LEGAL POSITION OF THE ISSUES ASSOCIATED WITH
MAIN CONTRACTOR’S INSOLVENCY
NG SOCK HOOI
A project report submitted in partial fulfilment of the
requirement for the award of the degree of
Master of Science (Construction Contract Management)
Faculty of Built Environment
Universiti Teknologi Malaysia
JULY 2006
v
ABSTRACT
The East Asian Financial crisis has resulted in long-term financial
difficulties, which translated into high level of insolvency especially in the sector of
construction. Among the construction insolvency, the insolvency of a main
contractor is the frequent occurrence. This has brought issues or problems to the
sub-contractor who would become unsecured creditors in the event of main
contractor’s insolvency. The aim of this study is to determine the legal positions
relating to issues faced by sub-contractor in the event of main contractor’s
insolvency. The issues that commonly arise are direct payment, retention fund, set-
off, materials and goods, determination, novation etc. However, this study would
only focus on the legal positions of the critical issues specifically: direct payment,
retention fund, unfixed materials and goods, set-off and determination. The critical
issues are those issues that are commonly arising. There are valid and invalid
positions for each of the issue arise. For example, the valid position in direct
payment means that the employer entitled to pay sub-contractor direct. While,
invalid position is the sub-contractor not entitle to be paid directly by employer. The
legal positions for each issue can protect the interaction of sub-contractor in the
event of main contractor’s insolvency. Therefore, the sub-contractor can use this
study as guidance when dealing with those issues.
vi
ABSTRAK
Krisis kewangan Asia Timur telah menyebabkan kesukaran kewangan yang
berjangka panjang. Ini telah mengakibatkan kejadian tak solvent yang begitu tinggi.
Di antara kesemua jenis tak solvent yang berlaku dalam sector pembinaan, kejadian
kontraktor utama yang tak solvent adalah yang paling banyak berlaku. Kejadian ini
telah mendatangkan pelbagai isu dan masalah kepada sub-kontraktor yang rendah
kedudukannya serta akan menjadi pemiutang tak sekure dalam kejadian sedemikian.
Kajian ini bertujuan untuk mengenalpasti keadaan perundangan bagi isu yang
dihadapi yang sub-kontraktor dalam kejadian kontraktor utama yang tak solvent.
Isu-isu yang dihadapi oleh su-kontraktor adalah bayaran terus, wang tahanan,
pemotongan bayaran, bahan-bahan binaan, penamatan kontrak, bon dan jaminan
serta pertukaran pelaksanaan. Namun begitu, kajian ini hanya tertumpu ke atas isu-
isu yang kritikal iaitu bayaran terus, wang tahanan, pemotongan bayaran, bahan-
bahan binaan dan penamatan kontrak. Isu yang kritikal adalah isu yang selalunya
timbul. Terdapat keadaan yang berjaya dan gagal bagi setiap isu yang timbul.
Contoh, isu bayaran terus, keadaan yang boleh diamalkan adalah dimana majikan
boleh bayar sub-kontraktor secara terus. Oleh itu, sub-kontraktor boleh menjadikan
kajian ini sebagai panduan dalam menyelesaikan masalah kontraktor utama yang tak
solvent.
vii
TABLE OF CONTENT
CHAPTER TITLE PAGE
DECLARATION ii
DEDICATION iii
ACKNOWLEDGMENTS iv
ABSTRACT v
ABSTRAK vi
TABLE OF CONTENT vii
LIST OF CASES x
LIST OF FIGURE xiv
1 INTRODUCTION 1
1.1 Background Study 1
1.2 Problem Statement 6
1.3 Objective of Study 9
1.4 Scope and Limitation of Study 9
1.5 Significance of Study 10
1.6 Research Methodology 10 1.6.1 First Stage: Identifying the Research Issue 11 1.6.2 Second Stage: Literature Review 11 1.6.3 Third Stage: Data Collection 12 1.6.4 Fourth Stage: Data Analysis 12
viii
1.6.5 Fifth Stage: Conclusion and Recommendations 12
1.7 Chapter Organisation 14
2 SUB-CONTRACTING 15
2.1 Introduction 15
2.2 Reasons for Sub-Contracting 16
2.3 The Contractual Chain 17
2.4 Relationship between Main Contractor and Sub-Contractor 18
2.5 Relationship between Employer and Sub-Contractor 21
2.6 Important Terms in Sub-Contract 22 2.6.1 Direct Payment Clause 22 2.6.2 Retention Fund 24 2.6.3 Determination 25 2.6.4 Set-off 28 2.6.5 Liquidated and Ascertained Damages for Delay 29
2.7 Summary 30
3 INSOLVENCY 31
3.1 Introduction 31
3.2 Terminology and Governing Statute 32 3.2.1 Corporate Insolvency 32 3.2.2 Bankruptcy 36
3.3 Distribution of Property 37 3.3.1 Property 37 3.3.2 Principle of Distribution 38 3.3.3 Priority of Distribution 39
3.4 Construction Insolvency 41 3.4.1 Insolvency of Employer 41 3.4.2 Insolvency of Main Contractor 42 3.4.3 Insolvency of Sub-Contractor 43
3.5 Summary 44
ix
4 ISSUES ASSOCIATED WITH MAIN CONTRACTOR’S INSOLVENCY 45
4.1 Introduction 45
4.2 Issues Arises in Main Contractor’s Insolvency 46 4.2.1 Direct Payments 46 4.2.2 Unfixed Materials and Goods 51 4.2.3 Set-off 55 4.2.4 Retention Fund 57 4.2.5 Determination 59 4.2.6 Bond and Guarantee 61 4.2.7 Novation 62
4.3 Summary 63
5 LEGAL POSITION OF ISSUES ARISE 65
5.1 Introduction 65
5.2 Legal Position of Issues Arise 65 5.2.1 Direct Payment 66 5.2.2 Unfixed Materials and Goods 77 5.2.3 Retention Fund 84 5.2.4 Set-off 89 5.2.5 Determination 93
5.3 Summary 94
6 CONCLUSION 95
6.1 Introduction 95
6.2 Realization of Research Objective 95
6.3 Recommendation for Further Study 98
6.4 Summary 99
REFERENCE 100
x
LIST OF CASES
CASES PAGE
Acsim (Southern) Ltd. v Danish Contracting & Development Co. Ltd.
