an assessment of the performance of public sector

218
AN ASSESSMENT OF THE PERFORMANCE OF PUBLIC SECTOR CONSTRUCTION PROJECTS: AN EMPIRICAL STUDY OF PROJECTS FUNDED UNDER CONSTITUENCY DEVELOPMENT FUND (CDF) IN WESTERN PROVINCE, KENYA A THESIS SUBMITTED TO THE UNIVERSITY OF DELHI FOR AWARD OF THE DEGREE OF DOCTOR OF PHILOSOPHY BY CHRISTOPHER NGACHO UNDER THE SUPERVISION OF DR. DEBADYUTI DAS FACULTY OF MANAGEMENT STUDIES UNIVERSITY OF DELHI DELHI 110007 JULY, 2013

Upload: others

Post on 18-Dec-2021

0 views

Category:

Documents


0 download

TRANSCRIPT

AN ASSESSMENT OF THE PERFORMANCE OF PUBLIC SECTOR

CONSTRUCTION PROJECTS: AN EMPIRICAL STUDY OF PROJECTS

FUNDED UNDER CONSTITUENCY DEVELOPMENT FUND (CDF) IN

WESTERN PROVINCE, KENYA

A THESIS SUBMITTED TO THE UNIVERSITY OF DELHI FOR AWARD OF

THE DEGREE OF DOCTOR OF PHILOSOPHY

BY

CHRISTOPHER NGACHO

UNDER THE SUPERVISION OF

DR. DEBADYUTI DAS

FACULTY OF MANAGEMENT STUDIES

UNIVERSITY OF DELHI

DELHI 110007

JULY, 2013

ii

DEDICATION

This PhD work is dedicated to my beloved family, wife Mary and children David,

Antony and Monica.

“To my wife for her continuous support and encouragement”

“To my children, I hope this will inspire them to pursue their education and lead

successful lives”

iii

DECLARATION

This is to declare that the research work embodied in this thesis titled “AN

ASSESSMENT OF THE PERFORMANCE OF PUBLIC SECTOR

CONSTRUCTION PROJECTS: AN EMPIRICAL STUDY OF PROJECTS

FUNDED UNDER CONSTITUENCY DEVELOPMENT FUND (CDF) IN

WESTERN PROVINCE, KENYA”, is original and is the result of investigation

carried out by the candidate under the supervision of Dr. Debadyuti Das at the Faculty

of Management Studies, University of Delhi. This work has not been submitted in any

part or full for any other degree or diploma of this or any other institution. The extent

of information derived from the existing literature has been indicated in the body of

the thesis at appropriate places, giving the source of information.

.................................................Date......................... CHRISTOPHER NGACHO RESEARCH SCHOLAR (PhD 10/018)

.................................................Date......................... DEBADYUTI DAS SUPERVISOR ASSOCIATE PROFESSOR FACULTY OF MANAGEMENT STUDIES UNIVERSITY OF DELHI DELHI – 110 007

.................................................Date....................... PROF. RAJ S. DHANKAR DEAN AND HEAD FACULTY OF MANAGEMENT STUDIES UNIVERSITY OF DELHI DELHI 110007

iv

ABSTRACT

The present work attempts to develop a multidimensional performance evaluation

framework of public sector construction projects by considering all relevant measures

of performance and the factors that influence success of these kinds of projects. In

order to demonstrate the workability of this framework, it has considered the case of

Constituency Development Fund (CDF) construction projects constructed between

2003 and 2011 and conducted the study at two phases: exploratory and confirmatory.

The exploratory study collected the viewpoints of 175 respondents comprising clients,

consultants and contractors involved in the implementation of CDF projects with

regard to their perception on 35 performance related variables and 30 project success

variables. Confirmatory study, on the other hand, separately collected viewpoints of

211 respondents from the same target population with regard to their perception on 27

performance related variables and 27 project success variables obtained from

exploratory study. A five-point Likert scale was used as a response format for

different variables with the assigned values ranging from 1 = Strongly Disagree to 5 =

strongly Agree.

The findings of the exploratory study reveal that the individual items constituting six

factors of performance measurement variables essentially represent six key

performance indicators (KPIs) namely time, cost, quality, safety, site disputes and

environmental impact. The relative influence of each KPI towards overall

performance of construction projects shows that time is the most important measure

followed by cost while safety comes last in order of importance in the performance

evaluation of CDF construction projects. Similarly, the six factors of project success

variables represent the six critical success factors (CSFs) namely project-related,

client-related, consultant-related, contractor-related, supply chain-related and

external environment-related factor. The relative influence of each success factor

towards project success reveals that project related factor is the most important factor

followed by client related factor while contractor related factor come last in order of

importance amongst the factors influencing the success of CDF construction projects.

Confirmatory factor analysis (CFA) results show that cost, time and quality are

significantly correlated with overall project performance while the relationship of

v

project performance with site disputes, safety and environmental impact are not

statistically significant. In terms of their importance, based on factor loadings, cost

was the most important, followed by quality, while environmental impact comes last

in order of importance. Further, all the six CSFs, project-related, client-related,

consultant-related, contractor-related, supply chain-related and external

environment-related factor were found to have significant influence on project success

with external environment related factor being the most important followed by project

related factor, consultant related factor, contractor related factor, client related factor

and supply chain related factor in that order.

The two measurement models: one for KPIs and the other for CSFs were combined

into a single performance evaluation model and Structural Equation Modelling (SEM)

was applied on 211 responses in order to examine the influence of the six CSFs on

project success, the association between project success and overall project

performance and the relationship between overall project performance and the six

KPIs. It was found that, in order of importance, project related, consultant related,

client related, contractor related, supply chain related and external environment

related factors influence the success of public sector construction projects. It was also

found that external environment related factor does not mediate the influence of CSFs

on the success of the project. Further, the results show that project success is

positively associated with the overall performance of public sector construction

project. Of the six KPIs earlier determined, four of them namely cost, time, quality

and site dispute performance were found to be significant measures of overall project

performance, whereas safety and environmental impact were found insignificant. The

findings of this study have significant bearing on other similar kind of public sector

construction projects undertaken in developing countries.

vi

ACKNOWLEDGEMENT

I wish to express my profound gratitude to my supervisor Dr. Debadyuti Das whose

guidance, constructive criticism, advice, support and encouragement enabled the

completion of this project and the work leading up to this thesis. I also appreciate the

encouragement I received from members of my advisory board, Prof. V.K. Seth and

Prof. Ajay Pandit towards completion of this work. The study leading up to this thesis

would have been next to impossible without the leadership and support of the faculty

at FMS, who taught, encouraged, and led me to reach this point in my academic

career. These include Prof M.L. Singla, Dr. Pankaj Sinha and Prof. Sunita Singh

Sengupta. The contribution and support of Mr. Hari- and my colleagues within the

PhD programme at FMS are highly commendable; especially Ms. Ruchika, Ms. Nidhi,

Mr Purushottam, Mr. Virendra, Mr. Rohella, Mr Tabash and all those others who

spared time to clarify several issues during our coursework.

I would also like to thank the editors and reviewers of the International Journal of

Project Management (IJPM) and International Journal of Project Organization and

Management (IJPOM) for their valuable comments on the papers we submitted to

their respective journals for publication. Further special thanks go to participants in

both XV and XVI Annual International Conferences of the Society of Operations

Management (SOM) in IIM Calcutta, and IIT, Delhi respectively and African

International Business and Management (AIBUMA 2012) conference in Nairobi.

Your comments and questions have enriched the contents of this thesis.

I appreciate the continued concern and support of my family, led by my elder brother

Mr. John Sebastian Wesonga and my Uncle Mr. Gabriel Kwoba Mukele, for both the

doctoral degree programme and my overall progress in the academia. I must

acknowledge the undisputable support of my caring and God fearing wife, Mary and

my children David, Antony and Monica. They provided the home logistics for the

success of the work.

Finally I wish to thank my employer, Kisii University, and especially the Vice-

Chancellor Prof. John Akama for granting me study leave to pursue this degree. To

this end, special thanks go to the Government of India, for her financial support

through the Indian Council for Cultural Relations (ICCR).

vii

DEDICATION............................................................................................................. ii

DECLARATION........................................................................................................ iii

ABSTRACT................................................................................................................ iv

ACKNOWLEDGEMENT......................................................................................... vi

TABLE OF CONTENTS.......................................................................................... vii

LIST OF TABLES.....................................................................................................xii

LIST OF FIGURES................................................................................................... xv

LIST OF MAPS........................................................................................................ xvi

LIST OF APPENDICES......................................................................................... xvii

LIST OF ABBREVIATIONS.................................................................................xviii

TABLE OF CONTENTS

CHAPTER 1: OVERVIEW OF THE STUDY......................................................... 1

1.0 Introduction.............................................................................................................. 1

1.1 Background of the Study......................................................................................... 1

1.2 Public sector construction projects: Contribution and challenges............................3

1.3 Research Problem.................................................................................................... 4

1.4 Research Objectives................................................................................................ 5

1.5 Scope of the Study.................................................................................................. 6

1.6 Significance of the Study........................................................................................ 6

1.7 Organization of Thesis............................................................................................. 7

1.8 Assumptions of the Study...................................................................................... 10

1.9 Definition of Terms………………………………………………………………10

CHAPTER 2: REVIEW OF LITERATURE ......................................................... 13

2.0 Introduction............................................................................................................ 13

2.1 Overview of public sector construction projects....................................................13

2.1.1 Definition of construction projects.................................................................. 14

2.1.2 Classification of construction projects............................................................ 14

2.1.3 Phases of construction projects....................................................................... 16

2.2 Performance measurement amongst public sector construction project................ 17

2.2.1 Key Performance Indicators (KPIs) of public sector construction

projects............................................................................................................. 19

viii

2.2.1.1 Traditional criteria, the “iron triangle”...............................................19

2.2.1.2 Performance criteria based on “five pillars”.......................................21

2.2.1.3 The contemporary measures of project performance.......................... 22

2.2.2 Critical Success Factors (CSFs) influencing the success of public

sector construction projects............................................................................. 25

2.3 Research gaps in literature..................................................................................... 29

CHAPTER 3: PUBLIC CONSTRUCTION SECTOR IN KENYA AND THE

CONSTITUENCY DEVELOPMENT FUND (CDF): AN OVERVIEW...…… 31

3.0 Introduction…………………………………………………………………..….. 31

3.1 Facts on Kenya………………………………………………………………….. 31

3.2 Construction sector in Kenya: Early government initiatives................................. 35

3.3 Constituency Development Fund (CDF) in Kenya............................................... 36

3.3.1 Identification and selection of CDF projects.................................................. 38

3.3.2 CDF Project procurement approaches............................................................. 39

3.3.3 Implementation of CDF projects..................................................................... 42

3.4 Existing practices of monitoring the performance of CDF construction

Projects.................................................................................................................. 44

CHAPTER 4: RESEARCH METHODOLOGY (PHASE I): EXPLORATORY

STUDY....................................................................................................................... 47

4.0 Introduction........................................................................................................... 47

4.1 Key issues……………………………………………………………………….. 47

4.2 Process followed in Research Methodology (Phase I).......................................... 47

4.3 Design of Survey Instrument……………………………………………………. 49

4.4 Reliability of Survey Instrument………………………………………………… 51

4.4.1 Validity and Reliability of project performance measurement variables….. 51

4.4.2 Validity and Reliability of variables influencing project success………… 54

4.5 Study site and identification of target population……………………………….. 57

4.6 Identification and training of field investigators………………………………... 57

4.7 Data collection………………………………………………………………… 58

CHAPTER 5: RESEARCH FINDINGS AND DISCUSSION (PHASE I).......... 59

5.0 Introduction……………………………………………………………………... 59

ix

5.1 Screening of collected Data................................................................................... 59

5.2 Demographic characteristics of projects and respondents’ profile........................ 62

5.2.1 Description of CDF projects and their procurement approaches.....................62

5.2.2 Status of CDF construction projects................................................................ 65

5.2.3 Respondents’ profile........................................................................................ 69

5.3 Exploratory Factor Analysis (EFA) of performance measurement variables

for Key Performance Indicators (KPIs) Scale........................................................70

5.3.1 Descriptive statistics of performance measures………………....................... 70

5.3.2 Assessing the factorability of performance measurement variables............... 73

5.3.3 Factor Analysis following Varimax Rotation.................................................. 77

5.3.4 Validation of the KPIs......................................................................................79

5.3.4.1 Reliability of KPIs scale............................................................................. 79

5.3.4.2 Content validity......................................................................................... 80

5.3.4.3 Convergent and Discriminant validity....................................................... 80

5.3.5 Theoretical Framework of the KPIs & Discussion........................................ 82

5.4 Exploratory Factor Analysis (EFA) of project success variables for Critical

Success Factors (CSFs) Scale.................................................................... 86

5.4.1 Descriptive statistics of project success variables…………………………... 86

5.4.2 Assessing the factorability of project success variables.................................. 88

5.4.3 Factor Analysis following Varimax Rotation.................................................. 90

5.4.4 Validation of the CSFs..................................................................................... 93

5.4.4.1 Reliability of CSFs scale............................................................................ 93

5.4.4.2 Content validity.......................................................................................... 93

5.4.4.3 Construct validity....................................................................................... 93

5.4.5 Theoretical Framework of CSFs..................................................................... 95

5.5 Conceptual framework of project performance evaluation.................................. 98

CHAPTER 6: RESEARCH METHODOLOGY (PHASE II):

CONFIRMATORY STUDY................................................................................. 101

6.0 Introduction.......................................................................................................... 101

6.1 Key Issues……………………….......………………………………….……….101

6.2 Theoretical framework and statement of Hypotheses for performance

x

evaluation of public sector construction projects……………..………..…....…. 102

6.3 Process followed in Research Methodology (Phase II)....................................... 112

6.4 Design of Survey Instrument………………………….……………..………… 112

6.5 Study site and identification of target population………..……………..……….113

6.6 Data Collection…….……………………………………..…………..…….….. 113

CHAPTER 7: RESEARCH FINDINGS AND DISCUSSION (PHASE II)….... 115

7.0 Introduction.......................................................................................................... 115

7.1 Screening of collected data………………………………………………….…. 115

7.2 Demographic characteristics of respondents and projects....................................115

7.2.1 Project characteristics and brief profile of the respondents............................116

7.2.2 Status of CDF construction projects...............................................................117

7.2.3 Relationship amongst project characteristics, respondents’ profile

and incidences of time overrun, cost overrun and quality defects..................119

7.2.3.1 The extent of differences in the occurrence of time overrun,

cost overrun and quality defects across different types of

construction projects………………………….……………….……..…. 119

7.2.3.2 The association between the project procurement approaches used

and the occurrence of time overrun, cost overrun and quality defects

amongst public sector construction projects………………………...……. 120

7.2.3.3 The association between respondents’ experience in

construction projects and occurrence of time overrun, cost

overrun and quality defects………………………………………………….. 122

7.3 Confirmatory factor analysis (CFA) of performance measurement

variables for KPIs Scale...................................................................................... 124

7.3.1 Validation of performance measurement variables........................................124

7.3.2 First order measurement model of KPIs........................................................ 125

7.3.3 Second order measurement model of KPIs.................................................... 132

7.3.4 Evaluation of constructs in KPIs measurement model................................. 134

7.3.4.1 Unidimensionality and face validity....................................................... 134

7.3.4.2 Construct Reliability.................................................................................134

7.3.4.3 Construct Validity.................................................................................... 136

xi

7.4 Confirmatory factor analysis (CFA) of success variables for CSFs Scale......... 137

7.4.1 Validation of project success variables........................................................ 138

7.4.2 First order measurement model of CSFs......................................................139

7.4.3 Second order measurement model of CSFs................................................... 144

7.4.4 Evaluation of constructs in CSFs measurement model................................ 145

7.4.4.1 Unidimensionality and face validity.........................................................145

7.4.4.2 Construct Reliability................................................................................ 145

7.4.4.3 Construct Validity.................................................................................... 147

7.5 Structural Equation Modelling (SEM)................................................................. 148

7.5.1 A summary of CFA results.............................................................................148

7.5.2 Evaluation of the structural model................................................................. 150

7.5.3 Tests of Hypotheses and Discussion.............................................................. 155

7.5.3.1 Tests of direct impact of re-specified model............................................ 155

7.5.3.2 Test of indirect impact of re-specified model........................................... 157

CHAPTER 8: CONCLUSION................................................................................158

8.0 Introduction.......................................................................................................... 158

8.1 A snapshot of summary findings..........................................................................158

8.1.1 Summary findings regarding the relationship between projects’

characteristics, respondents’ profile and occurrence of time overrun,

cost overrun and quality defects.................................................................. 160

8.1.2 Summary findings regarding KPIs.................................................................161

8.1.3 Summary findings regarding CSFs................................................................ 164

8.1.4 Summary findings regarding the Performance Evaluation Framework…….167

8.2 Managerial implications of the findings............................................................. 169

8.3 Recommendations............................................................................................... 170

8.4 Limitations of the study...................................................................................... 171

8.5 Directions for Future Research............................................................................ 172

REFERENCES......................................................................................................... 173

Appendices............................................................................................................... 191

xii

List of Tables

Table 2.1: Summary of the contributions to the study of KPIs....................................24

Table 2.2: Success variables and their impact on project success............................... 26

Table 4.1: Descriptive statistics of performance measurement variables obtained

through pilot survey.................................................................................... 52

Table 4.2: Item-to-total correlations among performance measurement variables

obtained through pilot survey................................................................... 53

Table 4.3: Descriptive statistics of project success variables of pilot survey............. 55

Table 4.4: Item-to-total correlations amongst project success variables obtained

through pilot survey .................................................................................... 56

Table 5.1: Distribution of respondents according to counties & Constituencies........ 59

Table 5.2: Types of CDF projects and their procurement approaches.........................63

Table 5.3: Status of CDF construction projects........................................................... 65

Table 5.4: Respondents’ Profile................................................................................... 69

Table 5.5: Descriptive statistics of performance measurement variables................... 70

Table 5.6: Original Correlation Matrix of performance measurement variables......... 74

Table 5.7 Measures of Sampling Adequacy and Partial Correlations amongst

performance measurement variables............................................................ 76

Table 5.8: Results of the Factor Analysis of performance measurement variables..... 78

Table 5.9: Correlation matrix of performance measurement variables after

grouping according to factor analysis...................................................... 81

Table 5.10: Descriptive statistics of project success variables.....................................86

Table 5.11: Original Correlation Matrix for project success variables....................... 89

Table 5.12: Results of the Factor Analysis of project success variables..................... 92

Table 5.13: Correlation matrix of project success variables after grouping

according to factor analysis....................................................................... 94

Table 7.1: Project characteristics and brief profile of the respondents.................... 116

Table 7.2: Incidences of time overrun, cost overrun and quality defects................. 118

Table 7.3: Results of ANOVA test between the types of projects and time

overrun, cost overrun and quality defects................................................ 119

Table 7.4: Results of the Chi-square test between project procurement approaches

and time overrun, cost overrun and quality defects................................ 120

xiii

Table 7.5 Post-hoc Chi-square tests between procurement approaches used and

occurrence of cost overrun....................................................................... 122

Table 7.6: Results of the Chi-square test between respondents’ experience

and time overrun, cost overrun and quality defects.................................. 123

Table 7.7: Summary of measurement results of Key Performance

Indicators (KPIs)....................................................................................... 125

