspecting Agency . I/we ____________________________________ Firm herewith enclose BID for appointment of my/our firm as Inspecting Agency for ________________. I/We hereby accept and abide by the scope & terms and conditions of BID document unconditionally. I/we ____________________________________ Firm also undertake that in case of the award of consultancy assignment for the Nigam / utilities, to provide services for the proposed assignment, we and any of our affiliates, will not be eligible to work as contractor for turnkey projects or in any other capacity with the Nigam during the currency of the quality monitoring assignment. I/we undertake to open office at the head quarter of DHBVN. Yours faithfully,
Signature : _________________ Full Name : _________________ Address : _________________
Form No F-2: Certificate as to Corporate Principal CERTIFICATE AS TO CORPORATE PRINCIPAL
Signature :
(To be signed by any of Board Directors or Co.Secry) I _______________________ certify that I am _________________ of the Company under the laws of __ _______________ and that __________________ who signed the above tender is authorised to bind the Company / Firm by authority of its governing body.
_________________ Seal: Full Name
_________________
Form No F-3a: Project Experience Kindly provide relevant Project Experience of the Firm's relevant past experience in either: Expe rie nce for qua lity monitoring work for s upe rvis ion of e xe cution of e le ctric powe r distribution/ transmission projects of Govt. owned Discoms/SEB’s/Power Departments/ CPSUs. Va lue a nd Ye a r of a wa rd/ comple tion of a s s ignme nts . Role of the Firm in a s s ignme nt Applica tions / Module s worke d on by the Firm Sl. No.
Assignment
Year Value of Assignment
Role of Firm
Client & Business
Award Completion
Please provide proof of completed assignments.
Signature
_________________ Seal: Full Name
_________________ Address : _________________
Form No F-3b: Performance Certificate Kindly provide Client Performance Certificates for the completed projects provided for Form No F-3a stating the role, value, Year of award/ completion and broad scope of work of the engaged firm and the client’s satisfaction level. Or Copy of LoA/ Work Order along with proof of release of final payment
Form No F -4: Company Information Kindly provide the following details for the Firm and Consortium Members: 1 Name of the Firm:______ ____________________________ 2 Individual and Cumulative Turnover in the Last three audited financial years (in Rs): Firm
Year 2006-07
Year 2007-08
Year 2008-09
Total
<Amount in Rs >
<Amount in Rs >
<Amount in Rs >
<Amount in Rs >
(Please provide Published Annual Account for Balance Sheet and Profit and Loss statements as Proof)
Signature : _________________ Seal: Full Name
_________________
Form No F-5: Approach and Methodology Approach & Methodology, Team Composition and Task Assignment
Technical approach, methodology and work plan are key components of the Technical
Proposal. The Participants are suggested to present their approach, methodology and work
plan in maximum 50 pages, inclusive of charts and diagrams, dividing into the following
three chapters:
a) Technical Approach and Methodology,
b) Work Plan, and
c) Organization and Staffing,
a) Technical Approach and Methodology: In this chapter, understanding of the
objectives of the assignment, approach to the services, methodology for carrying out
the activities and obtaining the expected output, and the degree of detail of such
output shall be explained. The problems areas to be addressed and their importance
shall be highlighted along with explanation of the technical approach; the
participants will adopt to address them. The participants shall also explain the
methodologies they propose to adopt including the compatibility of those
methodologies with the proposed approach.
b) Work Plan: In this chapter, the main activities of the assignment, their content and
duration, phasing and interrelations, milestones (including interim approvals by the
Client), and delivery dates of the reports shall be included. The proposed work plan
should be consistent with the technical approach and methodology, showing
understanding of the SoW and ability to translate them into a feasible working plan. A
list of the final documents, including reports, drawings, and tables to be delivered as
final output, should be included here. The work plan should be consistent with the
Deliverables and Time Schedule.
c) Team Composition and Task Assignment: In this chapter, the structure and
composition of team and the task assignment to each team member shall be
highlighted in the table given below. It should be based on main activities/tasks of
the assignment and the key expert assigned to that activity/task.
Name of Staff Area of Expertise Position Assigned Task Assigned
Signature : _________________ Attestation by
authorized Signatory Full Name
_________________
Form No F-6: Deviations/No Deviations Confirmation, Comments & Suggestions
Signature :
DEVIATIONS/COMMENTS/ SUGGESTIONS OF CONSULTANT On the Scope of Work, or any related area: 1. 2. 3. 4. (In case of no deviations, a statement to that effect must be given)
_________________ Seal Full Name
_________________ Address : _________________