(1989) 47 BLR 55 29
Administrator, Natal v Magill, Grant & Nell (Pty) (in liquidation)
[1967] 1 SALR 660 75, 78
Archivent Sales & Developments Ltd v Strathclyde Regional Council
(1984) 27 BLR 98 8, 54, 83
Balfour Beatty Ltd. v Britannia Life Ltd. [1997] SLT 10 61
Bandar Raya Developments Bhd v Woon Hoe Kan & Sons Sdn Bhd
[1972] 1 MLJ 75 57
BMC Construction Sdn Bhd v Dataran Rentas Sdn Bhd [2001] 1 MLJ
356 8, 58, 94
Brican Fabrications Ltd v Merchant City Developments Ltd [2003]
BLR 512 71, 78
British Eagle International Airlines Ltd v Compagnie Nationale Air
France [1975] 2 All ER 390 7, 8, 39, 50, 74
Caister Group Developments Ltd. v Paul Rackham Construction Ltd.
[1973] 226 Estates Gazette 809 21
xi
Campana Distributor Sdn Bhd v Amseal Engineering (M) Sdn Bhd
[1998] 7 MLJ 677 95
Clark Taylor & Co Ltd v Quality Site Development (Edinburgh) Ltd
[1981] SLT 308 55
Dawber Williamson Roofing Limited v Humberside County Council
(1979) 14 BLR 70 8, 56, 79, 99
Dawnays Ltd. v F. G. Minter Ltd. (1971) 1 BLR 16 57
Equitable Debenture Assets Corp. Ltd. v William Moss Group & Ors
(1984) 3 Constr LR 1 20
Ferguson v John Dawson & Partners (Contractors) Ltd. [1976] 1
WLR 1213 (C.A.) 19
G and T Earle Ltd v Hemsworth Rural District Council [1928] All ER
Rep 602 25
Gilbert-Ash (Northern) Ltd. v Modern Engineering (Bristol) Ltd.
(1973) 1 BLR 73 29, 58
Greater Nottingham Co-operative Society Ltd. v Cementation Piling
and Foundations Ltd. [1989] QB 71 22
Harry Bibby & Co Ltd v Neill Construction Ltd and Anor [1973] EGD
52 87
Henry Boot Building Ltd v The Croydon Hotel and Leisure Co Ltd
(1987) 36 BLR 41 91
Hitachi Plant Engineering & Construction Co Ltd & Anor v Eltraco
International Pte Ltd & Anor Appeal [2003] 4 SLR 384 40, 77, 78
Independent Broadcasting Authority v EMI Electronics Ltd. and BICC
Construction Ltd. (1980) 14 BLR 1 20
xii
Joo Yee Construction Pte Ltd (In Liquidation) v Diethelm Industries
Pte Ltd & Ors [1990] 2 MLJ 66 7, 8, 24, 26, 51, 73, 78
MacJordan Construction Ltd v Brookmount Erostin Ltd [1992] BCLC
350 86
McBrian v Shanley [1874] 24 CP 28 19
National Westminster Bank Ltd v Halesowen Presswork & Assemblies
Ltd [1972] AC 785 58, 93
Norwich City Council v Harvey [1989] 1 All ER 1180 22
Official Receiver v J Grigg [1933] 7 FMSLR 48 39
Pembenaan Leow Tuck Chui & Sons Sdn Bhd v Dr Leela's Medical
Centre Sdn Bhd [1995] 2 MLJ 57 29, 58
Pembinaan KSY Sdn Bhd v Lian Seng Properties Sdn Bhd [1992] 1
MLJ 571 35
People’s Park Chinatown Development Pte Ltd. (In Liquidation) v
Schindler Lifts (S) Pte Ltd. [1993] 1 SLR 591 (CA) 56, 81
Perar BV v General Surety & Guarantee [1994] 66 BLR 72 64
Quinn v Burch Bros. (Builders) Ltd. [1966] 2 QB 370 (C.A.) 19
Rayack Construction Ltd v Lampeter Meat Co Ltd. (1979) 12 BLR 30 61, 86, 88
Re Arthur Sanders (1981) 17 BLR 125 61, 86, 87, 92, 95
Re CG Monkhouse Pty Ltd (in liquidation) and the The Companies Act
[1968] 88 WN (Pt 2) (NSW) 238 50, 51
Re Cushla Ltd [1979] 3 All ER 415 93
Re D H Curtis (Builders) Ltd [1978] Ch 162 91, 93
Re Jartray Development Ltd (1982) 22 BLR 134 8, 60, 88, 90
xiii
Re Leinster Contract Corpn. [1903] 1 IR 517 41
Re Lough Neagh Ship Co. ex p Thompson [1896] 1 IR 29 41
Re Tout and Finch Ltd [1954] 1 All ER 127 48, 49, 51, 60, 61, 70, 78, 86, 90
Re Wilkinson ex p Fowler [1905] 2 KB 713 24, 48, 49, 51, 68, 71, 72, 78
Re Winter, ex p Bolland [1878] 8 Ch D 225 58
Re Yorkshire Joinery Co. [1967] 111 SJ 701 43
Saripah bte Manap & Ors v Emar Sdn. Bhd. (In dissolution) & Ors.
[1998] 1 MLJ 323 35