Table 7.8: Discriminant validity checks: Chi-square differences............................. 125

Table 7.9: Results of Goodness of fit indices (GOF) of KPIs scale......................... 129

Table 7.10: Dimensions of performance evaluation among CDF

construction projects............................................................................. 130

Table 7.11: Loadings of First-order CFA of KPIs’ performance variables.............. 131

Table 7.12: Reliability test of performance measures among CDF

construction projects............................................................................. 135

Table 7.13: Discriminant Validity of KPIs................................................................ 136

Table 7.14: Summary of measurement results of Critical Success Factors (CSFs)... 138

Table 7.15: Discriminant validity checks: Chi-square differences............................ 138

Table 7.16: Results of Goodness of fit indices (GOF) of CSFs................................ 141

Table 7.17: Critical success factors among CDF construction projects.................... 142

Table 7.18: Loadings of First-order CFA of CSFs’ success variables...................... 143

Table 7.19: Reliability test of CSFs among CDF construction projects................... 146

Table 7.20: Discriminant Validity of CSFs............................................................... 147

Table 7.21: Summary of the results of Confirmatory Factor Analysis...................... 149

Table 7.22: Goodness of fit tests of SEM.................................................................. 153

Table 7.23: Summary of the constructs and measurement items in the

Structural Equation Model..................................................................... 154

Table 7.24 Direct impact of re-specified model based on standardised

regression weights.................................................................................. 156

Table 7.25 Indirect impact of re-specified model based on Standardised

regression weights.................................................................................. 157

Table 8.1 Summary of the dimensions of KPIs and performance measurement

variables in both survey I and survey II................................................... 162

xiv

Table 8.2 Summary of the dimensions CSFs and project success variables in

both survey I and survey II..................................................................... 165

xv

List of Figures

Figure 1.1: Flow chart of thesis organization................................................................ 8

Figure 2.1: Classification of construction projects……………,,,,………………….. 15

Figure 2.2: Phases of a construction project……………………………………….....16

Figure 2.3 Relationship between critical success factors and key

performance indicators.............................................................................. 30

Figure 3.1 Management structure of CDF construction projects................................. 37

Figure 3.2: Design/Bid/Build project procurement approach...................................... 40

Figure 3.3: Design/Build project procurement approach............................................. 41

Figure 4.1: Sequence of research followed in Study Phase I.................................... 48

Figure 5.1: Types of projects surveyed………………………...……………………. 63

Figure 5.2: Approaches used in project procurement……………………………….. 64

Figure 5.3: Time overrun amongst different types of projects.................................... 66

Figure 5.4: Cost overrun amongst different types of projects…………..………… 67

Figure 5.5: Quality defects amongst different types of projects………..………… 68

Figure 5.6: Scree Plot of performance measurement variables…............................... 77

Figure 5.7: Proposed theoretical framework of key performance indicator………… 82

Figure 5.8: Scree Plot of project success factors......................................... 90

Figure 5.9: Proposed theoretical framework of critical success factors...................... 95

Figure 5.10: Conceptualised relationship between project success and overall

project performance................................................................................ 99

Figure 6.1: Hypothesised performance assessment model for public

sector construction projects................................................................... 102

Figure 6.2: Sequence of research followed in Study Phase I..................................... 112

Figure 7.1: First order KPIs measurement model (Final)......................................... 128

Figure 7.2: Second order KPIs measurement model (Final)................................... 133

Figure 7.3: First order CSFs measurement model (Final)......................................... 140

Figure 7.4: Second order CSFs measurement model (Final)……………………..... 144

Figure 7.5: Initial Performance evaluation Model……………………………….... 151

Figure 7.6:Re-specified performance evaluation model…………………………... 152

xvi

List of Maps

Map 3.1: Map of Africa showing location of Kenya………………………….…... 32

Map 3.2: Map of Kenya showing Administrative (provinces) units………………. 33

xvii

LIST OF APPENDICES

Appendix A1: Questionnaire for Exploratory Study (Phase I)............................... 191

Appendix A2: Questionnaire for Confirmatory Study (Phase II)........................... 197

xviii

List of Abbreviations

AAK-Architectural Association of Kenya

AMOS-Analysis of Moments

BoQ-Bill of Quantities

CDFC- Constituency Development Fund Committee

CDF-Constituency Development Fund

CFA-Confirmatory Factor Analysis

CI-Construction Industry

CSF-Critical success Factor

DPC-District Project Committee

EFA-Exploratory Factor Analysis

EU- European Union

GDP-Gross Domestic Product

IEA- Institute of Economic Affairs

IGAD- Intergovernmental Authority on Development

ILO-International Labour Organization

IPAR- Institute for Policy Analysis and Research

KABCEC- Kenya Association of Building and Civil Engineering Contractors

KCA-Kenya contractors’ associations

KIPRA-Kenya Institute of Public Research and Analysis

KPI-Key Performance Indicators

MDGs-Millennium Development Goals

MPs- Members of Parliament

NCC- National Construction Company

NMB-National Management Board

PMC-Project Management Committee

PSCP-Public Sector Construction Projects

SEM-Structural Equation Modelling

SID-Society for International Development

SPSS-Statistical Package for Social Scientists

WB- World Bank

WPA-K- Women Political Alliance-Kenya

1

CHAPTER 1: OVERVIEW OF THE STUDY

1.0 Introduction

This chapter presents the background of the study emphasising upon of the

importance of performance measurement of public sector construction projects in

Kenya and other developing countries, the contribution of public construction sector

to the economy and the challenges it faces in developing countries. Subsequently, the

chapter discusses the research problem, research objectives, scope of the study and the

significance of the study. It also outlines the organization of the thesis in terms of

chapterization and the contents contained in each chapter. Further, assumptions of the

study and the specific terms used in the study have been highlighted.

1.1 Background of the Study

Assessment of performance amongst public sector construction projects has assumed

great importance in current scenario due to the sector’s ability to create economic

wealth, deliver social welfare services and at the same time its possibility to create

negative environmental impact. With reference to developing countries, performance

measurement of public sector construction projects has become even more important

due to its immense potential in addressing the problem of poverty, unemployment,

inequitable distribution of resources in different regions etc. However, as revealed in

literature, these projects have mostly been evaluated on the criteria of time, cost and

quality (Atkinson, 1999; Chan, 2001; Ahadzie, Proverbs & Olomolaiye, 2008; Salleh,

2009). This traditional approach, popularly known as the “iron triangle” (Atkinson,

1999) merely captures the economic aspects of public sector construction projects and

ignores relevant social or environmental aspects.

In view of this shortcoming of traditional criteria, Organisation for Economic Co-

operation and Development's (OECD) Development Assistance Committee (DAC)

has introduced a performance evaluation criterion of development projects based on

relevance, efficiency, effectiveness, impact and sustainability (Beck, 2006; Chianca,

2008; Ika, Diallo & Thuiller, 2012). This criterion, popularly known as the five pillars

of development projects (Beck, 2006; Ika et al., 2012), though seems to capture both

economic and social aspects of public sector construction projects, do not adequately

address the environmental aspects that are considered quite important in these kinds

2

of projects. Further the researchers have suggested hardly any objective measure upon

which the five pillars can be operationalised.

Academic researchers with a view to overcoming the limitations of the traditional

performance evaluation criteria of time, cost and quality have suggested the inclusion

of additional measures of performance. These include safety of the project site

(Ortega, 2000; Haslam et al., 2005; Billy, Cameron & Duff, 2006), site disputes

(Tabish and Jha, 2011), environmental impact (Eriksson and Westerberg, 2011) and

community/client/customer satisfaction (Chan & Chan, 2004; CURT, 2005; Ali &

Rahmat, 2010). These contributions, although widen the scope of performance

evaluation amongst public sector construction projects, are skewed towards either

societal or environmental aspects. None of the above has provided a balanced set of

Key Performance Indicators (KPIs) which would capture all essential and unique

features of a public sector construction project.

Further, these studies have not talked about the appropriate facilitating factors that can

help project managers achieve success on KPIs identified above. The identification of

these factors, also known as critical success factors (CSFs), is very important for

ensuring success of any project because it enables project managers to commit

resources on specific factors.

A survey of success factors amongst construction projects reveals that they are

numerous in number and they influence project success to varying degrees, with

certain factors being more critical to project success than others. Different researchers

have suggested a number of CSFs that influence project success on different

dimensions of construction projects. The CSFs have been classified in various ways

by the researchers (as has been revealed in Literature Review Chapter) based on the

common characteristic features of construction projects. However, there is hardly any

study which has attempted to identify CSFs of construction projects based on the

KPIs of the same specifically with reference to public sector construction projects.

With this backdrop, the present study is an attempt to identify the KPIs amongst

public sector construction projects and on the basis of these KPIs, identify appropriate

CSFs relevant for success of public sector construction projects and find out the

influence of these CSFs on project success. The relationship between project success

3

and overall project performance in terms of the KPIs is also investigated in the current

study. This has been demonstrated with the help of relevant data collected from the

Constituency Development Fund (CDF) projects constructed during the period

between 2003 and 2011 in the Western Province, Kenya.

1.2 Public sector construction projects: Contribution and challenges

Public sector construction projects play a key role in the growth of economies in

developing countries in terms of their contribution towards Gross Domestic Product

(GDP), employment generation and provision of an important market for materials

and products produced by other sectors of the economy (ILO, 2001). Khan (2008)

argues that there is a clear relationship between a construction activity, economic

growth and economic development. A recent survey reports that total world

construction spending on infrastructural projects in 2007 was $4.7 trillion, which rose

to $ 7.2 trillion in 2010 and is expected to grow to $12 trillion in 2020 (Global

construction 2020, 2010). A large proportion of this expenditure is in the public

construction sector.

In developing countries, the construction of public sector projects is undertaken by the

national governments. In most cases, because of the requirement of huge capital

which is lacking in many developing countries, the governments supplement their

development budget with aid from international agencies and other development

partners. According to Shen et al. (2010), addressing the infrastructural needs

especially in view of the current economic pressures in developing countries require

government agencies and construction industry stakeholders to find more efficient and

effective ways of delivering the capital projects while controlling the costs. However,

project implementing agencies have faced several challenges in search of appropriate

mechanism for delivering public sector construction projects.

Specific challenges that project implementing agencies face in the construction of

public sector construction projects include limited funding, scarcity of raw materials,

presence of a large unskilled labour force and the presence of several rules and

regulations that limit their independence (Datta, 2002). In addition, public

construction sector is faced with low levels of infrastructural development, poor

financial practices and a lot of political interference due to multiple funding sources

4

(Ofori, 2000). Further, political instability, a common phenomenon in developing

countries and fraudulent practices inherent in this sector hinder the growth of public

construction sector. These challenges present difficulties in implementation of public

sector construction projects such that if not properly managed, the construction of

these projects may lead to colossal financial loss instead of desired economic

outcome. This may eventually make it difficult for the project implementing agency

to realise the intended objective of public sector construction projects of delivering

services to the people.

1.3 Research Problem

As it has been mentioned, the purpose of public sector construction projects is to

provide services for public use, while charging minimal fees. In many developing

countries, these construction projects include those projects that aim at providing

basic Educational facilities, Health Care facilities, Business opportunities and

Employment opportunities etc. In order to enable the community derive the benefits

of the above projects, these projects need to be evaluated on all relevant dimensions

including economic, social and environmental ones. However, as already mentioned,

these projects have so far been evaluated mostly on the basis of traditional

performance evaluation criteria of time, cost and quality which are found to be

relevant for commercial projects. This criterion, though captures the economic

aspects, ignores other important elements of public sector construction projects and

hence makes it difficult to attain the main purpose for which the projects were

conceptualised. Although OECD/DAC has introduced the “five pillars”, the criterion

has faced problems of operationalisation.

The “iron triangle” criterion currently used to evaluate the performance of public

sector construction projects focus more on the perspectives of the project

implementing agencies and ignores the needs of the beneficiaries. These agencies are

satisfied with a project once it meets budgeted cost, adheres to stipulated time and

conforms to the technical specifications. However, merely fulfilling these criteria may

not ensure the realization of ultimate benefits of the project to the communities for

whom the same is constructed. The implementing agencies are hardly concerned with

whether the project is delivering intended services to the community, whether the

5

project has created any safety issue among the people or it has created any dispute

with surrounding community. Further, iron triangle criterion does not take into

consideration the adverse environmental impact that might be created due to the

project. Thus iron triangle criterion may satisfy the needs of implementing agency in

terms of time, cost and quality but fail to address the needs of the community thereby

defeating the very purpose for which public sector construction projects were

implemented.

Therefore, the problem facing public sector construction projects in developing

countries seems to be the lack of an appropriate performance measurement framework

that does not merely focus on the needs of the project implementing agency, but also

addresses the needs of the actual beneficiaries. Without such a framework, project

implementing agencies will not be able to assess the performance of public sector

construction projects on economic, social and environmental dimensions, which are

considered important for these kinds of projects.

1.4 Research Objectives

In view of the background of the research problem, the broad objective of this study is

to develop a multi-dimensional performance evaluation framework encompassing

economic, social and environmental dimensions of public sector construction projects.

Specific objectives of research are to

i) Identify the KPIs appropriate for measuring performance of public sector

construction projects.

ii) Identify the CSFs influencing the success of public sector construction

projects.

iii) Confirm the KPIs identified above and examine the relationship between the

confirmed KPIs and overall project performance.

iv) Confirm the CSFs identified above and examine the influence of the

confirmed CSFs on project success.

v) Find out the mediating effect of external environment in the influence of CSFs

on project success.

vi) Examine the relationship between project success and overall project

performance in terms of the KPIs.

6

vii) Examine the extent of differences in the occurrence of cost overrun, time

overrun and quality defects across different types of construction projects.

viii) Examine the association between the project procurement approaches

followed in public sector construction projects and occurrence of cost overrun,

time overrun and quality defects.

ix) Examine the association between stakeholders’ (client, consultant and

contractor) experience on construction projects and occurrence of cost

overrun, time overrun and quality defects.

1.5 Scope of Study

In pursuing this research, the focus of attention was on the public sector construction

projects. The study was based on the Constituency Development Fund (CDF)

construction projects in Western province, Kenya. The kinds of projects analysed in

this study were mainly the construction projects pertaining to Education, Health,

Agricultural Markets and Industrial Estates. These are the main projects upon which

CDF is allocated, for purposes of improving socio-economic wellbeing of the

communities. The study targeted those projects which were funded by CDF in Kenya

in the financial years between 2003/2004 to 2010/2011. This is because prior to 2003,

public sector construction projects were mainly undertaken by the central government

through various line ministries and hence obtaining relevant information proved to be

difficult.

For the purpose of analysis, the study sought perceptions of three kinds of

stakeholders namely clients, consultants and contractors involved in the construction

of the above mentioned CDF projects. This was necessary because all three kinds of

stakeholders had different roles to play on construction project but they all had an

ultimate goal of delivering a project successfully (Wang and Huang, 2006).

1.6 Significance of this study

The outcome of the current study will be of benefit to several stakeholders that

implement public sector construction projects as well as future researchers.

The project monitoring and evaluation agencies will use the developed framework to

evaluate performance of public sector construction projects. Other than merely

7

declaring a project as successful or not, they will be able to describe performance in

terms of how “good” it is on different performance indicators.

The set of KPIs and CSFs identified will enable the project implementing agencies to

assess, monitor and report the progress of the project as construction takes place.

Further, the project implementing agencies can use the performance evaluation

framework for allocation of appropriate resources to the CSFs with a view to realising

desired performance on specific KPIs.

The performance evaluation framework in the current study also provides direction to

the government and donor agencies that they should not merely focus on economic

measures of performance but also consider project outcome in terms of providing

appropriate services to the society while taking care of adverse environmental impact.

Further, on the basis of findings of the current study, the beneficiaries of the project

will have an idea of whether the intended benefits are actually being delivered by the

project as conceptualised. Therefore, the study provides a basis through which the

services delivered can be compared with the intended benefits.

Further, literature review of literature has revealed that there is hardly any empirical

research on performance evaluation of construction projects with reference to Kenya.

Given that this study could be the first of its kind to develop a multidimensional

performance evaluation framework, it advances the body of knowledge in terms of

performance evaluation amongst this kind of projects. The future researchers will also

gain insights as to how apparently intangible measures of performance are

operationalised in order to capture all relevant project objectives.

1.7 Organization of Thesis

The thesis is organised sequentially in several steps. These steps are discussed in eight

chapters as shown in Figure 1.1.

Chapter 1 discusses the overview of the study by highlighting the background of the

study, the contribution of public sector construction projects and the challenges they

face, research problem, research objectives, scope of the study and significance of the

study. The chapter further provides the assumptions of the study and definition of

terms used in the current study and outlines the organization of the thesis.

8

Figure 1.1: Flow chart of thesis organization

Background of the Study Public sector construction projects: Contribution and challenges Research problem, Research objectives, Significance of the Study, Scope of the study Organization of the thesis, Assumptions of the Study and Definition of terms

Overview of public sector construction projects Performance of construction projects Key Performance Indicators (KPIs) of public sector construction projects. Critical Success Factors (CSFs) Relationship between KPIs and CSFs

Summary of the Study, Managerial implications of the results, Recommendations of the Study, Limitations of the study, Future Research directions Conclusion

Research findings (Phase I) Screening of collected Data, Demographic characteristics of projects and respondents’ profile, Exploratory factor analysis of performance measurement variables and Exploratory Factor analysis of project success variables

Key issues in the study, Process followed, Design of the survey instrument, Reliability of the survey instrument, Study site and identification of target population and Data collection.

Facts on Kenya Early government initiatives Constituency Development Fund (CDF) in Kenya Existing practices of Monitoring of CDF projects

Research findings (Phase II) Screening of collected Data, Demographic characteristics of respondents and projects, Confirmatory factor analysis of performance variables, Confirmatory factor analysis of project success variables, Structural Equation Modelling

CHAPTER 1: OVERVIEW OF

THE STUDY

CHAPTER 2: LITERATURE

REVIEW

CHAPTER 3: PUBLIC

CONSTRUCTION SECTOR IN

KENYA AND THE

CONSTITUENCY DEV. FUND

CHAPTER 4: RESEARCH

METHODOLOGY (PHASE I)

CHAPTER 5: RESEARCH

FINDINGS AND DISCUSSION

(PHASE I)

CHAPTER 7: RESEARCH FINDINGS AND DISCUSSION (PHASE II)

CHAPTER 8: SUMMARY,

CONCLUSION AND

RECOMMENDATIONS.

CHAPTER 6: RESEARCH

METHODOLOGY (PHASE II)

Key issues in phase II, Theoretical framework and statement of hypotheses, process followed in research methodology, design of survey instrument, study site, target projects and target population, Data collection

9

Chapter 2 focuses on the literature review and provides an overview of public

construction projects in terms of their definition, classification and phases involved in

project construction. The chapter also discusses the performance of construction

projects in general and the performance of public sector construction projects in

particular. Further, the chapter reviews relevant literature on KPIs and CSFs of public

sector construction projects. Based on the review, literature gaps are identified and

highlighted in this chapter.

Chapter 3 provides a brief overview of construction sector in Kenya, early

government initiatives to develop the sector and the nature of CDF construction

projects. It highlights the process of identification and selection of CDF projects, their

implementation and the current practice in monitoring and evaluation of the same.