Schindler Lifts (Singapore) Pte Ltd v People's Park Chinatown
Development Pte Ltd (In Liquidation) [1990] 3 MLJ 406 6, 9
Sims v Foster-Wheeler Ltd. [1966] 2 All ER 313 19, 21
Spartan Steel and Alloys Ltd. v Martin & Co. (Contractors) Ltd.
[1973] QB 27 22
Teoh Kee Keong v Tambun Mining Co. Ltd [1968] 1 MLJ 39 21
Thompson v Pearson [1821] 1 S. 139 24
Tubeworkers Ltd. v Tilbury Construction Ltd. (1985) 30 BLR 67 29
United Malayan Banking Corporation Bhd. v Official Receiver &
Liquidator of Soon Hup Seng Sdn. Bhd. (In liquidation) & Anor.
[1986] 1 MLJ 75 35
Wallis v Robinson [1862] 3 F & F 307 22
Water Construction (London) Ltd v. Franthom Property Ltd (1991) 53
BLR 23 25
xiv
LIST OF FIGURE
FIGURE NO. TITLE PAGE
Figure 1-1: Flow Chart of the Research Methodology. 13
CHAPTER ONE
1 INTRODUCTION
1.1 Background Study
In construction contract, ordinarily, the main contractor will perform the
basic operations and sub-contract the remainder to various specialist contractors1
that possesses specialized skills.2 Sub-contracts are found in most construction
work, since very few contractors have the resources to carry out the whole of a
project themselves.3 In construction projects, sub-contractors play a vital role in
performing their specific tasks.4 Sub-contracting is used much more extensively in
housing and building construction projects than in engineering and industrial
projects.5
Generally, the main contract allows the practice of sub-contracting by the
main contractor. This has been illustrated by the sub-letting and nominated sub-
contractor clauses in clauses 17.0, 27.0 & 28.0 of the PAM Agreement and
Conditions of building contract 1998 and clauses 27, 28 & 29 of PWD 203A
1 Arditi, D., and Chotibhongs, R., “Issues in Sub-contracting Practice.” (ASCE: Journal of Construction Engineering and Management, Vol. Aug, 2005), p 866-876. 2 Ibid. 3 Uff, J. “Construction Law.” 3rd Ed. (London : Sweet & Maxwell, 1981), p 115. 4 Arditi, D., and Chotibhongs, R., ibid. 5 Clough, R., and Sears, G., “Construction Contracting.” (New York : Wiley, 1994).
2
Standard Form of Contract to be Used Where Bill of Quantities Form Part of the
Contract. Those clauses discussing that the main contractor should with the written
consent of the Architect or employer to sub-let any portion or the whole works to the
sub-contractor.6
In the context of building and engineering contracts, sub-contracting includes
supply only contractors, supply and fixes contractors and labour only supply
contractors. The first two types of sub-contractor can be either nominated or
domestic. While, both main and sub-contractor engaged labour supply only sub-
contractors to supply the labour required for the works. Nominated sub-contractors
are employed by employer while domestic sub-contractors employed by main
contractor.7
An employer through the selection of contract administrator employs
nominated sub-contractor.8 Main contracts usually contain special provisions
governing the rights of the parties concerning nominated sub-contract work.9
Besides that, the relation between main contractor and nominated sub-contractor
also set out in sub-contract which normally specified by the employer. There is
different sub-contract for different type of project. In private project, the sub-
contract used is PAM Agreement and Conditions of Building Sub-Contract 1998
and PWD 203N condition of sub-contract for nominated sub-contractor is for public
project. However, there is different provision in the context of domestic sub-
contractors.