Chapter 4 describes the research methodology employed in carrying out exploratory

research (phase I). This chapter discusses the design of the survey instrument,

reliability of the survey instrument, study site and identification of target population

and data collection procedure. The aim of the chapter is to identify the KPIs and CSFs

of CDF construction projects in Kenya with a view to developing scales for project

performance measurement and project success.

Chapter 5 discusses the findings of exploratory study (phase I). The chapter reports

the characteristics of the projects and respondents’ demographic profile in terms of

their experience and role on the project. It further deals with factorability of

performance measurement variables and project success variables, factor analysis of

the performance measurement variables and project success variables and the

validation of the KPIs and CSFs scales. The chapter also presents theoretical

frameworks for the KPIs and CSFs scales separately and finally describes the

conceptual framework for assessment of performance of public sector construction

projects.

Chapter 6 discusses the research methodology used in carrying out confirmatory

research (phase II). The aim of this chapter is to confirm the KPIs and CSFs identified

in Phase I and show the relationships between CSFs, project success, overall project

performance and KPIs. The chapter mentions the various hypotheses proposed in the

study based on the conceptual framework developed in chapter 5. It further describes

10

the design of survey instrument, study site, target projects, target population and data

collection approach used in phase II.

Chapter 7 discusses the findings of confirmatory study (phase II). It presents the

demographic characteristics of respondents and projects and discusses the results of

confirmatory factor analysis (CFA) of both KPIs scale and CSFs scale. Further, it

presents the results of Structural Equation Modelling (SEM) that was used to

determine the influence of CSFs on project success, the association between project

success and overall project performance and the relationships between overall project

performance and the KPIs. The results of tests of hypotheses are also presented and

discussed.

The final part of the thesis, chapter 8, describes the summary of results, managerial

implications, recommendations, limitations and direction for future research.

1.8 Assumptions of the Study

There are three assumptions made in this study. First, this research assumed that the

experts were capable of accurately articulating their viewpoints regarding the

performance measurement variables and project success variables which were

administered to them for pilot survey. Secondly, this study assumed that the

stakeholders from all the three categories namely clients, consultants and contractors

are equally capable of judging performance of construction projects. It is further

assumed that all three stakeholders’ perspectives are based on identical experiences

with similar types of projects, though it is acknowledged that these stakeholders’

perception may be influenced by their previous experiences with the private projects

too. In scale development, it is assumed that the measure used is assessing what it is

presumed to assess.

1.9 Definition of Terms

Project: Any human undertaking that has a clear beginning and a clear end. In the

current study, a project is defined in terms of the various construction activities which

are undertaken within a given timeline with an objective of having constructed a

facility for the use of the community.

Project management: The process of planning, organising, executing and monitoring

of project construction activities.

11

Construction: This is the process in which an infrastructure is developed,

Construction Project: This refers to all those activities and resources necessary for

coming up with an infrastructure for occupation by the end users,

Funding: Refers to the provision of the required capital/fund for project construction.

Rework: Refers to working again i.e. the process of repeating work that had not been

done properly the first time.

Time overrun: Also known as schedule delay, time overrun is the excess time by

which actual time exceeds the scheduled time of the project.

Cost overrun: This is the amount by which the actual expenditure exceeds the

budgeted cost of the project. It can also be referred to as cost escalation.

Project Performance: This is the extent to which a project achieves the intended

objectives on prescribed metrics. In this study project performance is expressed in

terms of time, cost, quality, safety, site disputes and environmental impact.

Key performance indicators: Metrics upon which performance is measured.

Time Performance: The degree to which a project achieves its time targets and is

measured on the basis of scheduled time and the actual time taken by the project.

Construction Time: The number of days from the commencement of work on site to

the practical completion point.

Cost Performance: This is a comparison between actual expenditure and budgeted

cost.”

Quality performance: During project inception, certain technical and quality

specifications are prescribed for a project. The extent to which a project adheres to the

specifications indicates the level of its quality performance.

Safety performance: This is the extent to which a project adheres to safety standards.

It is reflected through the number of accidents and/or fatalities experienced.

Site dispute performance: Refers to work disruptions that result from disagreements

during and after project construction.

Environmental impact performance: The impact of constructed facility on the

surrounding environment.

Critical success factors: Those specific factors which are important if a project has

to achieve its mission

12

Public sector construction project: A project that is publicly funded by central

government through CDF for the benefit of surrounding community.

Endogenous variables: These are the dependent variables in SEM i.e. constructs that

are influenced by other constructs.

Exogenous variables: In SEM, they are the independent variables i.e. constructs that

exert an influence on other constructs under study and are not influenced by other

factors. They are also said to be observed, measured, indicator, and manifest

variables.

“Mwanainchi”: A Swahili name for an ordinary citizen

Financial Year: In reference to Kenya, this is an accounting period that starts on 1st

June and has twelve consecutive months (52 weeks) up to 31th May of the next year

at the end of which a budget is read out.

13

CHAPTER 2: REVIEW OF LITERATURE

2.0 Introduction

This chapter presents an overview of public sector construction projects by

highlighting the definition, classification and construction phases of these projects.

Next, the chapter discusses the performance of public construction projects in terms

of KPIs that have been identified for performance measurement amongst public sector

construction projects and the CSFs that influence the success of these projects. Since

the concept of performance measurement is rooted in operations management

literature, the researcher relied heavily on the rich literature available in this

functional domain. Using the terms ‘project performance’, ‘performance criteria’

“project success”, ‘key performance indicators’ and ‘critical success factors revealed

a rich source of research articles, mainly in the journals published by numerous

publishers, in particular Elsevier, Emerald, IEEE Engineering management, American

Society of Civil Engineering (ASCE), Inderscience publishers and Taylor and Francis

during the period 1995-2013. The specific journals included Automation in

Construction, Building and Environment, Construction Management and Economics,

IEEE Transactions on Engineering Management, International Journal of Production

Economics, International Journal of Project Management, Journal of Cleaner

Production, Journal of Construction Engineering and Management, International

journal of project organisation and Management, Journal of Construction in

Developing Countries and Total Quality Management.

The last section highlights the research gaps in the existing literature and explains the

relationship between CSFs, project success, overall project performance and the

various KPIs as derived from literature.

2.1 Overview of public sector construction projects

This section of the study provides a description of the public sector construction

projects in developing countries. It defines public sector construction projects and

discusses the classification of construction projects in general. The section also

highlights the phases of construction projects.

14

2.1.1 Definition of construction projects

According to Kerzner (2006), a construction project is a complex set of activities and

tasks with a definite start date and a definite completion date and consumes resources

such as money, human resources, outputs and equipment in order to achieve specific

objectives. Further Project Management Institute (PMI, 2008) emphasizes that a

project is temporary because it has a defined beginning and a defined end in time as

well as defined scope and resources. It is also unique because it is not a routine

operation. Construction has generally been said to be a process in which material,

equipment and machinery are assembled into a permanent facility. It is generally

defined to encompass the creation of physical infrastructure (roads, railways,

harbours), other civil-engineering work (dams, irrigation projects, power plants), all

building work (including housing), as well as the maintenance and repair of existing

structures. Construction projects have been classified in several ways in order to

distinguish amongst them.

2.1.2 Classification of construction projects

The construction projects in most developing countries can be classified into various

categories depending on their complexity, scope and use. Shenhar (2001) argues that

despite all projects having certain features such as a goal, budget and timeframe, they

differ in several ways to the extent that “one size does not fit all”. Construction

projects can, therefore, be classified based on size as small, medium, large or mega;

ownership as private or public; use as residential, commercial, industrial or utility;

and scope as building or infrastructural projects. Among these categories of

classification, project scope provides a better classification of public construction

projects.

Accordingly, based on scope, a project is categorized as a building or an

infrastructural project. Infrastructural projects include engineering industries,

highway, heavy constructions and bridges (Grace, 2010). A building project could be

residential or non residential when it is further classified based on its use. Residential

construction projects include houses, townhouses, apartments, and cottages. Because

of its use, residential building construction is perhaps the most popular type of

construction projects undertaken in developing countries especially by the private

15

sector. Non residential buildings refer to institutional and commercial buildings that

cover a great variety of project types and sizes such as hospitals and clinics, schools

and universities, sports facilities and stadiums, large shopping centres and retail chain

stores, light manufacturing plants and warehouses and skyscrapers for offices and

hotels. Figure 2.1 shows the classification of construction projects.

Figure 2.1: Classification of construction projects

Institutional construction is a major part of public construction sector and is very

important for the development of a country to satisfy the varied needs of its people.

Infrastructural projects constitute a small part of the whole construction industry

although it is a very important part of the industry. These projects are generally

owned by big, for-profit industrial corporations such as manufacturing, power

generation, medicine, petroleum, etc. Specialized Industrial Construction usually

involves very large scale projects with a high degree of technological complexity such

as nuclear power plants, chemical processing plants, steel mills and oil refineries.

Highway construction involves the construction, alteration and repair of roads,

highways, streets, alleys, runways, paths, parking areas etc. It includes all incidental

construction in conjunction with the highway construction project. Heavy

construction projects usually involve projects that are not properly classified as either

CONSTRUCTION PROJECTS

Buildings Infrastructure

Non-residential Residential Highway Heavy commercial

Institutional Commercial

16

"building" or "highway." Examples of this type of project would be: water and sewer

line projects, dams, sewage treatment plants and facilities, flood control projects,

dredging projects, and water treatment plants and facilities. Halpin and Woodhead

(2006) provided a classification under three categories: (1) building and

infrastructure, (2) non residential and residential; and (3) institutional and

commercial.

The current study only concentrates on building projects that are non-residential as shaded in Figure 2.1. Though such projects could be either institutional or commercial, public sector construction projects majorly involve construction of institutional facilities such as Schools, Hospitals, Industrial Estates and Agricultural Markets. Regardless of the classification, every project is developed through a number of stages referred to as phases of construction projects (Kerzner, 2006; PMI, 2008), that are sequentially related.

2.1.3 Phases of construction projects

The construction of building projects is undertaken in a number of phases, each of which is a designated group of activities that normally result in a milestone. A number of scholars have described the phases of projects in terms of conception, planning, procurement, construction and start-up (Kerzner, 2006). Others have explained it in fewer stages: conception, design and construction (Puspasari, 2006).

PMI (2008) stated that there are four phases to a project namely (1) conception, (2) development, (3) implementation and (4) termination. These phases capture all the activities that take place in construction projects. The four different stages could also be termed as (1) Project conception and planning, (2) Project design and tendering, (3) Project construction and (4) Project operation and maintenance. This nomenclature better reflects the activities carried out during the four phases of construction projects.

Figure 2.2 presents the project life-cycle.

Figure 2.2: Phases of a construction project

Project conception and Planning

Project design and tendering

Project construction

Project operation and maintenance

17

According to the PMI (2008) description, project conception and planning is the

recognition of the need for creation of a physical structure. The project design and

tendering phase translates the primary concept into an expression of a spatial form

which will satisfy the owner’s requirements in optimum and economic manner. The

construction phase creates the physical form which enables realization of the design.

The last phase, that is, operation and maintenance phase examines whether the

physical structure satisfies the identified need. The current study examines the

performance evaluation at the construction phase as shaded in Figure 2.2.

2.2 Performance measurement amongst public sector construction projects

By engaging in the construction sector, national governments in developing countries

aim at improving the socio-economic condition and standards of living of its people.

However, public sector construction projects are characterised by the scarcity of

resources in terms of material, equipment and funding, which makes it essential on

the part of implementing agency to exercise utmost prudence while managing

expenditure with a view to realising the goal of public sector construction projects.

Different parties involved in the construction of public sector construction projects

differ in terms of their objectives. In such circumstances, a project would be deemed

to be successful when it addresses the objectives for which it was conceptualised.

Several researchers (Bryde & Robinson, 2005; Diallo & Thuiller, 2005) have noted

that a project is said to have been successful if it addresses the needs and requirements

of project stakeholders.

The stakeholders involved in public construction projects include the government

agencies, project designers, contractors and the community for which the project is

being undertaken. In many occasions, the government is the client of public sector

construction projects whereas the community constitute the beneficiaries for which

the project is being implemented. Wang and Huang (2006) reported that the most

important stakeholders of a construction project are the client, consultant and

contractor. They summarise the role of each of these stakeholders as follows:

• Project client shall procure construction contractor through bidding/tendering

and encourage independent and professional project management services

provided by consultant.

18

• Consultant and contractor shall perform their technical, organizational and

human responsibilities for the project.

• Construction contractor shall perform the construction in accordance with

relevant technical, management and contract specifications.

According to PMI (2008) the interest of stakeholders may be same, overlapping or

conflicting in nature, but the project implementing agency should attempt to

harmonise all these interests in order to achieve project success.

Several researchers (Zhao, et al., 2010; Yu & Kwon, 2011) have indicated that

client’s criteria for measuring performance is on the basis of completing the project

on schedule and budget while ensuring that the project function as per the intended

use (satisfy users and customers). Consultant’s criteria for measuring success are:

satisfied client (obtain or develop the potential to obtain repeat work), satisfactory

quality of architectural product, receipt of design fee etc. In addition, consultants

consider professional staff fulfilment (e.g. gain experience, learn new skills) and

meeting project budget and schedule as additional criteria of success. Contractors aim

at producing marketable product/ process that is appealing to the client, consultant

and other contractors while involving minimum cost. As they pursue profit objectives,

they seek to meet or exceed quality specifications so as to satisfy project clients.

Based on the stakeholders’ criteria, it is evident that there are some unique factors

associated with each of the three groups. The consultant, for instance, is looking for a

project that will increase the level of professional development and professional

satisfaction among his employees (Aaltonen & Jaakko, 2010). Safety, that would not

normally be an issue with the other two groups of stakeholders is a high-priority issue

for the contractors because their employees are at much more risk during the

construction of a building than the employees of consultants and clients during design

or operation of a building respectively (Bryde & Robinson, 2005; Diallo & Thuiller,

2005). A client is extremely interested in knowing that the building project functions

properly for the intended use and is free from long-term defects or lingering

maintenance problems.

Previously, performance of public construction sector has been measured on the basis

of the sector’s contribution to Gross Domestic Product (GDP) and increase in labour

19

productivity (Willis & Rankin, 2011). This approach has, however, been dismissed as

being impractical because contribution to GDP is a mere economic activity whereas

labour productivity is difficult to measure (Harrison, 2007). Henricsson and Ericsson

(2005) suggested performance evaluation of a public construction sector based on its

competitiveness but this could also not be operationalised. These shortcomings have

compelled project implementing agencies in the public sector to utilize performance

metrics popular among private sector construction projects with suitable

modifications. These performance metrics are known to be based on key performance

indicators (KPIs).

2.2.1 Key Performance Indicators (KPIs) of public sector construction projects

The various KPIs that have been considered for performance evaluation in existing

literature can be broadly classified into three categories: the traditional criteria of the

iron triangle, the five pillars proposed by OECD/DAC and the contemporary

measures.

2.2.1.1 Traditional criteria, the “iron triangle”

Majority of the researchers associated with construction project management have

mostly talked about the importance of time, cost and quality (Zuo et al., 2007;

Ahadzie et al., 2008; Kaliba et al., 2009; Kamrul & Indra, 2010) while evaluating the

performance of public or private construction projects. The use of these three metrics

can be traced back to the inception of project management concept in 1950s. As early

as in 1989, Kerzner reported that project management has been traditionally described

as managing or controlling company resources on a given activity, within time, within

cost and within performance (Kerzner, 2006).

Project time can be considered as being the duration from the inception of a project to

its completion. Two aspects of time are important in project management: planned or

expected project time and actual completion time. When actual project completion

time exceeds the planned time, such a project is said to have experienced a time

overrun or schedule delay. Delays are incidences that impact on project delivery

process and usually postpone project activities. This aspect of project performance has

been reviewed by several researchers using different approaches (Frimpong, Oluwoye

& Crawford, 2003; Williams, 2003; Assaf & Al Hejji, 2004; Kamrul & Indra, 2010).

20

Time performance can be considered upon three measures: construction time, speed

of construction and time variation (Chan & Chan, 2004).

A project cost includes the overall costs that are incurred on a project from inception

to its completion. It covers the tender sum, construction costs, costs that arise from

variations and modifications during construction as well as costs that arise from legal

claims such as litigation and arbitration (Chan & Chan, 2004). When the actual

project cost exceeds the budgeted cost, the project is said to experience cost overrun,

cost increase or budget overrun. Several researchers (Chan & Chan, 2004; Kaliba et

al., 2008; Patanakul & Milosevic, 2009) have emphasized the need to consider cost

when determining project performance in project management literature. Cost

performance on a project can be measured in terms of unit cost or as a percentage of

net variation over the overall cost as suggested by Chan and Tam (2000). Ali and

Rahmat (2010) used a cost element to describe project performance and specifically

stated that cost variance is calculated by the variance between the actual cost and the

budgeted cost of a project.

Previous researches have also indicated that project quality can be used to measure

the performance of a construction project (Jha & Iyer, 2006; Palaneeswaran, 2007;

Love et al., 2010; Ogano & Pretorius, 2010; Yung & Yip, 2010). In their article, Ali

and Rahmat (2009) indicate that BS 5750 (1987) defines quality as ‘The totality of

features and characteristics of a product or service that bear on its ability to satisfy

stated or implied needs. In project management, the emphasis of quality is on the

ability of the project to adhere to the set up specifications. Poor quality in projects

results in numerous reworks which unnecessarily undermine other project

performance indicators. The measurement of quality is subjective and varies from one

entity to another.

This traditional criterion of time, cost and quality has been hailed for having provided

a basis in evaluating the extent of success across projects (Cao & Hoffman, 2011),

being simple (Toor & Ogunlana, 2010), being easy and timely to measure (Willard,

2005) and its ability to capture the tangible benefits of the projects (Litsikakis, 2009).

The use of these three dimensions is still considered a good practice for some

projects, while for others it could undermine some important project outcomes. Critics

21

of these criteria have indicated that they do not adequately cover all aspects of

performance measurement (Gardiner, 2000), they are related to each other (Shenhar,

Asher, Dov, Stanislav, & Thomas, 2002) and are rigid in their evaluation of

performance amongst public sector projects (Bassioni, Price & Hassan, 2004).

Terming the three measures of performance (time, cost and quality) as efficiency

variables, Kylindri, et al. (2012) have stated that they have been over researched and

there is need for new variables. In order to improve a project evaluation system, one

has to consider differences in project characteristics, appropriateness of project goals

and changes taking place in project environment. A project performance measurement

criterion should consider diversity and both technical and social needs of the project

(Barclay and Osei-Bryson, 2010).

2.2.1.2 Performance criteria based on “five pillars”

In pursuit of a new criterion, major development agencies internationally, have

adopted the evaluation criteria defined OECD/DAC (Beck, 2006; Chianca, 2008) in

evaluating public sector projects. The definition contains five evaluation criteria that

should be used in assessing public sector projects: relevance, efficiency, effectiveness,

impact and sustainability. The relevance of a project describes the extent to which the

aid activity is suited to the priorities and policies of the recipient, donor and the

beneficiaries. Whereas the above definitions describe "relevance" as an ex-

ante element of evaluation, it can also be applied ex-post once the project is

completed and handed over to the beneficiaries. The ex-ante relevance of public

sector project is presumably taken care of during project identification and selection

phase. Within a particular community, public sector projects are identified by the

respective communities based on their needs (Wanjiru, 2008). Such projects undergo

rigorous approval procedure before their ultimate construction. This ensures that they

are relevant to the communities where they are constructed. At the ex-post evaluation,

one should ask whether the originally intended relevance has been realized. Such a

question can only be answered by the actual beneficiaries of the project when they

start reaping its benefits because economic growth and the general wellbeing of a

community can be noted during operational phase as they take time to realize.