Sub-contractors who are not nominated are sometimes called domestic sub-
contractors.10 The employer plays no part in the selection of domestic sub-
contractors except simply giving consent where this is required under the terms of
the main contract.11 For domestic sub-contractor and labour supply only sub-
6 See cl. 17.0 of PAM Agreement and Conditions of building contract 1998 and cl. 27 of PWD 203A Standard Form of Contract to be Used Where Bill of Quantities Form Part of the Contract. 7 Abdul Aziz, “Subkontrakor.” 8 Murdoch, J. and Hughes, W., “Construction Contracts : Law and Management.” 2nd Ed. (London : E & FN Spon, 1992), p 299. 9 Uff, J. ibid., p 35. 10 Uff, J. ibid., p 36. 11 Murdoch, J. and Hughes, W., ibid., p 287.
3
contractor, there is no specific standard form of sub-contract. The terms and
conditions to bind the main contractor and domestic sub-contractor are in clause
17.012 and clause 2713. Besides bound with the terms in main or sub-contract, they
held some obligations and rights against both parties vice versa.14
The doctrine of privity of contract means that the rights and obligations
contained in each contract apply only to those who are parties to it.15 It means that
only the parties to the contract can sue or be sued under it.16 For example, where
there are defects in the sub-contractor’s work, the employer will have a contractual
remedy against the main contractor, who will in turn take action against the sub-
contractor.17 There are some consequences once the link breaks.
Once the contractual links between main contractor and sub-contractor
breaks, for example the insolvent of main contractor, problems will arise.18 For
example, defects work caused by sub-contractor, once the main contractor goes into
insolvency, the employer can therefore effectively bring action against main
contractor. An employer cannot in similarly bring an action against a sub-contractor
directly due to no privity of contracts.
In the context of construction, insolvency, in practical means inability to pay
debts.19 The definition by Wikipedia20 for insolvency is a financial condition
experienced by a person or a business entity when the owner of a company’s assets
no longer exceed liabilities or when the person or entity can no longer meet his debt
obligations when the debt come due.21
12 PAM Agreement and Conditions of building contract 1998. 13 PWD 203A Standard Form of Contract to be Used Where Bill of Quantities Form Part of the Contract. 14 Murdoch, J. and Hughes, W., ibid., p 289. 15 Ibid., p 286. 16 Price, J., “Sub-contracting under the JCT Standard Forms of Building Contract.” (London : Macmillan, 1994), p 16. 17 Murdoch, J. and Hughes, W., ibid., p 286. 18 Ibid. 19 Uff, J., ibid., p 121. 20 The free encyclopedia. 21 Wikipedia, the free encyclopedia. “Insolvency.” (2006).
4
The term of insolvency is often incorrectly used as a synonym for
bankruptcy, which is a distinct concept.22 This is due to, ordinarily, insolvency
includes company and individual. Company insolvency consists of winding-up23,
receivership, and arrangement. Winding-up, or liquidation, is a collective
insolvency process leading to the end of the company’s existence (dissolution).24 A
receiver would be appointed in receivership to take control of the company’s
assets.25 Whereas, arrangement in Companies Act 1965 is a reorganization of the
share capital of a company by the consolidation of shares of different classes or by
the division of shares into shares of different classes or by both these methods’
again.26
On the other hand, individual insolvency consists of bankruptcy. Bankruptcy
is a proceeding by which possession of the property of a debtor is taken for the
benefit of his creditors by the Official Assignee.27 The relating provision for
governing the individual insolvency is different with the company insolvency.
Unlike United Kingdom, that has an Insolvency Act 1986,28 in Malaysia we
do not have such act. In Malaysian legal system, the core of Malaysia’s current
company and corporate insolvency law is contained in the Part X of Companies Act
1965 (Act 125), whilst the bankruptcy proceeding in governed by the provisions of
the Bankruptcy Act 1967.29
22 Ibid. 23 Can be known as liquidation. 24 Goode, R. M., “Principles of Corporate Insolvency Law.” (London : Sweet & Maxwell, 1990), p 12. 25 Ibid., p 10. 26 K. V. Padmanabha Rau., “Company Law of Malaysia : Shares, Meetings, Receivers and Managers.” (Selangor : Internation Law Book Services, 2003), p 346. 27 See Para 100.001 Halsbury's Laws of Malaysia, vol 6, p 4. 28 The Cork Committee was appointed in 1977 with wide-ranging terms of reference covering corporate and individual insolvency. Its report in 1982 led to a government White Paper in 1984 setting out an intention to implement the bulk, but not all of the Committee’s recommendation. This eventually led to the Insolvency Act 1986 – see further Sealy and Milman, Annotated Guide to the 1986 Insolvency Legislation 4th edition (1994) 29 Wallace, I. N. D., “Hudson’s Building and Engineering Contracts including the Duties and liabilities of Architects, Engineers and Surveyors.” 10th Ed. (London : Sweet & Maxwell, 1970), p 775.