Efficiency is a measure of how economically resources/inputs (funds, expertise, time,

etc.) are converted to results (Beck, 2006; Chianca, 2008). It includes the cost of

22

resources as well as the construction cost of the development. Effectiveness is the

extent to which the project’s objectives were achieved, or are expected to be achieved

and seeks to determine the factors that influence achievement or non achievement of

the objectives. Further, projects’ impacts refer to the direct or indirect positive and

negative, primary and secondary long-term effects produced by a project. This pillar

assesses whether the effects achieved correspond with the needs, problems and issues

that are to be addressed by the construction projects. Sustainability refers to the

continuation of benefits from a project after major development assistance has been

completed (Beck, 2006; Chianca, 2008). This is in reference to post implementation

phase and assesses whether the project will continue to operate as intended. It further

calls for the need for appropriate mechanism of financing the operational and

maintenance cost incurred in providing the intended services to the community. This

OECD definition, therefore, hardly covers ecological sustainability which is also

important in a public sector project.

The proposed five pillars, though considered an improvement over the iron triangle,

suffer from several weaknesses. According to Chianca (2008), these pillars focus

more on the needs of funding agency than on the needs of the targeted communities.

The definitions are ambiguous and overlapping especially those of relevance,

effectiveness and impact. Further, efficiency and sustainability merely focus on

monetary aspects and ignores the intangible elements that could bring about increases

in cost. These definitions, therefore, lack an objective measure upon which the pillars

can be operationalised (Chianca, 2008). Ngacho and Das (2013a) have argued that

difficulties in the operationalisation of these pillars pose a major challenge to the

project implementing agency in capturing the economic, social and environmental

dimensions of public sector projects. Attainment of the five pillars becomes further

complicated due to the uniqueness in the environment that surrounds these projects.

2.2.1.3 The contemporary measures of project performance

A number of researchers have advocated for a wider focus of construction project

performance. Some researchers (Ortega, 2000; Haslam et al., 2005; Billy et al., 2006;

Zuo, 2011) have argued that it is important to incorporate safety aspects of the project

in performance evaluation because the construction industry is the most unsafe

23

industry due to its high rate of fatalities. In most developing countries, the

construction industry is mainly labour intensive and the majority of the workforce

working on construction sites is unskilled. The workers are, therefore, exposed to risk

and health hazards inherent in construction projects that require adequate safety

provisions (Zuo, 2011). Project safety, being a humane issue, needs to be considered

separately from time, cost and quality dimensions. Few other researchers (David,

2009; Tabish & Jha, 2011) have given emphasis on dispute resolution which might

otherwise lead to disagreements amongst project participants and derail the project

objectives. Dispute resolution is part of stakeholder management and hence should be

part of project performance evaluation criteria (David, 2009).

According to Eriksson and Westerberg, (2011), construction projects have irreversible

impact on the local environment because construction processes not only consume

huge energy but also create the most waste, use large quantity of non-energy related

resources and are responsible for the most pollution. Environmental impact, being

indirect and long term in nature, can hardly be captured for inclusion under any of the

three traditional measures, but has implications on sustainability of the project within

the community. It is, therefore, necessary to include environmental impact into the

performance metric of construction project performance (Tsoulfas & Pappis 2008;

Chen et al., 2010; Medineckiene et al., 2010; Tan et al., 2011). Currently, a number of

regulatory incentives are pushing organisations to adopt environmentally friendly

construction methods to ensure that they develop the capability of delivering

sustainable projects within acceptable cost constraints.

Shao and Müller (2011) reported that community satisfaction is the ultimate goal of

every construction project and hence it must be considered while evaluating

construction project performance. This view is supported by Ali and Rahmat (2010),

CURT (2005), Chan and Chan (2004), who found that client/user /customer

satisfaction is an important goal of every construction project and hence should be

considered when evaluating project performance. However, Miles et al. (2008)

observed that community satisfaction is a consequence of overall project performance

and hence the same cannot be used as one of the metrics of construction project

performance but as an outcome of the overall construction project performance. It is

24

manifested through the community’s wellbeing in terms of improved healthcare,

education development, provision of employment opportunities and enhanced

business activities. Further, Ngacho, Das and Makori (2012) showed that performance

of construction projects lead to community satisfaction. Takim and Akintoye (2002)

proposed the inclusion of functionality, profitability to contractors, absence of claims

and court proceedings and fitness for purpose for occupiers. In addition, Enshassi,

Mohamed and Ekarriri (2009) have suggested innovation and learning, productivity

and environment as possible measures of project performance.

The following table (Table 2.1) summarises the findings of various studies undertaken

with a view to identifying KPIs in public sector construction projects.

Table 2.1: Summary of the contributions to the study of KPIs KPIs Contributions

Cost Ahadzie et al. (2008), Ali and Rahmat (2010), Atkinson (1999), Chan

and Chan (2004), Kaliba et al.(2009), Zuo et al. (2007)

Safety Billy et al.(2006), Chan and Chan (2004), Haslam et al.(2005), Ortega

(2000), Patrick (2011), Zuo et al. (2007)

Time Ahadzie et al.(2008), Atkinson (1999), Kamrul and Indra (2010), Zuo

et al.(2007)

Quality Ahadzie et al. (2008), Atkinson (1999), Chan and Chan (2004), Love et

al.(2004), Palaneeswaran (2007), Zuo et al. (2007); Takim and

Akintoye (2002)

Site Disputes Chen et al. (2010), David (2010), Medineckiene et al.(2010), Tabish

and Jha (2011), Tan et al. (2011), Tsoulfas and Pappis (2008); Takim

and Akintoye (2002)

Environmental impact Ahadzie et al. (2008), Chan and Chan (2004), Chen et al. (2010),

Gangolells et al. (2011), Lim and Mohamed (2000), Shen (2010), Zuo

et al. (2007)

Community satisfaction/

Client satisfaction/

Participants' satisfaction

Shao and Müller (2011) Ali and Rahmat (2010), CURT (2005), Chan

and Chan (2004), Lim and Mohamed, (1999)

Learning and innovation Blindenbach-Driessen (2006); Leenders et al. (2005) Kratzer et al

(2005); Patanakul and Milosevic (2009); Enshassi et al. (2009)

Impact on the customer,

Direct and business

success.

Shenhar et al., (1997); Poli, Cosic and Lalic (2010)

25

With the above measures of performance as shown in table 2.1, it is possible to

capture all the dimensions of performance of public sector construction projects.

However, these KPIs have been used mostly in isolation as they have managed to

focus on one or just a few dimensions. They have tended to be skewed towards either

economic dimension or social dimension or environmental dimension of public sector

construction projects.

Realization of the above KPIs depends on how project stakeholders have been able to

identify the success factors and accordingly allocate resources on these factors. The

success factors serve as facilitating factors for the success of a project.

2.2.2 Critical Success Factors (CSFs) influencing the success of public sector

construction projects

While identifying the performance indicators of construction projects, researchers

have come up with an innumerable number of items which have great potential to

affect different dimensions of project performance. Evaluating the performance on

this huge number of items is neither feasible, nor advisable. Koushki et al. (2005) and

more recently Ahsan and Gunawan (2010) found that project time and cost

performance get influenced by project characteristics, procurement system, project

team performance, client characteristics, contractor characteristics, design team

characteristics and external conditions. Chan and Kumaraswamy (1997) identified

eight causes of delay in a construction project. Kaliba et al. (2009) mentioned that

poor site management and supervision leads to both time and cost overrun of a

construction project.

As regards the quality of construction projects, research findings have revealed that

design changes, lack of quality systems, contractor selection, ineffective use of

information technology and inter-organizational interactions significantly influence

the quality of construction projects (Alwaer & Clements-Croome, 2010). In addition,

inadequate details in drawings and rigidity in project design (Kaliba et al., 2009;

Alwaer & Clements-Croome, 2010), lack of technical expertise (Kaliba et al., 2009),

and unavailability of right materials or right equipments in the construction site

(Kaliba et al., 2009) also affects its quality. Typically safety performance measure

26

can be evaluated through the number and the rate of fatalities and/or crashes and

incidences, emergency response times. According to Tabish and Jha, (2011), the

factors influencing site dispute performance criterion are thorough understanding and

definition of owners, regular monitoring and feedback by top management, adequate

communication amongst all project participants and the affected parties, availability

of adequate resources and timely decisions by top management. The main factors that

have been identified as impacting negatively on the environment include excessive

use of energy (Saparauskas & Turskis 2006), emissions into the air (Medineckiene et

al., 2010), releases to water, incineration and recycling process and inability to use

renewable materials in construction (Medineckiene et al., 2010) and poor construction

methods (Chen et al., 2010) amongst others.

Based on extensive literature review, Ngacho and Das (2011, 2013b) identified a large

number of variables that influence performance indicators. An extract of a summary

of these variables are presented in table 2.2, where citations are shown in the right

column of the table.

Table 2.2: Success variables and their impact on project success Success Variables KPI/s affected References Project location and Site conditions.

• Time • Cost • Environmenta

l impact • Safety

Abdullah et al. (2009); Blake (2006); Frimpong et al. (2003); Ibnu (2006); Le-Hoai et al. (2008); Long et al. (2004); Omoregie and Radford (2006); Murali and Yau (2007).

Project size and Design Complexity of project (Type, nature and number of floors).

• Cost • Time • Environmenta

l impact • Quality

Alwaer and Clements-Croome (2010); Jha and Iyer (2006); Kaming, et al. (1997); Othman, et al. (2006).

Project managerial actions (planning and control of project activities)

• Cost • Time • Quality • Site disputes

Abdullah et al. (2009); Alwi (2002); Assaf et al. (2006); Ibnu (2006); Long et al. (2004); Murali and Yau, (2007); Yung and Yip (2010).

Communication system among project participants

• Cost • Site disputes • Safety • Time

Abdullah et al. (2009); Abudayyeh et al. (2006); Aksorn and Hadikusumo (2008); Ibnu (2006); Long et al. (2004); Murali and Yau (2007).

Collaboration of project participants

• Quality • Safety • Site disputes • Time

Abudayyeh et al. (2006); Aksorn and Hadikusumo (2008); Al Haadiri and Panuwatwanich (2011); Jha and Iyer (2006); Marosszeky et al. (2002).

Contract modifications. • Site disputes • Cost • Time

Blake (2006); Koushki et al. (2005); Syed et al. (2003).

27

• Safety Quality, health and safety program on the site (Necessary variations)

• Time • Quality • Safety • Cost

Aksorn and Hadikusumo (2008); Al Haadiri and Panuwatwanich (2011).

Budget progress monitoring

• Cost Frimpong et al. (2003); Koushki et al. (2005); Le-Hoai et al. (2008).

Formal organization structure for dispute resolution

• Site disputes • Time.

Assaf et al. (2006); Essam (2006).

Financial capability and payment schedule of the Client.

• Time • Cost • Site disputes

Abudayyeh et al. (2006); Aksorn and Hadikusumo (2008); Frimpong et al. (2003); Koushki et al. (2005); Sweis et al. (2007).

The process of project approvals.

• Time Blake (2006); Marosszeky et al. (2002); Sweis et al. (2007); Syed et al. (2003).

Client’s experience on similar projects.

• Cost • Time • Quality

Abdullah et al. (2009); Ibnu (2006); Koushki et al. (2005); Long et al. (2004); Murali and Yau (2007).

Frequent and erratic changes by the client.

• Time • Site disputes.

Ameh et al. (2010); Azhar et al. (2008); Enshassi et al. (2009); Essam (2006); Ibnu (2006); Le-Hoai et al. (2008); Omoregie and Radford (2006).

Client’s ability to make timely and objective decisions.

• Time • Quality • Site disputes

Abdullah et al. (2009); Enshassi et al. (2009); Frimpong et al. (2003); Ibnu (2006); Long et al. (2004);Syed et al. (2003).

Client's emphasis on quick construction instead of quality

• Quality • Safety • Site disputes

Frimpong et al. (2003); Syed et al. (2003); Yung and Yip (2010).

Client's emphasis on low construction cost

• Quality • Safety • Site disputes

Abdullah et al. (2009); Azhar et al. (2008); Enshassi et al. (2009); Frimpong et al. (2003); Jha and Iyer (2006).

Consultant’s commitment to ensure compliance of construction work according to specification.

• Quality • Site disputes .

Alwi (2002);Syed et al. (2003).

Adequacy of design, specifications and documentations.

• Quality • Site disputes

Abudayyeh et al. (2006); Aksorn and Hadikusumo (2008); Al Haadiri and Panuwatwanich (2011); Alwi (2002); Blake (2006).

Design team experience and technical skills.

• Quality • Time

Abdullah et al. (2009); Blake (2006); Ibnu (2006); Long et al. (2008); Long et al. (2004).

Delay in production of design documents

• Time. Blake (2006); Sweis et al. (2007).

Variations to Original design during construction.

• Time • Cost • Site disputes

Koushki et al. (2005); Syed et al. (2003).

Management skill of Site Managers (in controlling workers and sub-contractors)

• Time • Cost • Quality • Minimum site

disputes

Abdullah et al. (2009); Ameh et al. (2010); Azhar et al. (2008); Enshassi et. al. (2009); Frimpong et al. (2003); Ibnu (2006); Le-Hoai et al. (2008); Long et al. (2004); Murali and Yau (2007); Sweis et al., (2007); Omoregie and Radford (2006).

Contractor’s technical skills and Experience.

• Cost • Time • Quality.

Abdullah et al. (2009); Ameh et al. (2010); Enshassi et al. (2009); Frimpong, et al. (2003); Ibnu, (2006); Long et al. (2004); Murali and Yau, (2007).

28

Size and skills of the labour force

• Cost • Time • Quality

Abdullah et al. (2009); Azhar et al. (2008); Ibnu (2006); Le-Hoai et al. (2008); Murali and Yau (2007); Sweis et al. (2007).

Construction method adopted

• Cost • Site disputes • Safety • Environmenta

l impact.

Abdullah et al. (2009); Alwi (2002); Long, et al. (2004).

Cash flow of the contractor (payments to sub-contractors and workers)

• Time • Cost • Site disputes

Abdullah et al. (2009); Essam (2006); Frimpong et al. (2003); Ibnu, (2006); Le-Hoai et al. (2008); Long et al. (2004); Murali and Yau (2007).

Availability of skilled and experienced workers.

• Time • Cost • Quality.

Abdullah et al. (2009); Azhar et al. (2008); Kaliba et al. (2009); Le-Hoai et al. (2008), Sweis et al. (2007).

Availability of the right material

• Cost • Time • Quality

Azhar et al. (2008); Blake (2006); Frimpong et al. (2003); Ibnu (2006); Kaliba et al. (2009); Le-Hoai et al. (2008); Long et al. (2004); Murali and Yau (2007); Sweis et al. (2007); Omoregie and Radford (2006); Yung and Yip (2010).

Adequacy of working capital

• Time • Cost.

Abdullah et al. (2009); Azhar et al. (2008); Ibnu (2006); Le-Hoai et al. (2008); Long et al. (2004); Murali and Yau (2007).

Availability of suitable equipment.

• Cost • Time • Quality • Safety

Aksorn and Hadikusumo (2008); Al Haadiri and Panuwatwanich, (2011); Frimpong et al. (2003); Ibnu (2006); Kaliba et al. (2009); Long et al. (2008); Murali and Yau, (2007).

Internal procurement challenges

• Time • Cost

Abdullah et al. (2009);Enshassi et al. (2009); Frimpong et al. (2003); Murali and Yau, (2007).

Social and cultural issues of the community.

• Environmental impact

• Time • Site disputes

Ameh et al. (2010); Koushki et al. (2005); Long et al. (2004).

Climatic conditions and ecological environment.

• Cost • Time • Quality • Environmenta

l impact

Jha and Iyer (2006); Koushki et al. (2005); Le-Hoai (2008).

Economic conditions prevailing at the moment (Boom or Meltdown)

• Cost • Time • Quality • Economic

Environment.

Abdullah et al. (2009); Ameh et al. (2010); Azhar et al. (2008); Enshassi et al. (2009); Frimpong et al. (2003); Ibnu (2006); Le-Hoai et al. (2008).

Political conditions and industrial relations.

• Cost • Site disputes. • Safety. • Environment

impact

Blake (2006); Gangolells (2011); Jha and Iyer (2006); Marosszeky et al. (2002); Syed et al. (2003).

Technological sophistication.

• Quality • Cost • Environment

impact

Alwaer and Clements-Croome (2010); Frimpong et al. (2003); Love et al., 2010; Long et al. (2004).

Adapted from Ngacho and Das (2013b)

29

Researchers have attempted to identify the common characteristic features of

construction projects and classified these features into CSFs. While doing so, there

has been, however, no general agreement regarding one uniform grouping of

characteristic features into CSFs (Ameh et al., 2010). The classification has been

based on which factor/s is/are important to its success depending on the type and

nature of projects. Koushki et al. (2005) categorized the CSFs into four groups, viz.

(1) industry and environment related, (2) contractor related, (3) material related and

(4) client’s finance related factors. According to Chan and Tam (2000), there are five

major groups of factors namely (1) project related factors, (2) project procedures, (3)

project management actions, (4) human-related factors and (5) the external

environment. Odeh and Battaineh (2002) classified projects into (1) client related, (2)

procurement related, (3) environment related, (4) consultant related and (5) client

related factors.

The above review reveals that the success factors amongst construction projects are

based on the project itself, the construction stakeholders and the political, social and

economic environment prevailing at the moment as stated by Tiong (1992 cited in

Long et al., 2004). Out of the various CSFs, some are relatively new especially those

revolving around material and equipment supply and also the factor relating to the

environment. These factors point to the need for sustainable construction and is

considered to have significant influence on the success of construction projects

(Ngacho and Das, 2012). There is, however, no consensus on the classification of

factors influencing the success of construction projects. Further, the studies indicate

that these CSFs have not been identified on the basis of specific KPIs of public sector

construction projects.

2.3 Research gaps in literature

The foregoing discussion suggests that the project management literature is replete

with studies pertaining to both KPIs of projects as well as CSFs influencing the

success of the same. However, the following gaps are clearly identifiable from the

literature.

• The identification of KPIs based on economic, social and environmental

dimensions

30

• The identification of CSFs on the basis of KPIs

The influence of CSFs on project success

The association between project success and overall project performance.

The association between overall project performance and performance on

individual KPIs.

The current study is an attempt to fill this gap by conceptualising the relationship as

shown in Figure 2.3

Influences Predicted by

In terms of

Figure 2.3 Relationship between critical success factors and key performance

indicators

In Figure 2.3 several set of CSFs, namely human factors, supply chain related factors,

industry and environmental factors, financial or contractual obligations, project

characteristics as well as management practices and procedures influence the success

of public sector construction projects. Project success is then predicted through

overall project performance which, in turn, is expressed in terms of time, cost, quality,

site disputes, safety, environmental impact, community satisfaction, project

productivity, learning and innovation.

Critical success factors 1. Human Factor

Client related Consultant related Contractor related

2. Supply Chain related Factor

Material Supply factors

Equipment Supply factors

Labour availability 3. Industry and Environmental factor

Social Economic Ecological

4. Financial/Contractual obligation 5. Project characteristics 6. Project management and procedures

Key Performance indicators • Time • Cost • Quality • Site disputes • Safety • Environmental

impact • Community

satisfaction • Project

productivity • Learning and

Innovation

Overall Project Performance

Project success

31

CHAPTER 3: PUBLIC CONSTRUCTION SECTOR IN KENYA AND THE

CONSTITUENCY DEVELOPMENT FUND (CDF): AN OVERVIEW

3.0: Introduction

This chapter provides an overview of Kenya including its geographical location and

important demographic, political and economic features that distinguish Kenya from

other countries. This is followed by a review of public construction sector

emphasizing the previous efforts of the government directed towards the improvement

of this sector. The third section describes the background of Constituency

Development Fund (CDF), the nature of CDF projects and its implementation. The

last section focuses on the performance monitoring practices of CDF construction

projects, in Kenya.

3.1 Facts on Kenya

Kenya is situated in the Eastern part of the African continent between 5 degrees north

and 5 degrees south latitude and between 24 degrees west and 31 degrees east

longitude. It is almost bisected by the equator. The country exercises a significant

socio-economic and political influence in African continent through African Union

(AU), Intergovernmental Authority on Development (IGAD) and East African

Community (EAC). Ethiopia and Sudan border it to the North; Uganda to the West;

Tanzania to the South; Somalia to the northeast; and Indian Ocean to the southeast.

Map 3.1 shows the location of Kenya in Africa and also reveals its neighbouring

countries.

The coastline is about 536 kilometres. The total land area is about 582,650 square km

of which 569,250 square km constitutes dry land while water takes the rest of about

13,400 square km. Approximately, 80% of the land area is arid or semi-arid and the

remaining 20% is arable consisting of high to medium potential agricultural land. The

country has diverse physical features, which are a major source of tourist attraction.

These include vast plains which are home to world famous game parks and reserves;

the Great Rift Valley, which runs north to south and whose floor has provided

potential for geothermal power generation; Mount Kenya, the second highest

mountain in Africa at about 5,199m above sea level; Lake Victoria, the largest

freshwater lake on the continent supporting a major fishing industry in the East Africa

32

region; Lake Nakuru, a major tourist attraction because of its flamingos; Lake

Magadi, famous for its soda ash; and a number of major rivers, including Sondu-

Miriu, Tana and Athi, which generate the hydropower resources of the country

Map 3.1: Map of Africa showing location of Kenya.

Currently, according to the 2009 housing and population census (KNBS, 2010), the

country’s population is about 40 million people, 75-80% of whom live in the rural

areas. The population distribution varies from 240 persons per square km in high

potential areas to 4 persons per square km in arid areas. 20% of arable land supports

80% of the population. The remaining 20% of the population lives in 80% of arid and

semi-arid land. Kenya is faced with a high dependency burden, with over 50% of the

33

population below 15 years of age. This has resulted in high dependence ratios placing

excessive demands on social services such as primary education and health care.

However, the inter-censual population growth rate declined from 3.9% per annum

during 1969-79 to 2.9% during 1989-99. The country’s population is characterized by

high infant mortality and death rates, low and declining life expectancy, slightly

increased fertility rates (from 4.7 children per woman in 1995-1998 to 4.8 in 2000-

2003, then 4.9 in 2007-2010), and declining population growth rates (which could be

attributed to the HIV/AIDS pandemic). All these reflect the enormous challenges

faced by Kenyan government in achieving some level of Development. The

population remaining in absolute poverty was estimated to be 44.7% in 1992, 52% in

1997, 56% by 2002 and 58% in 2009. The National Revenue is mainly derived from

tourism and taxation and supplemented by donations and grants by Kenya’s

Development partners. Kenya, specifically Nairobi, still functions as the hub of East

Africa.

.

Map 3.2: Map of Kenya showing Administrative (provinces) units

Western Province

34

For administration purposes, the country is divided into eight provinces, namely

Central (1 ), Coast (2), Eastern (5), Nairobi (4), North Eastern (3), Nyanza (6), Rift

Valley (7) and Western (8) (as shown in Map 3.2). The numbers mentioned in

brackets adjacent to each province indicate the location of the said province as

indicated in the map.

Map 3.2 shows these 8 administrative units, referred to as provinces. Rift valley (7) is

the largest in size, followed North Eastern (3), Eastern (5), Coast (2), Nyanza (6),

Western (8), Central (1) and Nairobi (4) is the smallest in size as shown.

Map 3.2 further shows that the Western province is situated in the western part of

Kenya. It has a total area of 8361square km and a population of 5.4 million (according

to 2009 Housing and population census). The new constitution has split the country

into a total of 47 counties each to be headed by a governor at the county level and

represented by a senator at the national level. Western province has 4 counties namely

Kakamega, Vihiga, Bungoma and Busia as revealed in the left side of map 3.2.

Further, these counties are divided into a total of 24 constituencies. The country has

two legislative houses: a national assembly with 290 elected and 12 nominated

Members of Parliament (MPs) as well as 47 county women representatives and senate

with 47 elected senators and 6 nominated senators.

The Gross Domestic Product (GDP) in Kenya was worth 33.62 billion US dollars in

2011. The GDP value of Kenya is about 0.05 percent of the world economy.

Historically, from 1960 until 2011, Kenya GDP averaged 9.49 USD Billion reaching

an all time high of 33.62 USD Billion in December of 2011 and a record low of 0.90

USD Billion in December of 1962. According to Economic outlook (2012), the

economy experienced moderate growth of 4.4% in 2011 and 4.2% in 2012 and is

expected to reach 4.5% in 2013 and 5.2% in 2014.The main sectors that drive the

economy of Kenya include agriculture, manufacturing, tourism, building and

construction, transport and financial intermediation. In 2011, the Kenya’s economy

was majorly driven by financial intermediation, tourism, agriculture and building and

construction (African Economic Outlook, 2012). The building and construction sector

has, however, played a key role in the economic growth in Kenya over the past five

years. The African Economic Outlook (2012) attributes this to the increased bank

35

credit to the private sector for real estate development and the intense investment in

infrastructure projects being undertaken by the government all over the country.

3.2 Construction sector in Kenya: Early government initiatives

The construction sector in Kenya is very important for the Kenyan economy because

it contributes close to 5 per cent of the country’s gross domestic product (GDP) and

employing more than one million people. According to report by Kenya National

Bureau of Statistics (KNBS), the economy of Kenya grew by 4.9 per cent in the first

quarter of 2011 due to the improved productivity in the construction industry. This

can be attributed to higher public investment in infrastructure by the Government of

Kenya (African Economic Outlook, 2012).

Kenya has engaged in deliberate effort to improve the construction sector since

attaining her independence in 1963. In 1967, through an Act of Parliament, the

Kenyan government set up a National Construction Corporation (NCC) to train

African contractors in construction business management. The main function of NCC

was to “promote, assist, and develop the construction industry” (Republic of Kenya,

NCC Act 1972). It also operated as an architectural and engineering firm and it can

own and manage either a management institute or a technical college, operate

manufacturing business and own construction equipment for commercial use.

Furthermore, the NCC Act permitted the corporation to have a say in the design of the

syllabi at institutions that train personnel for the construction industry. This

corporation, however, lasted for only 25 years as it was disbanded in 1992 mainly for

having failed to indigenize the construction industry.

Currently, the government’s policy guidelines for various sectors in the economy are

contained in the development plans published by the Ministry of Economic Planning

every five years. Those on the construction industry can be divided into two direct

and indirect interventions. Under indirect intervention, the government imposed a

training levy and set up a craft training centre for training of employees in the

construction industry. The direct intervention policy involves setting aside some

categories of work for African-owned businesses.The construction industry in Kenya

is expected to see tremendous growth as a result of government spending on major

infrastructure projects around the country.

36

Public sector construction projects in Kenya, prior to 2003 were identified, planned

and implemented by the government line ministries or their implementing agencies in

state corporations. In most cases these projects were influenced by partisan politics

thus falling short of expectations. It is due to this that the government thought of

decentralizing public sector construction projects in an effort to realize equitable

development in all regions. Among the decentralization programmes formulated were

District Development Grant Program (1966), the Special Rural Development Program

(1969/1970), District Development Planning (1971), the District Focus for Rural

Development (1983 -84) and the Rural Trade and Production Centre (1988-89).

Though these programmes’ aim was to attain development in all parts of the country,

they failed due to the problem of funding. It is against this background that in 2003

the Constituency Development Fund (CDF) was created through an act of parliament

with the aim of ensuring balanced regional development by providing funds to

parliamentary jurisdictions (constituencies) to fight poverty.

3.3 Constituency Development Fund (CDF) in Kenya

The Constituency Development Fund (CDF) was established through an act of

parliament, CDF Act (2003), for the purpose of devolving national resources to

achieve rapid socio-economic development at constituency level through financing of

locally prioritized projects and enhanced community participation (Mapesa &Kibua,

2006). According to the CDF Act (2003) the Government should allocate at least

2.5% of the ordinary revenue collected to CDF (Wanjiru, 2008). However, this

amount has been increasing consistently and currently stands at around 4%,

translating to an average of Ksh. 50 million (1 USD=Ksh.85), for each of the 210

constituencies in Kenya per year (Baskin, 2010). According to the CDF Act (2003),

the stakeholders included in the management of the fund include the public and

community groups, CDF management agencies, existing government institutions, and

Member of Parliament for each constituency.

Under CDF Act (2003), funding is usually done for a completely new project or for

renovation of an existing facility and could also include acquisition of land. Further

the project must be development oriented and not recurrent, community based and

must suitably be defined and auditable (Mapesa & Kibua, 2006). CDF projects like

37

other community development projects (Ika et al., 2012), are based on five main

pillars: relevance, efficiency, effectiveness, impact and sustainability. This implies

that the projects must be suitable for the needs of the community and should use less

costly resources within the community. At their completion, they should meet the

desired objectives so as to lead to a change within the community. Further, the

benefits of the project to the community should be sustained even after the funding is

discontinued. The target projects include Educational facilities (32%), Health Care

facilities (26%), Water and Physical Infrastructure including Light Industries (27%)

and Agriculture, Security, Social Services and Wildlife (15%), (Baskin, 2010).

Figure 3.1: Management structure of CDF construction projects (Adapted from

Barasa, 2010)

The Educational projects aim at upgrading several primary schools, secondary schools

and youth polytechnics as a way of infrastructural improvement to facilitate proper

learning in these institutions. The public health and sanitation projects focus on

setting up of new primary Healthcare units, upgrading of the existing facilities and

proper management of these units. In the Agricultural sector, the aim is to support the

commercialization of agricultural produce by providing the farmers access to

Constituencies Development Fund Board – Responsible for national administration and coordination of CDF

Constituencies Development Fund Committee (CDFC) – Manage CDF in the constituency

Project Management Committee (PMC) – Manage and oversee an individual CDF

District Projects Committee (DPC) – Responsible for coordination and harmonization at district level

Constituencies Fund Committee (CFC) – Parliamentary Committee which gives policy direction on implementation of CDF

38

wholesale and fresh produce markets and increasing efficiency in marketing and trade

of agricultural produce. Through industrialization, the government aims at

constructing and equipping “jua kali” shades (light industries) to facilitate

participation of youth as artisans and entrepreneurs.

Recently the Government has embarked on the projects aimed at meeting the

Millennium Development Goals (MDGs). More precisely, in the year 2007-2008,

budgetary allocations of more than Ksh 58 Billion went to devolved structures. One of

the devolved funds earmarked under this period was Constituency Development

Fund.

The CDF projects involve the participation of different stakeholders at different stages

starting from project identification to eventual implementation and monitoring

(Wanjiru, 2008).

3.3.1 Identification and selection of CDF projects

The representatives of the community identify a set of candidate projects depending

on the level of development of their locations and their preference for particular kind

of projects. These projects are then scrutinized to find out their feasibility and

suitability and are forwarded to the district level for the purpose of harmonization

with other projects selected from other locations.

As stated earlier, CDF is directed towards those projects thought to be beneficial to

the community at large. These projects include those that are Educational in nature,

address health needs of the community, provide a market for agricultural produce,

ensure adequate provision of water, provision of employment through

industrialization and also those projects that build roads and bridges. From the

communities’ perspective, these projects can be broadly classified into four main

categories: the Educational, Health, Agricultural and Industrial Estates.

a) Educational: In Educational Sector, the construction activities that are funded

by CDF include construction of classrooms, laboratories, workshops, teachers’

houses and dormitories. The expansion / renovation of schools and

construction of new ones has led to ease of congestion especially in primary

39

schools brought by the introduction of free primary and secondary education

by the government of Kenya.

b) Health Care: In the Health sector, CDF funds expansion / construction of

physical facilities like hospitals, health centres, dispensaries and maternities.

This has promoted the quality and accessibility of health care services to all

beneficiaries.

c) Agricultural Markets: There has been very little construction in Agriculture

sector but in recent times, CDF is funding construction of fresh produce

markets to enable small scale horticultural farmers to market their produce.

Part of the fund has been spent in areas like the improvement of livestock

sector through rehabilitation / construction of cattle dips.

d) Industrial Estates: CDF does not fund major facilities but during 2009/2010

financial year, in conjunction with ministry of industrialization, CDF started

putting up Industrial Estates to boost the informal sector, popularly referred to

as jua kali (hot sun).

Other construction works undertaken by CDF include opening up of feeder roads,

improvement of existing roads and construction of culverts and minor bridges,

provision of safe water and provision of bursary to the needy students. All these,

however, support the above four categories of projects. After the 2007 Amendments,

the Constituency Development Fund Committee (CDFC) can now acquire land and

buildings, although all assets remain the property of the CDF Board. CDF does not

fund private enterprises, merry-go-rounds, religious and political organisations and

activities, and recurrent costs.

3.3.2 CDF project procurement approaches

Project procurement has been described as an organized method or process and

procedure for clients to obtain or acquire construction products (Rashid et al., 2006).

The kind of procurement method used in securing a project is vital to the success of a

given construction project. In considering the procurement method to adopt, the

organization ought to have a clear understanding of project objectives and constraints,

define the roles of the various contracting parties and consider the fair allocation of

40

risks and obligations between the contracting parties. Specifically, while deciding

upon a project delivery approach, Tyson Building Corporation (2005) recommends

that one should consider:

• length of time you have to build your facility;

• the complexity of what you are building;

• does it comply with state procurement statutes

• available time and expertise of your in-house staff;

• the budget constraints;

• how much risk you are willing to assume in the building process

Rashid et al. (2006) discussed about different project procurement systems and the

effect of the different procurement systems on project performance. The common

project procurement methods are discussed below.

Design/Bid/Build: In this procurement approach, the client divides the award of

contract between two entities namely consultant and the contractor. The consultant

undertakes the design of the project while the contractor is responsible for

construction of the same. The consultant and contractor in turn, respectively engage

engineers and sub-contractors for execution of their work. Figure 3.2 shows this

procurement approach.

Figure 3.2: Design/Bid/Build project procurement approach

In this arrangement, it is the responsibility of the selected contractor to build the

facility according to the specification. In such an arrangement, the client exercises

Client

Consultant (Architect)

Engineer

Contractor (Builder)

Sub-contractor

41

more control over the project because of his authority to select the consultant and

contractor. This approach clearly outlines the responsibility of each party on the

project and hence makes it a fairly popular approach among CDF funded projects.

Design/Build: This is a project procurement method in which the client awards

contract to a single entity for both design and construction process. On the basis of

specific requirements of the client, the selected contractor undertakes the preparation

of blue print of the project including its design documents and actual construction of

the same. Diagrammatically, this can be shown as in Figure 3.3.

Figure 3.3: Design/Build project procurement approach

This approach has been favoured on the basis of ensuring early contractor

involvement in the project that is thought to improve constructability (Tyson Building

Corporation, 2005).

Competitive bid: In this project procurement method, different entities are hired for

the design and construction process. The unique feature of this procurement approach

is that the consultant is given the task to assist the client and represent the client’s best

interest, from design through occupancy by providing unbiased service to the client.

The consultant is involved in the day to day construction process of the project in

order to ensure that the project is constructed according to the specifications.

Whenever any dispute arises between the owner and the contractor, the architect

(consultant) operates as a third party to offer professional advice (Hill, 1986). This

approach has gained popularity with CDF funded projects because it is relatively easy

Client

Contractor-Designer and Builder

Sub- Contractors

42

to implement and also provides cushion to clients who are otherwise not professionals

in project construction.

Negotiated General Contract: Under this approach, a single prime contractor is

entrusted with the responsibility of undertaking the entire work. The contractor is

accountable for the activities taking place on the project. This approach creates

common project goals and objectives and acts as a single point of responsibility that

enhances project communications. The approach relies heavily on trust, experience

and quality. This delivery method significantly reduces construction problems and

poor workmanship. To protect the owner, it also provides quality services with checks

and balances.

Build–Own–Operate–Transfer (BOOT): This project procurement approach is not

very common amongst CDF funded projects because it is relatively new. In this

method, developers use their own resources to construct a public facility, operate it

for an agreed upon period while charging a fee and eventually transfer it to the

government or its agencies. This approach is used for relatively large Public sector

construction projects that can only be constructed through consortium. The

government or the relevant agencies, however, have to bear some financial and

viability risk.

Turnkey contract: Rashid et al. (2006) explain that in this procurement approach, the

contractor is commissioned to undertake the responsibilities for everything necessary

for construction, completion, commissioning and hand over of the project. Turnkey

implies that on project completion, the contractor hands over the key to the client for

successful operationalisation of the project.

3.3.3 Implementation of CDF projects

Once funds for a project are approved, tendering has been done and the

contractors/consultants have been identified, the next stage includes the

implementation of the project including making purchases, giving out payments,

keeping records, overseeing the construction work to ensure that it is done according

to specification, and eventually handing over the completed project to the community

or to the relevant government department. All CDF funded projects are managed by

project management committees (PMCs), consisting of members who manage the

43

projects on behalf of the community. These PMCs are recognised as public entities

and are subjected to various government financial regulations. CDF funded projects

are implemented by four parties.

• Clients (PMCs)

• Consultants (Architect/Designer)

• Contractor

• Community

Clients (PMCs): A client could be an individual or a group of individuals or an

organization that owns the project. They define project requirements, functions and

services the project is expected to deliver and are responsible for provision of project

funds. A client can also participate in day to day construction project by actively

employing a construction manager. In the present study, clients are the various project

management committees (PMCs) who represent the community during construction

process.

Consultants (Architect/Designer): These are firms or individuals licensed by the

state to practice architecture. They may also possess a background on structural

engineering and may be hired by the client to design the project. They sometimes

monitor the construction of the project in order to assure that construction is being

undertaken according to plans and specifications prepared by the architect and

approved by owner and contractor. With regard to CDF projects, the consultants

include an official of the Ministry of Public Works and the line ministry responsible

for implementation of all government projects.

Contractor: This is the entity that directly interfaces with the client in order to

execute certain projects according to the prescribed specifications. They create the

facility based on project plans, specifications and contract documents and manage

different resources during the entire period of project construction.