5
When a company is wound up, all its business is concluded by a liquidator
who takes over the powers of the board.30 He collects in the debts, which are owed
to the company and, as far as he is able, pays off the creditors.31 The fundamental
principle in the distribution of assets is the pari passu distribution.32 Pari passu
principle is where all creditors participating in the common pool in proportion to the
size of their admitted claims.33 The distribution of assets is depending on various
types of debts.
If a company is insolvent, the assets must be distributed in the following
order :34
i. The cost of winding up;
ii. Preferential debts such as rates, taxes, official levies and wages of
employees;
iii. Secured debts;
iv. Unsecured debts;
v. Deferred debts.35
The law of winding-up companies provide for the realisation and distribution
of assets, with certain debts, having priority for payment.36 In building contracts, the
insolvency of one party will usually bring the work to an end.37 This would
probably bring problems and delay to the others parties in construction project.38
30 Uff, J., ibid., p 40. 31 Ibid. 32 Section 264 of Companies Act 1965. 33 Goode, R. M., ibid., p 59. 34 Uff, J., ibid., p 41. 35 Robinson, N. M. and Lavers, A. P., “Construction Law in Singapore and Malaysia.” (Singapore : Butterworths, 1988), p 184. 36 Uff, J., ibid., p 121. 37 Ibid. 38 Wright, H. “Bankruptcy, the Unexpected Storm.” (Columbus : Bricker & Eckler LLP, Vol III Issue 6 June, 2002), p 2.
6
1.2 Problem Statement
The East Asian financial crisis was a financial crisis that started in July 1997
in Thailand and affected currencies, stock markets, and other asset prices in several
Asian countries that were considered as “East Asian Tigers”.39 Malaysia was one of
the countries in East Asia that was hit by the East Asian financial crisis and this had
brought a long-term of economic difficulties.40 It is suggested that down economies
often translate into high levels of insolvencies.41
One of the consequences of the financial crisis was the insolvency of some of
the major construction companies such as Renong, UEM, System Transit Aliran
Ringan Sdn. Bhd., Prolink Development Sdn. Bhd. and Linkedua Bhd.42 As the
number of construction insolvency continues to rise, the risk is that either the
developer, main contractor or one or more of the specialist sub-contractors will
become insolvent during the course of the project.43
Although the number of construction insolvency continues to rise,44 the
insolvency of a main contractor is a relatively frequent occurrence.45 By referring to
the Archivent Sales & Developments Ltd v Strathclyde Regional Council46 case, sub-
contractors and suppliers would become unsecured creditors in the event of main
contractor’s liquidation. In liquidation, an unsecured creditor is a person who is not
entitled to any priority towards settlement of the debt owing to him and may include
39 Wikipedia, the free encyclopedia , “East Asian Financial Crisis.” 40 Wikipedia, the free encyclopedia, “East Asian Financial Crisis.” 41 McCarter & English attorneys at law, “Commercial Litigation – Debtor/Creditor.” 42 These companies were under Corporate Debt Restructuring Committee jurisdiction, See Bank Negara Report on the Closure of the CDRC : Status at 15 August 2002 for a complete list. 43 Newman, P. and Barrister, “Insolvency in the Construction Industry.” (Trett Consulting : Trett Digest Issues 10 Article 4, Autumn 1993); See also Schindler Lifts (Singapore) Pte Ltd v People's Park Chinatown Development Pte Ltd (In Liquidation) [1990] 3 MLJ 406. 44 Ibid. 45 Bagnall, B., “Contract Administration for Architects and Quantity Surveyors.”, 6th ed. (London : Collins, 1986), p 85. 46 [1984] 27 BLR 98.
7
a judgment creditor.47 An unsecured creditor of the insolvent company has to share
the assets of an insolvent company through the applicable of pari passu principle.48
In the pari passu principle is a rateable distribution among creditors is rarely
achieved. There are several reasons for this, first, the principle is in general
confined to assets of the company and does not affects creditor-having rights in rem.