Community: Community is said to be a social group of any size whose members

reside in a specific location, share public facilities and often have common cultural

and historical heritage. This is a group comprising every “mwanainchi” (a common

person) within the locality in which the projects are constructed. In the context of

public sector construction projects, a community refers to individuals or groups of

44

project beneficiaries residing in a particular area where the project has been

constructed.

3.4 Existing practices of monitoring the performance of CDF construction

projects

Once project construction is complete, they are transferred to the respective line

ministries which manage the projects on behalf of the government. The line ministries

provide necessary staff and ensure maintenance of the facilities through a cost sharing

policy in which the costs are borne by government and the community. Monitoring

and evaluation of completed projects is undertaken by the CDF monitoring Unit, the

National management Board, District Development Officer (DDO), relevant

government line ministries, and other national agencies like the National Taxpayers

Association (NTA). Wanjiru (2008) reports that at present, the monitoring systems

instituted under the CDF Act (2003) are not thorough enough to evaluate performance

of the projects as it only entails “visits to the project site and a verbal report on the

project, which gives a very superficial picture.”

In fact, the Social Audit Guide booklet (Wanjiru, 2008) noted that CDF

implementation has encountered a number of operational and policy challenges which

include:

• Low utilization of completed facilities especially Educational and health

institutions due to lack of collaboration with line ministries especially on staff

requirement.

• Poor community participation and contribution to projects.

• Weak capacity to identify viable projects.

• Low technical capacity to implement public sector projects.

• Non-adherence to laid down government procedures, rules and regulations,

such as those governing public procurement.

• Poor management of transition during elections.

• Low utilization of technical officers in the implementation of projects.

• Too many small projects thinly spread with little impact.

45

Performance of public sector construction projects implemented by CDF is a matter of

public interest and the government of Kenya as it requires huge capital investment

such that poor management of the process lead to huge financial loss (Kimenyi,

2005). Different stakeholders have criticised the manner in which CDF projects are

conceptualised, managed and implemented. This has necessitated various studies at

both national and international levels mainly focusing on composition of CDF

committees, the role of CDF in poverty reduction (through provision of employment

and wealth creation), participation of women in CDF activities, distribution of CDF

projects in the constituency and the overall manner in which CDF funds are

distributed, managed and accounted for. The local organizations in Kenya that have

undertaken studies in this area include; Women Political Alliance-Kenya (WPA-K),

Institute for Policy Analysis and Research (IPAR), Kenya Institute of Public Research

and Analysis (KIPRA), Institute of Economic Affairs (IEA), University of Nairobi

(UoN), Parliamentary Select Committee on CDF and the mainstream media group.

The international community has also shown interest through organizations such as

Society for International Development (SID), European Union (EU), World Bank

(WB) and Abantu for Development.

Based on these studies, relevant watchdog organizations including the National

Taxpayers Association (NTA) and the CDF monitoring unit have been able to classify

constituencies as either good performers or poor performers as far as implementation

of CDF funded projects is concerned. Good performing constituencies have witnessed

significant improvement in people’s lives whereas in poor performers, the

constituents have suffered despite the availability of fund. This has led to the freezing

of fund accounts by the National Management Committee on CDF.

A few other researchers have raised concern on the way fund is run and the projects

implemented. Kimani, Nekesa and Ndung’u (2009) examined CDF processes and

structures as well as community participation in administration and monitoring of

CDF construction projects in order to determine why some constituencies have been

termed as good constituencies while others have been termed as bad. They found that

there are some practices that good constituencies undertake but the same are not

visible in the bad constituencies. The best practices include proper targeting of

46

projects to marginalised communities, transparency in the project tendering process

and involving the communities in identification and prioritization of projects.

Similarly, Romero (2009) reported that there have been concerns that participation of

residents in decision making has been limited and that the fund lacks transparency.

They proposed that voters should use information about the quality of the services

they receive from the facilities constructed in their areas when making voting

decisions. This would ensure that decentralization efforts have a positive impact on

poverty and make members of parliament (MPs) accountable to the people. Further,

Awiti (2008) sought to find out whether CDF has contributed to the efficiency in

resources use or has been hijacked by the politicians for their selfish gains. The

findings show that the lack of strong institutionalisation of CDF has facilitated the

process of wealth accumulation by the MPs through corruption and creation of a

platform for the fund patronage.

These studies reveal the need for further studies on the performance of CDF projects,

especially now that it is ten years since CDF was initiated. These studies will show

the impact that CDF has had on the communities whose projects have been

constructed in the past. The current study is likely to come up with recommendations

that can be implemented in order to strengthen the management of the fund and the

projects undertaken. This will ensure that the very objectives of decentralisation are

achieved.

47

CHAPTER 4: RESEARCH METHODOLOGY (PHASE I): EXPLORATORY

STUDY

4.0 Introduction

This chapter discusses the research methodology followed in phase I which involves

the identification of KPIs and CSFs through exploratory studies. It first enumerates

the key issues of Phase I study and describes the process followed in Research

Methodology. This encompasses the research instrument, reliability of the survey

instrument, study site, and identification of target population, selection of field

investigators and data collection.

4.1 Key Issues

The exploratory phase of the study seeks to address the following issues

Examine the characteristics of the projects surveyed in the current study in

terms of their types and procurement approaches used.

Examine the profile of respondents (client, consultant and contractor) involved

in the construction of CDF projects in terms of their experience on similar

projects and the value of the projects they had worked on in the past.

Examine the status of the projects surveyed in terms of the occurrence of cost

overrun, time overrun and quality defects.

Identify the appropriate KPIs for performance measurement of public sector

construction projects.

Identify the CSFs based on KPIs that influence the success of public sector

construction projects.

4.2 Process followed in Research Methodology (Phase I)

The study commenced with an extensive literature review in order to gain an

understanding of the domain of project performance and project success. This formed

a basis of developing performance measurement variables and project success

variables. The insights from experts comprising academicians and practitioners were

then sought through in order to conceptualise performance measurement of public

sector construction projects. This was followed by the design of a preliminary

48

questionnaire. The questionnaire was presented to the same experts and a pilot survey

amongst a few representative respondents was conducted. The questionnaire was

refined based on the feedback of the pilot survey and finally administered to clients,

consultants and contractors involved in the construction of CDF projects in order to

collect relevant data for the study. Gain an understanding of the

meaning and domain of project performance and project success.

Discuss the concept of project performance and project success with experts and academicians in order to conceptualise the project performance measurement.

Design a preliminary questionnaire based on literature review and viewpoints of experts. Present the questionnaire to the same experts for their comments and revise it appropriately.

Conduct a pilot survey on a few selected respondents and make appropriate adjustments to the scale.

Select field investigators and administer the revised questionnaire to a larger group of project stakeholders (Survey I)

Conduct Exploratory Factor Analysis to come up with a scale of multiple items for assessing performance of construction projects.

Figure 4.1: Sequence of research followed in Study Phase I.

The data collected pertains to demographic characteristics of the projects and

respondent’s profile, performance measurement variables and project success

variables. Data analysis was undertaken using descriptive statistics at the preliminary

PHASE I:

EXPLORATORY

STUDY

Literature Review

Insights from Experts

Design of survey instrument

Pilot survey

Data Collection I

Refinement of the survey instrument

Expected Outcome

A multiple-item measurement scale for - Performance measurement variables of

construction projects

-Variables influencing project success

49

stage to provide insights and more detailed analysis was done using Exploratory

Factor Analysis (EFA). Both SPSS and AMOS software were employed to aid the

analysis. The result of EFA forms the basis of identifying performance measurement

variables and project success variables amongst public sector construction projects.

Figure 4.1 depicts the overall research sequence adopted by this study.

4.3 Design of Survey Instrument

The information gathered through literature review provided background information

on evaluation of public sector construction projects. A list of performance

measurement variables and success variables relevant to CDF construction projects

was derived from literature and shown to 5 experts comprising 2 professors in the area

of project planning, 2 practitioners and 1 consultant in order to secure their viewpoints

regarding the suitability of the same in performance measurement of Public sector

construction projects in developing countries. Both the professors possess more than

10 years of teaching and consulting experience for many government projects. Due to

their rich experience, they were thought to be familiar with economic, socio-cultural

and political environment surrounding various projects earmarked for this study. The

two practitioners were chairmen of Kenya association of contractors, Busia and

Kakamega counties, Western Kenya. The choice of these practicing managers was

based on their rich experience with construction projects in their respective regions.

The fifth expert, a regional public works officer in charge of the Busia County since

2003, is responsible for all CDF construction projects funded by the Government in

Busia County. The experts confirmed that the measurement items identified were

relevant to CDF construction projects in Kenya.

The literature review coupled with the feedback received from the experts on the

performance measurement items enabled the researcher to design a structured

questionnaire for the purpose of assessing the performance of CDF construction

projects. Questionnaire was divided into three sections, each section addressing

covering a different aspect of performance evaluation among CDF construction

projects. The first section covers the demographic characteristics while the second and

third section deal with the variables relating to project performance and project

success respectively.

50

Section A: Demographic characteristics of projects and respondents’ profile

This section of the questionnaire contains questions relating to the demographic

profile of the respondents (i.e. whether they acted as clients, consultants or

contractors), their experience associated with construction projects in general and

CDF construction projects in particular and the type of CDF projects they are

currently involved in. Further this section seeks information on the procurement

approaches followed in the current projects, the budgeted and actual construction cost

of the project, the scheduled and actual duration of the project and the variations

introduced on the project during construction.

Section B: Variables relating to project performance measurement

The second section contains questions pertaining to the perception of the respondents

on their level of agreement on various statements representing different aspects of

project performance. A total of 35 performance indicator variables were identified. A

five-point Likert scale was used as a response format for different variables with the

assigned values ranging from 1 = Strongly Disagree to 5 = strongly Agree.

Section C: Variables relating to project success

This section contains questions relating to those facilitating factors that lead to project

success. A total of 30 success variables were identified. To obtain responses on these

30 variables, a five-point Likert scale was used as a response format for different

variables with the values ranging from 1 = Strongly Disagree to 5 = strongly Agree.

The respondents were required to indicate their perception on the success variables.

The purpose of sections B and C of the questionnaire was to secure opinions of the

respondents on 35 performance measurement variables and 30 success variables

respectively with reference to a specific project they had been involved in. The

questionnaire was presented to the same experts once again with a view to seeking

their expert opinion on the adequate and appropriate coverage of all the items

affecting the performance of construction projects and also the user-friendliness and

overall workability of the questionnaire. They stated that some of the questions need

to be rephrased for ease of understanding, given the varying level of education of the

prospective respondents. The entire exercise ultimately helped the researcher in

achieving the content validity of the questionnaire. With the help of language experts,

51

the questionnaire was also translated into local (Swahili) language for those

respondents, who cannot properly understand English language.

4.4 Reliability of the Survey Instrument

In order to find out the reliability of the survey instrument, a pilot survey was carried

out amongst 5 contractors (including 2 sub-contractors), 4 consultants and 21 clients,

who were working on ongoing construction projects. The sample used in this survey

was drawn primarily from a database of contractors, consultants and clients

maintained by the CDF regional office in Western Province. These respondents were

found to have over 7 years of experience in the construction industry and had been

involved in the construction of CDF projects for at least 3 years. Further, they had

handled over 4 CDF projects per year in various constituencies previously. This bears

testimony to the fact that these respondents were quite experienced in providing

relevant information requested in the questionnaire.

4.4.1 Validity and Reliability of project performance measurement variables

In the first stage, the distribution of responses of each measurement item amongst 30

respondents was checked through minimum score, maximum score, mean and

standard deviation of scores. Table 4.1 summarises these scores.

The minimum and maximum values of the above variables were found to be 1 and 5

respectively for 33 out of 35 variables, which indicates that in general, the

respondents used the entire 5 point survey scale. The mean score ranged between 2.25

(Fatalities did occur –PV22) and 4.03 (Proper medical facilities provided –PV35).

The standard deviations were all found to be greater than 1 except in two variables

namely “All stakeholders supervised project quality” and “Proper medical facilities

provided”. Despite their low standard deviations, these variables were not deleted

because of their theoretical significance in the measurement of construction project

performance.

52

Table 4.1: Descriptive statistics of performance measurement variables obtained through pilot survey

Performance Indicator variables (PV) Mini mum

Maxi mum

Mean Std. Dev.

PV1: No increase in materials cost 1 5 2.93 1.461 PV2: Labour costs remained stable 1 5 2.97 1.217 PV3: Minimum variations in cost. 1 5 2.73 1.258 PV4: Equipments purchased at pre budgeted rates. 1 5 2.93 1.285 PV5: Resources matched budget. 1 5 3.40 1.329 PV6: No incidences of frauds 1 5 3.23 1.431 PV7: No incidences of trade union agitation 1 5 2.90 1.348 PV8: No serious dispute due to specifications 1 5 2.93 1.258 PV9: Disputes due to frequent changes 1 5 2.77 1.165 PV10: Dispute resolution meetings were held regularly 1 5 3.07 1.285 PV11: No financial claims at completion 1 5 3.17 1.392 PV12: Adverse effect on quality of groundwater level 1 5 3.33 1.213 PV13: Timely delivery of resources 1 5 3.07 1.363 PV14: A clear plan was formulated 1 5 3.07 1.258 PV15: No design changes 1 5 3.00 1.114 PV16: Harmonious relationship on site 1 5 3.00 1.259 PV17: Project has led to air pollution 1 5 2.77 1.331 PV18: Project has led to depletion natural resources 1 5 3.00 1.313 PV19: Project has led to increased solid waste 1 5 3.10 1.094 PV20: Accidents were reported 1 5 2.57 1.194 PV21: Near misses occurred 1 5 3.13 1.306 PV22: Fatalities did occur 1 5 2.30 1.489 PV23: Utilised environmentally friendly technology. 1 5 2.40 1.133 PV24: Led to the increased release of toxic materials 1 5 2.93 1.461 PV25: No delays in securing funds. 1 5 3.43 1.165 PV26: At handover there were no apparent defects 1 5 3.33 1.269 PV27: Contractors were often called back to repair defects. 1 5 3.27 1.143 PV28: No effect of weather and climatic conditions. 1 5 3.43 1.165 PV29: Utilised reusable and recyclable materials. 1 5 3.30 1.343 PV30: Right material was used for the construction work. 1 5 3.40 1.453 PV31: Employees possessed requisite skills. 1 5 2.87 1.279 PV32: A sound QMS was adhered to. 1 5 3.10 1.242 PV33: Workers were trained on positive attitudes 1 5 3.47 1.196 PV34: All stakeholders supervised project quality. 2 5 3.97 .964 PV35: Proper medical facilities were provided 2 5 4.03 .964

53

In the next stage, scale reliability (internal consistency) was inspected using

Cronbach’s coefficient alpha as shown in table 4.2.

Table 4.2: Item-to-total correlations of performance measurement variables obtained through pilot survey Performance Indicator variables (PV) Corrected

Item-to-total correlation

Cronbach's Alpha if item deleted

PV1: No increase in materials cost .469 .732 PV2: Labour costs remained stable .361 .739 PV3: Minimum variations in cost. .469 .734 PV4: Equipments purchased at pre budgeted rates. .455 .734 PV5: Resources matched budget. .275 .744 PV6: No incidences of frauds .473 .732 PV7: No incidences of trade union agitation .224 .746 PV8: No serious dispute due to specifications .090 .753 PV9: Disputes due to frequent changes -.107 .761 PV10: Dispute resolution meetings were held regularly .168 .749 PV11: No financial claims at completion .386 .737 PV12: Adverse effect on quality of groundwater level .245 .745 PV13: Timely delivery of resources .402 .736 PV14: A clear plan was formulated .399 .737 PV15: No design changes .363 .740 PV16: Harmonious relationship on site .184 .748 PV17: Project has led to air pollution .176 .749 PV18: Project has led to depletion natural resources .074 .754 PV19: Project has led to increased solid waste -.039 .757 PV20: Accidents were reported .092 .752 PV21: Near misses occurred .054 .755 PV22: Fatalities did occur .319 .741 PV23: Utilised environmentally friendly technology. .311 .742 PV24: Led to the increased release of toxic materials .157 .750 PV25: No delays in securing funds. .201 .747 PV26: At handover there were no apparent defects .252 .745 PV27: Contractors were often called back to repair defects. .183 .748 PV28: No effect of weather and climatic conditions. .248 .745 PV29: Utilised reusable and recyclable materials. .329 .741 PV30: Right material was used for the construction work. .160 .750 PV31: Employees possessed requisite skills. .382 .738 PV32: A sound QMS was adhered to. .346 .740

54

PV33: Workers were trained on positive attitudes .482 .734 PV34: All stakeholders supervised project quality. .056 .753 PV35: Proper medical facilities were provided -.279 .765

A scale is said to be reliable, if Cronbach’s coefficient alpha of the scale is well above

the threshold value of 0.700 and the acceptable minimum of 0.600 (Hair et al., 2006).

In this study, the Cronbach’s coefficient alpha for the entire scale consisting of 35

measurement variables was 0.751 with relatively high corrected item-to-total

correlations indicating the presence of high internal consistency in the measurement

scale.

Investigation of individual variables shows that deletion of 8 variables, PV8 (0.753),

PV9 (0.761), PV18 (0.754), PV19 (0.757), PV20 (0.752), PV21 (0.755), PV34

(0.753) and PV35 (0.765) would slightly improve the value of Cronbach’s alpha as

indicated in the brackets of the above variables. Firstly, the improvement achieved

through the deletion of the above variables as mentioned in the brackets was marginal.

Secondly, the inclusion of the above three variables does maintain the Cronbach’s

alpha coefficient at 0.751, which is well above 0.7 threshold value. Finally, this being

a pilot study and the variables being important in theoretical sense, the same might

improve the measurement of construction project performance at a later stage.

4.4.2 Validity and Reliability of variables influencing project success

Validity of the 30 variables that influence project success was assessed through

minimum and maximum scores of each item and also the scores for means and

standard deviations. Table 4.3 shows the summary of these scores.

Table 4.3 shows that the means of 27 out of the 30 variables had minimum and

maximum scores ranging from 1 to 5. This implies that these items utilised the entire

scale. As regards standard deviations of two variables (SV16 and SV30) secured

scores less than 1. However, these two items were still included in the scale because

of their theoretical importance in determining success of construction projects. All

mean scores were found to be above 2.50 the mid value, which indicate that the

variables are important.

55

Table 4.3: Descriptive statistics of project success variables obtained through

pilot survey

Variables of factors influencing project success Min Max Mean Std. Dev

SV1: Effect of location and Site conditions 1 5 3.30 1.418 SV2: Influence of Design Complexity 1 5 2.80 1.215 SV3: Adequate Project planning and, Scheduling 1 5 3.27 1.202 SV4: Project funds secured on time 1 5 2.80 1.424 SV5: Design documents approved on time 1 5 3.10 1.423 SV6: Adequate experience on similar projects 1 5 2.73 1.437 SV7: Adequate Information sharing and collaboration 1 5 2.70 1.442 SV8: Adherence to the requisite Quality standards 1 5 2.60 1.429 SV9: Continuous monitoring of actual expenditures 1 5 3.30 1.236 SV10: Formal dispute resolution structures 1 5 2.83 1.315 SV11: Site Managers possessed requisite skills 1 5 3.07 1.437 SV12: Contractor had adequate technical skills 1 5 3.17 1.262 SV13: Contractor used latest construction methods 1 5 3.03 1.520 SV14: Community had no issues against the project 1 5 3.50 1.280 SV15: Adversely affected by the surrounding weather 2 5 3.40 1.003 SV16: Effect of Macro- economic conditions 2 5 3.43 .858 SV17: Effect of the Governance policy 1 5 3.17 1.315 SV18: Adequate commitment of the consultant to project 1 5 2.87 1.224 SV19: Adequate designs/specifications and documentations 1 5 3.17 1.234 SV20: Client’s emphasis on time rather than quality 1 5 3.10 1.470 SV21: Cheap materials were used 1 5 2.80 1.518 SV22: No variations were incorporated 1 5 3.07 1.202 SV23: Satisfactory technological sophistication 1 5 3.37 1.377 SV24: No incidences of industrial unrests 1 5 3.43 1.104 SV25: Favourable physical and ecological conditions 1 5 3.30 1.055 SV26: Few internal procurement challenges 1 5 2.77 1.278 SV27: Client decisions were timely and objective 1 5 2.83 1.315 SV28: Right equipments were available 1 5 3.27 1.388 SV29: Effect of stringent insurance/warranty rules 1 5 3.17 1.206 SV30: Working capital was adequate 3 5 4.27 .785

Reliability was checked through the Cronbach’s alpha value of the entire scale

consisting of 30 success variables which turned out to be 0.881. This is well above the

threshold value of 0.7 (Hair et al., 2006). The variables also exhibited a high item-to-

total correlation as shown in Table 4.4.

56

Table: 4.4 Item-to-total correlations among project success variables obtained

through pilot survey

Variables of factors influencing project success Corrected Item-Total Correlation

Cronbach's Alpha if Item Deleted

SV1: Effect of location and Site conditions .485 .876

SV2: Influence of Design Complexity .392 .878

SV3: Adequate Project planning and, Scheduling .444 .877

SV4: Project funds secured on time .421 .877

SV5: Design documents approved on time .387 .878

SV6: Adequate experience on similar projects .609 .873

SV7: Adequate Information sharing and collaboration .691 .870

SV8: Adherence to the requisite Quality standards .675 .871

SV9: Continuous monitoring of actual expenditures .560 .874

SV10: Formal dispute resolution structures .298 .880

SV11: Site Managers possessed requisite skills .386 .878

SV12: Contractor had adequate technical skills -.060 .887

SV13: Contractor used latest construction methods .632 .872

SV14: Community had no issues against the project .142 .883

SV15: Adversely affected by the surrounding weather .076 .883

SV16: Effect of Macro- economic conditions .431 .878

SV17: Effect of the Governance policy .277 .881

SV18: Adequate commitment of the consultant to project .502 .876

SV19: Adequate designs/specifications and documentations .435 .877

SV20: Client’s emphasis on time rather than quality .440 .877

SV21: Cheap materials were used .669 .871

SV22: No variations were incorporated .448 .877

SV23: Satisfactory technological sophistication .250 .881

SV24: No incidences of industrial unrests .453 .877

SV25: Favourable physical and ecological conditions .333 .879

SV26: Few internal procurement challenges .376 .878

SV27: Client decisions were timely and objective .298 .880

SV28: Right equipments were available .569 .874

SV29: Effect of stringent insurance/warranty rules .410 .878

SV30: Working capital was adequate .440 .878

The results in table 4.4 show that deletion of any of the three variables (SV12, SV14

and SV15) would slightly improve the Cronbach’s alpha. However, the improvement

57

to be achieved is too insignificant to warrant their deletion. Therefore, all the success

variables were retained in the questionnaire.

4.5 Study site and identification of target population

The present study has been carried out in 24 constituencies located in the western

province of Kenya. Different types of CDF projects are undertaken in these

constituencies. Inspection of the list of projects in each constituency revealed that

there were over 4000 projects undertaken between 2003 and 2011. Out of 4000

projects undertaken between 2003 and 2011, those projects have been considered as

target projects which are involved in the construction of Educational facilities, Health

Care facilities, Light industries and Agricultural Markets. It was found that only 586

projects were involved in the construction of the above facilities. Thus these 586

projects qualified as target projects in the present study.

The 586 projects identified above allowed the researcher to define the target

population (i.e. target respondents) of the current study. The researcher identified

three categories of target respondents, namely clients, consultants and contractors.

There were 586 clients for 586 projects. In addition, there were 124 consultants and

212 contractors registered by Architectural Association of Kenya (AAK) and Kenya

contractors’ associations (KCA) county offices in Western province respectively.

Therefore, the size of the target population became 922 consisting of 586 clients, 124

consultants and 212 contractors.

Given the small size of the target population, a decision was made to consider all the

respondents in the survey. This was, therefore, a census survey encompassing all

clients, consultants and contractors involved in the construction of CDF projects

between 2003 and 2011.

4.6 Identification and training of field investigators

The researcher selected 24 field investigators, one each for each of the 24

constituencies that constitute Western province, for the purpose of enabling them to

administer questionnaires to the respondents, namely clients, consultants, and

contractors. These are the students in the Faculty of Commerce at the Kisii University

College. One day training programme was organized for the field investigators in

order to make them clearly understand the purpose of the study, various technical

58

terms used in the questionnaire both in English and the local language (Swahili) and

the data collection methodology. They were also imparted training on the art of

extracting information from the respondents depending on a particular situation and

the mood of the respondents. Further they were also made aware of the varying

response patterns that might occur during interview process. In all circumstances, the

field investigators were asked to ensure that they carried copies of both version of the

questionnaire, English and Swahili while visiting a particular constituency for

fieldwork.

4.7 Data collection

Based on the population size of individual stratum determined in section 4.5, all three

categories of respondents, i.e. clients, consultants and contractors spread over 24

constituencies were, first of all, identified. The contact number, e-mail address, postal

addresses of the respondents were collected from the database maintained by CDF

regional office, Western Kenya. They were then contacted through telephone calls

and e-mails for explaining them the whole issue, purpose and the importance of

undertaking the survey. Subsequently each one of them was sent a brief note and a

copy of the questionnaire through e-mail in order to enable them to have an idea about

the kind of inputs required by the researcher. In the next stage, an appointment along

with the date, time and venue was sought from the respondents. Based on the

appointment, the field investigators visited the designated place in person with a hard

copy of the questionnaire with a view to eliciting responses from them through face-

to-face interview. This process was necessary in order to motivate the respondents to

participate in the interview process and also to minimize their unwillingness to share

their experience in CDF construction projects. Further face-to-face interview allowed

the field investigators to explain the respondents the issues relating to the variables

affecting construction project success and also gave them the opportunity to seek

clarifications on related aspects.

The survey was undertaken from December 2011 to the end of February 2012. The

response rate turned out to be quite good, which is contrary to survey research. Such a

response rate can be attributed to the prior interaction between the researcher and the

respondents in seeking their willingness to be interviewed for the study.

59

CHAPTER 5: RESEARCH FINDINGS AND DISCUSSION (PHASE I)

5.0 Introduction

In this chapter, the findings of exploratory factor analysis (EFA) are discussed. The

chapter presents a brief overview of the responses received and describes the process

of data screening employed. It is followed by a description of projects’ characteristics,

respondents’ profile and status of the CDF projects. The descriptive statistics of the

scale items are then obtained and discussed. The next section reports on the EFA of

performance measurement variables starting with the factorability of the scale items

through the examination of the correlation matrix, Bartlet’s test, Kaiser-Meyer-

Olkin (KMO) measure of sampling adequacy and anti-image correlation matrix.

Eventually Principal Component Analysis (PCA) using Varimax rotation is applied as

a data reduction technique and to explore interrelationships amongst performance

measurement variables. A similar process is followed to explore the project success

variables. At the end of the chapter, a relationship between project success factors,

project success, overall project performance and the various performance indicators is

conceptualised.

5.1 Screening of collected Data

At the end of twelve weeks, the field investigators were able to submit 196 completed

questionnaires, representing a response rate of 21.25%. Western province, as it has

already been explained in chapter 3 (section 3.1) is divided into four counties spread

over 24 constituencies. Table 5.1 summarises the distribution of responses on four

different categories of projects across different constituencies before the responses

were screened.

Table 5.1: Distribution of responses according to counties and constituencies Project Classification Total

COUNTY CONSTITUENCY Educational Health Care Industrial Estate

Agricultural Market

KAKAMEG

A COUNTY Malava 4 44.4% 3 33.3% 2 22.2% 0 0.0% 9

Lugari 3 30.0% 3 30.0% 1 10.0% 3 30.0% 10

Mumias 1 20.0% 2 40.0% 1 20.0% 1 20.0% 5

Matungu 4 66.7% 0 0.0% 1 16.7% 1 16.7% 6

Lurambi 5 45.5% 3 27.3% 2 18.2% 1 9.1% 11

60

Shinyalu 5 45.5% 5 45.5% 0 0.0% 1 9.1% 11

Ikolomani 0 0.0% 2 33.3% 2 33.3% 2 33.3% 6

Butere 4 50.0% 1 12.5% 2 25.0% 1 12.5% 8

Khwisero 2 40.0% 0 0.0% 2 40.0% 1 20.0% 5

SUB-TOTAL 28(39.4%) 19(26.8%) 13(18.3%) 11(15.5%) 71(36.2%)

VIHIGA

COUNTY Emukhaya 4 40.0% 5 50.0% 0 0.0% 1 10.0% 10

Sabatia 0 0.0% 6 54.5% 3 27.3% 2 18.2% 11

Vihiga 4 57.1% 2 28.6% 0 0.0% 1 14.3% 7

Hamisi 3 37.5% 1 12.5% 3 37.5% 1 12.5% 8

SUB-TOTAL 11(30.5%) 14(38.9%) 6 (16.7%) 5 (13.9) 36(18.4%)

BUNGOMA

COUNTY Mt. Elgon 4 66.7% 0 0.0% 1 16.7% 1 16.7% 6

Kimilili 2 33.3% 0 0.0% 2 33.3% 2 33.3% 6

Webuye 3 42.9% 1 14.3% 1 14.3% 2 28.6% 7

Sirisia 3 37.5% 1 12.5% 2 25.0% 2 25.0% 8

Kanduyi 4 44.4% 1 11.1% 3 33.4% 1 11.1% 9

Bumula 3 37.5% 1 12.5% 2 25.0% 2 25.0% 8

SUB-TOTAL 19(43.2%) 4 (9.1%) 11(25.0%) 10(22.7%) 44(22.4%)

BUSIA

COUNTY Amagoro 3 30.0% 1 10.0% 3 30.0% 3 30.0% 10

Nambale 4 36.4% 5 45.5% 1 9.1% 1 9.1% 11

Butula 3 37.5% 2 25.0% 0 0.0% 3 37.5% 8

Funyula 2 25.0% 2 25.0% 1 12.5% 3 37.5% 8

Budalang'i 3 37.5% 1 12.5% 3 37.5% 1 12.5% 8

SUB-TOTAL 15(33.3%) 11(24.4%) 8(17.8%) 11(24.4%) 45(23.0%)

GRAND TOTAL 73 (37.2%) 48 (24.5%) 38 (19.4%) 37 (18.9%) 196

Table 5.1 shows that out of all the projects surveyed, 71 (36.2%) were based in

Kakamega County, 36 (18.4%) were undertaken in Vihiga County, 44 (22.4%) were

carried out in from Bungoma County whereas 45 (23%) were based in Busia County.

Kakamega County had the maximum number of projects surveyed because it is the

largest in terms of size and has the highest number of constituencies in the Western

Province, Kenya.

61

Distribution of the four types of projects across all counties considered together

reveals that majority were Educational projects followed by Health care facilities,

Industrial Estates and finally Agricultural Markets.. Further, all types of projects were

undertaken in each of the counties with Educational projects dominating in

Kakamega, Bungoma and Busia Counties while in Vihiga, majority of the projects

were Health Care projects. The distribution of different types of projects depends on

the socio-economic conditions and preferences of residents.

Following initial observation of data, the negatively framed questions were suitably

reversed and all the scores were fed into SPSS software (version 20) for doing the

analysis. However, before actual analysis was carried out, it was important to

• Check if data had been entered correctly and whether it contained out-of-range

values.

• Check for missing values, and deciding how to deal with the missing values.

• Check for outliers, and deciding how to deal with outliers.

• Check for normality, and deciding how to deal with non-normality.

While inputting the data it was observed that a few sections of the questionnaire were

not fully completed. Such sections were left blank for purposes of proper analysis.

The SPSS Missing Data Analysis option was used to analyse the noted patterns in the

data. The Replace Missing Values option was used to replace the missing values that

were not significant with mean of all valid responses as is the norm with similar

studies (Hair et al., 2006). Those respondents with a significant number of missing

values were eliminated. It was found that 9 responses to section B of the questionnaire

had significant missing values and 12 respondents did not indicate their perceptions

on over 50% of the statements in the section C of the questionnaire. These 21

responses were, therefore, eliminated from the study.

62

While checking for outliers, it was found that the extreme values were either strongly

agree (5) or strongly disagree (1) in response to the interval Likert scaled statements.

Since this study sought to secure respondents’ perceptions towards the key

performance measurement variables and project success variables, it was seen to be

normal for a respondent to have such extreme feelings towards certain variables and

be moderate on others. According to Hair et al. (2006), deleting them would,

therefore, affect the generalisability to the entire population, and hence, they were all

retained. “...if they do represent a segment of the population, they should be retained

to ensure generalisability to the entire population (Hair et al., 2006).

Given that univariate outliers were allowed in the data, it was not possible to test

multivariate outliers since no significant decision could be taken. Hair et al. (2006)

hold that a situation in which all variables exhibit univariate normality will help gain,

although not guarantee multivariate normality among the variables. They further

argue that in most cases, assessing and achieving univariate normality in variables is

sufficient and multivariate normality is addressed when it is very critical. Observation

of the distribution of data in reference to skewness and kurtosis revealed that the data

was approximately normal.

At the end of item screening, 175 respondents remained for the purposes of data

analysis indicating an effective response rate of 19%.

5.2 Demographic characteristics of projects and respondents’ profile

This section reports on project characteristics in terms of the procurement approaches

and the status of projects regarding occurrence of cost overrun, time overrun and

quality defects.

5.2.1 Description of CDF construction projects and their procurement

approaches

Table 5.2 presents relevant data pertaining to the type of the projects surveyed and

their procurement approaches.

63

Table 5.2: Types of CDF projects and their procurement approaches Project classification

Total Educational Health Care Industrial

Estate

Agricultural

Market

Procurement approach

used

2. Design/Build 8 (4.6%) 2 (25.0%) 4 (50.0%) 1 (12.5%) 1 (12.5%)

3. Competitive bid 70 (40.0%) 32 (45.7%) 5 (7.1%) 17 (24.3%) 16 (22.9%)

4. Negotiated general

contract 97 (55.4%) 31 (31.9%) 35 (36.1%) 15 (15.5%) 16 (16.5%)

TOTAL 175 (100%) 65 (37.1%) 44 (25.1%) 33 (18.9%) 33 (18.9%)

The projects surveyed in this study consist of 65 Educational projects (37.1%), 44

Health Care facilities (25.1%), 33 Industrial Estates (18.9%) and 33 Agricultural

Markets (18.9%) as shown in Figure 5.1.

Figure 5.1: Types of projects surveyed

64

The dominance of the Educational and Health Care projects can be attributed to the

fact that the majority of the people residing in rural areas of Kenya are mainly women

and children as men usually migrate to urban centres in search of employment. Owing

to this, the projects that focus on children and women, namely Educational and Health

Care projects have multiplier effect on the quality of life in rural areas.

Table 5.2 also shows that three procurement approaches are used in securing

construction of CDF projects in Western province, Kenya. These are (i) Design/ build,

(ii) Competitive bid and (iii) Negotiated general contract. As shown in Figure 5.2,

majority of these projects were procured through Negotiated general contracts

(55.4%), followed by Competitive bidding (40%) and Design/Build (4.6%).

Figure 5.2: Approaches used in project procurement

The results indicate that the negotiated general contract is the most popular

procurement method used amongst CDF construction projects in Kenya. Under this

approach, a single prime contractor is entrusted with the responsibility of undertaking

the entire work. The contractor is accountable for the activities taking place on the

65

project. This approach creates common project goals and objectives and acts as a

single point of responsibility that enhances project communications.

5.2.2 Status of CDF construction projects

Three major problems facing CDF construction projects are said to be time overrun,

cost overrun and quality defects. Together, they provide a picture of the existing

status of CDF construction projects surveyed. The occurrence of time overrun, cost

overrun and quality defects across different types of projects is presented in Table 5.3.

Table 5.3: Status of CDF construction projects Project classification

Total Educational Health Care Industrial Estate

Agricultural Market

Time overrun

None 22 (12.6%) 10 (45.5%) 5 (22.7%) 1 (4.5%) 6 (27.3%)

Less than 6 months 95 (54.3%) 36 (37.9%) 21 (22.1%) 17 (17.9%) 21 (22.1%)

6-12 months 41 (23.4%) 12 (29.3%) 14 (34.1%) 11 (26.8%) 4 (9.8%)

over 12 months 17 (9.7%) 7 (41.2%) 4 (23.5%) 4 23.5%) 2 (11.8%)

Cost overrun

None 91 (52.0%) 37 (40.6%) 21 (23.1%) 20 (22.0%) 13 (14.3%)

Less than ksh.100,000 54 (30.8%) 18 (33.3%) 18 (33.3%) 6 (11.2%) 12 (22.2%)

Ksh.100,001-ksh.300,000 25 (14.3%) 9 (36.0%) 5 (20.0%) 5 (20.0%) 6 (24.0%)

Ksh.300, 001-ksh. 500,000 5 (2.9%) 1 (20.0%) 0 (0.0%) 2 (40.0%) 2 (40.0%)

Quality defects (Variations)

None

Less than 20%

20% and more

116 (66.3%)

55 (31.4%)

4 (2.3%)

46 (39.7%)

17 (30.9%)

2 (50.0%)

26 (22.4%)

17 (30.9%)

1 (25.0%)

25 (21.6%)

7 (12.7%)

1 (25.0%)

19 (16.3%)

14 (25.5%)

0 (0%)

TOTAL 175 (100%) 65 (37.1%) 44 (25.1%) 33 (18.9%) 33 (18.9%)

The findings in Table 5.3 indicate that 153 amongst 175 projects surveyed (87%) in

this study experienced time overrun ranging from less than six months to more than

12 months. However, much of the delay was for less than 6 months (54%). The table

shows the magnitude of time overrun across all four kinds of projects and reveals that

the proportion of time overrun was maximum amongst Industrial Estates (approx.

97%) and minimum amongst Agricultural Markets (81.8%).

66

Figure 5.3: Time overrun amongst different types of projects

The current findings show that the projects that were widely implemented

(Educational, Health and Agriculture) in the Western Province, Kenya experienced

relatively low time overrun. Figure 5.3 shows that of those projects that did not

experience any time overrun, about 45.5% were Educational, 22.7% were Health Care

and 27.3% were Agricultural Markets. This can be attributed to their significant

relevance to the needs of the community

Table 5.3 also demonstrates that 84 out of 175 projects surveyed (48%) incurred cost

overrun during their implementation in the range of less than Ksh. 100,000 to

67

Ksh.500, 000. While considering cost over-run across the types of projects, the table

further indicates that the same was maximum (60.6%) in case of agricultural projects

and minimum (39.4%) in case of Industrial Estates. In addition, 52.3% of Health Care

projects and 43% of Educational projects experienced cost over-run. Figure 5.4 shows

the occurrence of cost overrun across different types of projects.