These include secured creditors, fixed charges, suppliers of goods and third parties
for whom the company holds assets on trust. The effect of these rights in rem is
substantially to reduce the corpus of assets available for unsecured creditors. These
embrace:
1. Expenses of the liquidation
2. A range of debts which are preferential
When all these have been satisfied, the dividend produced by what is left is often
pitiful small.49
Besides that, the complexity and the sophistication of the sub-contract,50
together with the less attention given to insolvency rules in the sub-contract, have
led to greater problems to other parties in a construction project.51 The issues or
problems faced by the sub-contractor in the event of main contractor’s insolvency
include :-
• Direct payment,52 direct payment held to contravene to the pari
passu principle of asset distribution.53
47 S Kalyana Kumar and Pereira, P., “Bankruptcy Handbook.” (Kuala Lumpur : Malayan Law Journal Sdn Bhd, 1998), p I 34. 48 Rajah & Tan advocates & solicitors. 49 Goode, R M. Ibid. p 60-61 50 Newman, P. and Barrister, ibid. 51 Ibid. 52 Ibid.; Anderson, A. J., Brickford-Smith, S., Palmer, N. E. and Redmond-Cooper, R., “Emden Construction Law.” 8th Ed., (London : Butterworths, 1990), p IV 177-241; British Eagle International Airlines Ltd v Compagnie Nationale Air France [1975] 2 All ER 390 53 Joo Yee Construction Pte Ltd (In Liquidation) v Diethelm Industries Pte Ltd & Ors [1990] 2 MLJ 66
8
• Unfixed Materials and goods,54 sub-contractor have not received
any payment from main contractor, yet cannot recover the materials
and goods supplied.55
• Set-off,56 can be exercised in the payment due when main contractor
in financial difficulties.57
• Retention fund,58 held by main contractor cannot be claimed back
during the insolvent of main contractor.59
• Determination,60 the employment of sub-contractor automatically
determined once the employment of main contractor under main
contract has been determined.
• Bonds and Guarantee,61 can the sub-contractor claim back their
bonds when main contractor filed for liquidation.
• Novation,62 the main contract has been novated to another party
when main contractor went into insolvency.
Among the issues arise, the critical issues arise in relating to the sub-
contractor in the event of main contractor’s insolvency are direct payment, materials
and goods, retention fund, and set-off.
Direct payment has been illustrating in the case of Joo Yee Construction Pte
Ltd (In Liquidation) v Diethelm Industries Pte Ltd & Ors63, the sub-contractor
applied for direct payment from the employer. The liquidator of the main contractor
rejected this provision as contravening the insolvency law.
The issue of materials and goods has been discussing in Schindler Lifts
(Singapore) Pte Ltd v People's Park Chinatown Development Pte Ltd (In
54 Archivent Sales & Developments Ltd v Strathclyde Regional Council (1984) 27 BLR 98; Dawber Williamson Roofing Ltd. v Humberside County Council (1979) 14 BLR 70 55 Archivent Sales & Developments Ltd v Strathclyde Regional Council (1984) 27 BLR 98. 56 Anderson, A. J., Brickford-Smith, S., Palmer, N. E. and Redmond-Cooper, R., ibid., p IV 177-241. 57 BMC Construction Sdn Bhd v Dataran Rentas Sdn Bhd [2001] 1 MLJ 356. 58 Newman, P. and Barrister, ibid.; Anderson, A. J., Brickford-Smith, S., Palmer, N. E. and Redmond-Cooper, R., ibid., p IV 177-241. 59 Re Jartray Development Ltd (1982) 22 BLR 134. 60 Newman, P. and Barrister, ibid. 61 Newman, P. “Bonds, Guarantees and Performance Security in the Construction Industry.” 62 Newman, P. and Barrister, ibid. 63 [1990] 2 MLJ 66.
9
Liquidation)64. In that case, the sub-contractor succeeded in recovering for the
unfixed escalators, which yet received payment from the main contractor.
Based on the issues or problems discussed above, the sub-contractor, as an
unsecured creditor in the event of main contractor’s insolvency, should be getting
familiar with the legal position of those issues, so that, they can deal with it when it
occurred. Therefore, it comes to an objective of study.
1.3 Objective of Study
The objective of this research is to determine the legal positions relating to
issues faced by a sub-contractor in the event of a main contractor’s insolvency.
1.4 Scope and Limitation of Study
This research study those issues, that arise which faced by both nominated
and domestic sub-contractor during the insolvency of main contractor and its legal
position. Although there are many issues arise, this study only focus on those
critical issues: direct payment, retention fund, set-off, unfixed materials and goods
and determination.
The case analysed, included Malaysia, Singapore, United States, and English
cases. There is no limit for the cases chosen in terms of period.
64 [1990] 3 MLJ 406.
10
1.5 Significance of Study
The conclusion of this study will determine the legal position of the issues
faced by a sub-contractor in the construction industry in the event of the insolvency
of a main contractor.
All the issues arise in the event of main contractor’s insolvency will affect
the employer’s obligation and rights. This study will brings benefit for the employer
to strengthen their rights in the event of main contractor’s insolvency. It can be used
as guidance to deal with the issues. For liquidator, it can help the liquidator in the
position where the liquidator can claim back the payment, which has been directly
made by the employer to the sub-contractor.
This study, of course, will give the sub-contractor an idea about his legal
position in comply with the issues in main contractor’s insolvency, they can act
more reasonably while such event occurred. At last, it can help to avoid the disputes
in construction industry.
1.6 Research Methodology
A systematic of research process has been adopted to achieve the objective
of study. Generally, this research process consisted of five stages, which involved
identifying the research issue, literature review, data collection, data analysis, and
conclusion.
11
1.6.1 First Stage: Identifying the Research Issue
The most important step in a research is identification of the research issue.
Normally, the issue established by reading the various related materials in journals,
books, and articles. Based on the research issue on the insolvent of main contractor,
the objective of study has been identified. There is to determine the legal positions
relating to issues faced by sub-contractor in the event of main contractor’s
insolvency.
1.6.2 Second Stage: Literature Review
The stage of literature review is an important stage in achieving the aim and
objective of this study. The literature review will give the reader the brief concept
of the related field in this study. Therefore, the literature review has been divided
into 3 chapters which are reviewing of the sub-contracting, insolvency and issues
arise in relating to sub-contractor in the event of main contractor’s insolvency. The
materials used to carry out the stage of literature review are books, articles, journals,
and court cases. The referred books are Halsbury’s Law of Malaysia, Construction
Contract, Construction Law, Principle of Insolvency Law, Company Law of
Malaysia, Winding-Up Handbook, Sub-Contracting, Building Contract, Hudson’s
Building and Engineering Contracts, Emden Construction Law etc. The articles are
from the author: Paul Newman, Abdul Aziz, Harry Wright, and other solicitors.
Whereas, journals are Journals of Construction Engineering and Management, Trett
Digest etc. The court cases are collected from the electronic database: Lexis-Nexis
Legal Databases.
12
1.6.3 Third Stage: Data Collection
After setting out the background of study and relevant issues, the data been
collected. The data consists of case from Malayan Law Journal and other
commonwealth jurisdiction such as United Kingdom, Australia, New Zealand,
Singapore, Canada etc.
1.6.4 Fourth Stage: Data Analysis
Following that, the stage of cases study has been carried out on the related
court cases. Case study research calls for selecting some examples of the
phenomenon to be studied. By closely examining a relatively small number of
examples or court cases, comparing and contrasting them, the features have been
identified based on different circumstances.
The case study process started through reviewing and clarifying the facts of
the cases. Once the issues presented have been focus, comparison and discussion on
different circumstances can be done. Consequences of each curse of action been
studied and points and arguments had been developed.
1.6.5 Fifth Stage: Conclusion and Recommendations
In this stage, a reviews of the whole research process will be reviews entirely
to identify whether the research objectives has been achieved. After that, a
13
ANALYSIS Legal Position
Conclusion CONCLUSION
conclusion based on the findings been done and further research can be
recommended.
Figure 1-1: Flow Chart of the Research Methodology.
LITERATURE REVIEW
RESEARCH OBJECTIVE
RESEARCH ISSUE
Issues faced by sub-contractor in the event of main contractor’s insolvency
To determine the legal positions for the issues faced by sub-contractor in the event of main contractor’s insolvency
Data CollectionChapter 2 –Sub-
contracting Chapter 3 – Insolvency Chapter 4 – Issues Arise
Data Analysis
14
1.7 Chapter Organisation
Chapter 1 set the background of study identified the research issues,
determined objective, scope and limitation of study, research methodology and the
organisation of chapter.
Chapter 2 explained on the principles of sub-contracting in construction
project. This included the reasons for sub-contracting, the contractual chain, the
relation in between the main contractor and sub-contractor and in between the
employer and sub-contractor as well as the important terms in sub-contract also been
discussed in this chapter.
Chapter 3 explained the concepts and the general principles of insolvency
(i.e. liquidation, receivership, and arrangement), principles of property distribution
included the priority of distribution the property and the construction insolvency.
Chapter 4 analysed the cases relating to the issues arising in the event of
main contractor’s insolvency faced by the sub-contractors. The analysis is focused
on the critical issues arises such as direct payment, set-off, retention fund and so on.
Based on the issues arise which has been identified. The legal position for those
issues arise can be easily determined which would be discussed on the following
chapter.
Chapter 5 set out the legal position for those issues analysed in Chapter 4.
All the related court cases had been reviewed to determine the legal position for
those issues faced by the sub-contractor during the insolvent of main contractor.
Chapter 6 concluded the findings for the whole research. Recommendation
for further study had been stated as well in this chapter.
100
REFERENCE
1. Abdul Aziz Hussin. (2004) Subkontraktor.
2. Abdul Aziz Hussin. (2004). Konsep Pembayaran Kerja Kontrak Kepada
Subkontraktor Projek Kerajaan.
3. Alex, C. H. W. (1998). Companies Winding-Up Handbook. Kuala Lumpur :
Malayan Law Journal Sdn Bhd.
4. Anderson, A. J., Brickford-Smith, S., Palmer, N. E. and Redmond-Cooper,
R. (1990). Emden Construction Law. 8th Ed., London : Butterworths.
5. Arditi, D., and Chotibhongs, R. (2005). Issues in Sub-contracting Practice.
ASCE: Journal of Construction Engineering and Management. Vol. Aug,
2005. 866-876.
6. Hornby, A. S. (1995). Oxford Advanced Learner’s Dictionary. 5th Ed., New
York : Oxford University Press.
7. Bagnall, B. (1986). Contract Administration for Architects and Quantity
Surveyors. 6th Ed. London : Collins.
8. Clough, R., and Sears, G. (2004). Construction Contracting. New York :
Wiley.
101
9. Goode, R. M. (1990). Principles of Corporate Insolvency Law. London :
Sweet & Maxwell.
10. Haji Salleh Haji Buang. (2001). Malaysian Torrens System. Kuala Lumpur :
Dewan Bahasa dan Pustaka.
11. Halsbury’s Laws of Malaysia. (2000). Bankruptcy, Companies Winding-up.
Vol. 6. Asia : Butterworth.
12. Halsbury’s Laws of Malaysia. (2000). Building and Construction Revenue.
Vol. 3. Asia : Butterworth.
13. Halsbury’s Laws of Malaysia. (2000). Companies Law. Vol.13. Asia :
Butterworth.
14. Insolvency Suggested Checklist. (2005). Preface to Insolvency Suggested
Checklists. Malaysia : Malaysian Institute of Accountants.
15. International Law Book Services. (2004). The Companies Act 1965 (Act
125). Selangor : International Law Book Services
16. K. V. Padmanabha Rau. (2003). Company Law of Malaysia : Shares,
Meetings, Receivers and Managers. Selangor : International Law Book
Services.
17. Keating, D., (1978). Building Contracts including a Commentary on the JCT
Standard Form of Building Contract. 4th Ed. London : Sweet & Maxwell.
18. Klein, R. (2002). Supplementary Memorandum by the SEC Group. SEC
Group.
19. Lee, M. P. (2001). General Principles of Malaysian Law. 4th Ed. Selangor :
Penerbit Fajar Bakti Sdn Bhd.
102
20. Maclean, J. H. and Scott, J. S. (1995). The Penguin Dictionary of Building.
4th Ed. England : Penguin Books.
21. McCarter & English attorneys at law. (2006). Commercial Litigation –
Debtor/Creditor.
22. Md. Rodzi Harun. (1998). Winding-up a Company. Malaysia Company Law
for Everyone.
23. Murdoch, J. and Hughes, W. (1992). Construction Contracts : Law and
Management. 2nd Ed. London : E & FN Spon
24. Nelson, G. R., Rinker, O. M. and Baker, LLP. How to Respond to
Subcontractor Insolvency and Bankruptcy.
25. Newman, P. (2006). Bonds, Guarantees and Performance Security in the
Construction Industry.
26. Newman, P. and Barrister. (1993). Insolvency in the Construction Industry.
Trett Consulting : Trett Digest Issues 10 Article 4.
27. O’Donnell, N. H. and Matthews, J. M. (2006). Construction Subcontracting.
28. Pertubuhan Akitek Malaysia. (1998). PAM Agreement and Conditions of
Building Contract 1998.
29. Pertubuhan Akitek Malaysia. (1998). PAM Agreement and Conditions of
Building Sub-Contract 1998.
30. Powell-Smith, V. and Furmston, M. (1987). A Building Contract Casebook.
London : BSP Professional Books.
31. Price, J. (1994). Sub-contracting under the JCT Standard Forms of Building
Contract. London : Macmillan.
103
32. Public Work Department. PWD 203A Standard Form of Contract to be Used
Where Bill of Quantities Form Part of the Contract.
33. Public Work Department. PWD 203N Condition of Sub-Contract for
Nominated Sub-Contractor.
34. Robinson, N. M. and Lavers, A. P. (1988). Construction Law in Singapore
and Malaysia. Singapore : Butterworths.
35. S Kalyana Kumar and Pereira, P. (1998). Bankruptcy Handbook. Kuala
Lumpur : Malayan Law Journal Sdn Bhd.
36. Tolson, S. J. A. (2004). Payment, Abatement and Set-off. Paper given to the
Association of Independent Construction Adjudicators Annual Conference.
37. Uff, J. (1981). Construction Law. 3rd Ed. London : Sweet & Maxwell.
38. Vohrah, B. and Wu, M. A. (2004). The Commercial Law of Malaysia.
Selangor : Longman, 2004.
39. Wallace, I. N. D. (1970). Hudson’s Building and Engineering Contracts
including the Duties and liabilities of Architects, Engineers and Surveyors.
10th Ed. London : Sweet & Maxwell.
40. Wikipedia, (2006). East Asian Financial Crisis. The free encyclopedia
41. Wikipedia. (2006). Insolvency. The free encyclopedia
42. Wikipedia. (2006). Subcontractor. The free encyclopedia
43. Wright, H. (2002). Bankruptcy, the Unexpected Storm. Columbus : Bricker
& Eckler LLP, Vol III Issue 6. 2.