Figure 5.4: Cost overrun amongst different types of projects

Of the projects that did not experience any cost overrun, 40.7% were Educational,

23.1% were Health Care, 22.0% were Industrial Estates and about 14.2% were

Agricultural Markets. Further there was no Health Care project that experienced very

high cost overrun (Ksh. 300,001-Ksh. 500,000). This is also attributed to the

importance of these projects to the intended beneficiaries.

68

Quality defects of a construction project are measured by how the constructed quality

deviates from the prescribed technical specifications of the project. In the current

study, 116 projects (66.3%) were found to have been free from apparent defects with

only 4 projects (2.3%) recording quality defects of 20% or more. Of those projects

that suffered from quality defects, majority were Educational (19) followed by Health

Care projects (18), Agricultural Markets (14) and finally Industrial Estates (8). The

distribution of quality defects amongst different types of projects is shown in Figure

5.5.

Figure 5.5: Quality defects amongst different types of projects

However, when occurrence of quality defects is considered across different types of

projects, it was found that 39.7% were Educational, 22.4% were Health Care, 21.6%

were Industrial Estates and 16.4% were Agricultural Markets. Further, Educational

projects were found to constitute about 50% of those projects that experience the

69

highest percentage of quality defects (more than 20%). This is because of their

importance amongst communities in Western province and the variations in design

specifications.

5.2.3: Respondents’ profile

Table 5.4 attempts to capture the respondents’ profile in terms of their position on the

project, their experience in the construction industry and how long they have been

involved in CDF construction projects.

Table 5.4: Respondents’ Profile.

Total Respondent’s Position on the construction project

Client Consultant Contractor Experience in Construction of

projects

<3 Years 32 14 (43.8%) 11 (34.4%) 7 (21.9%)

3-6 Years 87 60 (69.0%) 4 (4.6%) 23 (26.4%)

>6 Years 56 18 (32.1%) 14 (25.0%) 24 (42.9%)

Respondent involvement in CDF

Projects

<3 Years 52 14 (26.9%) 11 (21.2%) 27 (51.9%)

3-6 Years 97 70 (72.2%) 13 (13.4%) 14 (14.4%)

>6 Years 26 8 (30.8%) 5 (19.2%) 13 (50.0%)

Value of CDF projects worked on

in the last 3 years

Over ksh. 15,000,000 35 15 (42.9%) 7 (20.0%) 13 (37.1%)

Ksh. 10,000,000-15,000,000 56 32 (57.1%) 2 (3.6%) 22 (39.3%)

Upto ksh. 10,000,000 84 45 (53.6%) 20 (23.8%) 19 (22.6%)

TOTAL 175 92 (52.6%) 29 (16.6%) 54 (30.0%)

The respondents comprised 92 clients (52.6%), 29 consultants (16.6%) and 54

contractors (30.9%).

Almost half of the respondents (49.7%) have been in the project construction industry

for 3-6 years followed by those with over six years experience (32.0%) and only 32

respondents (18.3%) had experience of less than 3 years.

Further, most of the respondents (70.3%) have specifically been involved in the

construction of CDF projects for a period exceeding 3 years. This adds credence to

70

the study in the sense that the views expressed by the respondents are based on their

actual experience associated with the construction industry in general and CDF

construction projects in particular.

An analysis of the average value of projects respondents had handled in the past

revealed that majority had dealt with relatively small projects. Of the projects

surveyed, 84 projects (48.0%) had a value of less than Ksh. 10,000,000, 56 projects

(32.0%) had a value of Ksh. 10,000,000 to Ksh. 15,000,000 whereas 35 projects

(20.0%) were large with values above Ksh. 15,000,000.

This information indicates that apart from having adequate experience in terms of

years the respondents have been involved in construction projects, respondents had

handled projects of different sizes.

5.3 Exploratory Factor Analysis (EFA) of performance measurement variables

for Key Performance Indicators (KPIs) scale

In this section, data in Phase I of the study comprising 175 responses was used to

carry out EFA on performance measurement variables in order to identify the KPIs of

public sector construction projects. First, the descriptive statistics of the performance

measurement variables are presented and subsequently the factorability of the

variables is assessed before the variables are subjected to EFA.

5.3.1 Descriptive statistics of performance measures

The responses on 35 variables relating to project performance provided by the

respondents were included in the present study. The findings regarding the minimum

score, maximum score, mean and standard deviations of the scores on responses to

performance measurement variables are presented in table 5.5.

Table 5.5: Descriptive statistics of performance measurement variables Performance measurement variables (PV) Min

Score Max Score

Mean Score

Std. Dev

PV1: There has not been any increase in the cost of raw

materials during construction of this project. 1 5 3.24 1.422

PV2: Labour costs more or less remained stable over the

period of construction of the current project. 1 5 3.18 1.145

PV3: The project experienced minimum variations and

hence hardly any additional cost attributable to variations 1 5 3.27 1.252

71

was incurred.

PV4: The required equipments were available at pre

budgeted rates. 1 5 3.21 1.371

PV5: The amount/quantity of different type of resources

required during the implementation phase matched with

those estimated during planning stage.

1 5 3.22 1.269

PV6: There were no incidences of fraudulent practices

and kickbacks during project execution. 1 5 2.92 1.362

PV7: There were no incidences of agitation by the trade

unions in the current project. 1 5 2.86 1.275

PV8: There were no serious dispute between the client

and contractor due to non adherence to the specifications. 1 5 2.81 1.285

PV9: Disputes were observed due to the frequent

changes in the design of the current project. 1 5 2.84 1.183

PV10: Dispute resolution meetings were often held

during project execution. 1 5 2.70 1.234

PV11: At the time of project completion, there were no

financial claims that remained unsettled from this

project.

1 5 2.54 1.363

PV12: This construction project has adversely affected

the quality of groundwater level. 1 5 2.25 1.052

PV13: All required resources for the project were

delivered on time during execution of this project. 1 5 2.90 1.298

PV14: A clear plan was formulated and an efficient

planning and control system was designed to keep the

current project up-to-date.

1 5 3.12 1.146

PV15: No changes were introduced in the designs of the

current during project execution. 1 5 3.09 .896

PV16: Harmonious relationship between labour and

management existed in the project site and hence no

work disruptions were reported during project execution.

1 5 3.18 1.204

PV17: This project has led to air pollution in the

adjoining areas. 1 5 2.59 1.100

PV18: This project has led to depletion of the precious

natural and mineral resources in the surrounding areas. 1 5 2.96 1.126

PV19: There has been an increase in solid waste due to

the construction of the current project. 1 5 2.93 1.145

72

PV20: Accidents were often reported during project

construction. 1 5 3.23 1.316

PV21: Near misses occurred quite often during

construction. 2 5 3.86 .889

PV22: Fatalities did occur on this project during

construction. 1 5 3.38 1.043

PV23: The construction work utilised environmentally

friendly technology. 1 5 2.54 1.010

PV24: This project has led to the increased release of

toxic material. 1 5 3.10 1.316

PV25: No delays were experienced in securing funds

during project implementation. 1 5 3.31 1.263

PV26: At the time of handover, the current project was

free from apparent defects 1 5 3.32 1.291

PV27: The project contractors were often called back

during the Defects Liability Period to repair defects. 1 5 2.70 1.247

PV28: Weather and climatic conditions did not have

much impact on delaying the project. 1 5 3.30 1.110

PV29: The current project has utilised reusable and

recyclable materials in construction work. 1 5 2.70 1.370

PV30: The right material was used for the construction

work. 1 5 2.46 1.138

PV31: Employees working in the current project

possessed requisite skills and most of them had worked

on similar kinds of projects in the past.

1 5 2.58 1.261

PV32: A sound quality management system was strictly

adhered to during project execution phase of the current

project.

1 5 2.49 1.066

PV33: Training was imparted to the workers in order to

develop a positive attitude and also to enable them to

apply the right method of work.

1 5 2.54 1.123

PV34: All stakeholders associated with the current

project supervised the quality of the project in all its

phases.

1 5 3.03 1.397

PV35: Proper medical facilities were available for

people working on the project. 2 5 3.79 .961

Responses collected on a five point Likert scale (1-Strongly Disagree .................. 5- Strongly Agree).Scores on negatively framed statements were reversed.

73

The minimum and maximum values were 1 and 5 respectively for 34 out of 35

variables, indicating that, in general, respondents used the entire 5 point survey scale.

The mean score ranged between 2.25 (This construction project has adversely

affected the quality of groundwater level-PV12) and 3.86 (Near misses occurred quite

often during construction-PV21). Standard deviations were found to be above 1

except in three variables; “no changes were introduced in the design of the current

project during project execution - PV15” (0.896), “near misses occurred quite often

during construction - PV21” (0.889) and “proper medical facilities were available for

people working on the project - PV35” (0.961). This shows that the means represent a

good measure of the distribution of scores in the survey data. However, the standard

deviation values of these three variables being close to 1 indicate that the responses to

these three questions varied considerably amongst the respondents.

5.3.2 Assessing the factorability of performance measurement variables

For assessing the factorability of 35 performance measurement variables, the

researcher found out the correlation for each pair of 35 variables which is

demonstrated with the help of a correlation matrix. This shows the strength of

relationship between every pair of items and is summarised below (table 5.6).

The correlation matrix in the above table suggests that the sample is characterised by

high degree of related variables which could be grouped together. With the exception

of a few variables, a large number of significant correlations are found amongst

different pair of variables in this matrix: 193 correlations significant at 5% level and

160 correlations significant at 1% level. This gives the researcher an indication that

exploratory factor analysis (EFA) could be carried out in the whole dataset.

The values in the correlation matrix suggest that the sample is characterised by high

degree of related variables which could be grouped together. This provides evidence

of factorability of the performance measurement variables.

74

Table 5.6: Original Correlation Matrix of performance measurement variables

PV1 PV

2 PV 3

PV 4

PV 5

PV 6

PV 7

PV 8

PV 9

PV 10

PV 11

PV 12

PV 13

PV 14

PV 15

PV 16

PV 17

PV 18

PV 19

PV 20

PV 21

PV 22

PV 23

PV 24

PV 25

PV 26

PV 27

PV 28

PV 29

PV 30

PV 31

PV 32

PV 33

PV 34

PV 35

PV1 1 PV2 .74 1 PV3 .70 .68 1 PV4 .81 .75 .87 1 PV5 -.01 -.06 .07 .04 1 PV6 .07 .01 .07 .09 .52 1 PV7 .25 .05 .11 .13 -.03 .01 1 PV8 -.05 -.27 -.15 -.15 -.01 -.04 .75 1 PV9 .01 -.25 -.08 -.08 .03 -.04 .72 .92 1 PV10 .16 .06 .09 .07 -.04 .02 .57 .77 .69 1 PV11 .45 .26 .33 .42 .00 .07 .65 .34 .31 .19 1 PV12 .30 .40 .28 .35 -.05 .05 .25 .24 .17 .25 .52 1 PV13 .24 .18 .14 .23 -.01 -.00 -.11 -.19 -.17 -.07 .10 -.23 1 PV14 .09 .04 .07 .13 .06 -.00 .00 .00 .04 -.02 .15 -.16 .73 1 PV15 -.04 -.07 -.11 -.03 .04 -.04 -.03 -.08 -.04 -.13 .13 -.08 .41 .43 1 PV16 .20 .01 .01 .19 .05 -.01 .03 -.06 -.01 -.15 .22 -.18 .62 .66 .52 1 PV17 -.04 .03 -.11 -.07 .04 -.06 .21 .20 .15 .11 .09 .05 -.14 .02 -.17 -.12 1 PV18 .02 .18 .02 .04 -.07 .02 .24 .23 .18 .12 .13 .16 -.17 .06 -.30 -.10 .57 1 PV19 -.05 .13 -.03 -.05 -.04 -.06 .20 .21 .16 .12 .04 .13 -.25 .00 -.24 -.12 .62 .79 1 PV20 .00 -.09 -.01 .02 .50 .34 .04 .01 .07 -.09 .09 -.03 .08 .08 .12 .12 -.01 -.06 -.07 1 PV21 .01 -.03 -.03 -.01 .01 .12 -.02 .05 .08 -.01 .04 .08 .05 .01 .01 .04 .03 -.03 .05 .45 1 PV22 -.05 -.08 -.07 -.07 .03 -.07 .02 .00 -.01 -.09 .08 .00 -.01 -.02 .06 .02 -.06 -.09 -.04 .52 .34 1 PV23 .00 -.00 -.11 -.06 .07 -.02 .20 .18 .12 .11 .05 .01 -.07 .04 -.04 -.03 .86 .44 .54 .04 .07 -.05 1 PV24 -.01 .05 -.02 .00 -.09 .02 .08 .04 -.02 .08 .03 -.00 .06 .02 .12 .01 -.03 -.03 .00 -.19 -.41 .02 -.03 1 PV25 .34 .21 .16 .21 -.04 -.08 .10 .02 .03 .03 .18 -.09 .77 .45 .44 .57 -.00 -.05 -.12 .10 .05 .02 .07 .10 1 PV26 .04 -.16 -.05 .01 -.02 -.02 .28 .32 .36 .18 .12 -.11 .40 .43 .10 .32 .05 .16 .12 .17 .21 .08 .10 -.01 .30 1 PV27 .21 .27 .30 .32 .09 -.03 .03 -.14 -.08 .01 .07 -.13 .34 .29 -.07 .17 -.19 -.04 -.10 -.09 -.15 -.11 -.18 .06 .23 .12 1 PV28 .29 -.04 .17 .28 .10 .07 .22 .13 .21 -.01 .21 -.26 .56 .53 .19 .57 -.05 -.06 -.15 .15 .07 -.02 -.03 -.05 .47 .64 .29 1 PV29 .06 -.02 .10 .06 -.04 .03 .06 .08 .07 .13 .00 -.02 -.18 -.18 -.22 -.13 .03 .08 .10 -.04 .02 -.05 -.02 -.07 -.15 -.03 -.02 -.03 1* PV30 .33 .37 .44 .46 .15 .11 .11 -.08 -.04 .02 .27 .08 .19 .26 -.11 .04 .05 .07 -.04 .00 -.09 -.06 -.02 -.03 .12 -.05 .40 .27 .02 1 PV31 .18 .20 .22 .18 -.06 .06 -.01 -.09 -.12 -.07 .08 .04 .09 .11 -.18 .04 -.03 .14 .08 .00 .02 .04 -.07 -.00 .02 .03 .19 .02 -.03 .28 1 PV32 .30 .33 .39 .40 .16 .11 .22 .02 .04 .11 .36 .10 .18 .29 -.12 .05 .07 .12 .02 -.03 -.11 -.06 .02 -.06 .08 -.01 .37 .23 .01 .92 .30 1 PV33 .34 .39 .46 .49 .12 .09 .15 -.06 -.02 .06 .29 .07 .23 .28 -.06 .06 -.02 .00 -.12 .04 -.11 -.05 -.08 -.04 .16 -.03 .37 .29 -.03 .92 .28 .88 1 * PV34 -.10 -.06 -.06 -.10 -.28 -.22 .07 .06 .07 .02 -.04 -.12 .07 .04 -.01 -.02 .01 -.07 .01 .00 .01 .35 -.03 .22 .11 .07 -.09 -.02 -.01 -.00 -.04 -.02 -.01 1 PV35 -.07 .01 -.07 -.06 -.24 -.21 .05 .05 .10 .02 -.02 -.02 -.03 -.07 -.03 -.04 .03 -.07 .02 -.18 .10 -.12 -.03 .24 -.07 .11 -.05 .01 -.03 -.03 -.03 -.07 -.04 .15 1

Correlation coefficient and p values are as follows: ρ > 0.15 denotes p-value <0.05 or significant at the 5% level; ρ > 0.20 denotes p-value <0.01; or significant at the 1% level Overall measure of sampling adequacy: 0.656 Bartlett test of sphericity: 4657.286, degrees of freedom=595, Significance: 000

75

However, before carrying out EFA, the overall significance of the correlation matrix

and its factorability needed to be tested with the help of Bartlett’s test of sphericity

and Kaiser-Meyer-Olkin (KMO) measure of sampling adequacy respectively.

Bartlett's test statistics was found significant at 0.000 levels, which indicates the

presence of non-zero correlations in the correlation matrix. Further the KMO measure

of the sampling adequacy turns out to be 0.656. Although both tests met the minimum

criteria for carrying out factor analysis in the dataset, observation of the correlations

along the diagonal of the anti image correlation matrix in table 5.7 revealed that 7

variables had their KMO values less than 0.5, which indicates that the dataset, in its

current form, is still not suitable for factor analysis (Hair et al., 2006). These variables

were iteratively removed one after another starting with the one whose correlation

along the diagonal of the anti image matrix was the lowest (Jahmane et al., 2011).

After the removal of five variables, it is found that all variables had individual KMO

values greater than 0.5. This resulted in the improvement of overall KMO measure of

sampling adequacy to 0.687. Further Bartlett's test statistics was found significant at

0.000 levels. These measures indicate that the reduced set of variables is appropriate

for factor analysis.

76

Table 5.7: Measures of Sampling Adequacy and Partial Correlations amongst performance measurement variables PV

1 PV 2

PV 3

PV 4

PV 5

PV 6

PV 7

PV 8

PV 9

PV 10

PV 11

PV 12

PV 13

PV 14

PV 15

PV 16

PV 17

PV 18

PV 19

PV 20

PV 21

PV 22

PV 23

PV 24

PV 25

PV 26

PV 27

PV 28

PV 29

PV 30

PV 31

PV 32

PV 33

PV 34

PV 35

PV1 .70a PV2 -.5 .70a PV3 .04 -.08 .79a PV4 -.2 -.18 -.68 .79a PV5 .00 -.0 -.16 .08 .49a PV6 -.01 .07 .07 -.04 -.41 .46a PV7 -.04 -.25 -.06 .18 .13 -.13 .75a PV8 .23 .06 .03 .14 -.09 .09 -.26 .64a PV9 -.21 .19 -.01 -.12 -.03 .06 -.10 -.64 .75a PV10 -.21 -.05 -.04 -.11 .08 -.12 -.05 -.62 .07 .61a PV11 -.31 .33 -.07 -.13 .04 .01 -.55 -.22 .19 .39 .56a PV12 .18 -.36 .14 -.18 .04 -.07 .31 -.16 .02 -.06 -.54 .59a PV13 .19 -.24 .02 .14 .03 -.07 .15 .25 .09 -.37 -.33 .19 .60a PV14 -.13 .13 -.13 .05 .02 .03 .12 -.19 -.07 .16 .16 -.11 -.67 .60a PV15 .30 -.20 .03 .05 -.02 .03 -.06 .26 -.17 -.12 -.25 .07 .27 -.40 .55a PV16 .01 -.01 .29 -.23 -.06 .03 .00 .02 .06 .00 -.16 .14 .18 -.46 -.09 .74a PV17 .16 -.11 .13 -.02 -.14 .14 .05 .11 -.06 -.11 -.21 .05 .13 -.19 .20 .20 .59a PV18 .17 -.22 .08 -.06 .25 -.21 .02 -.01 -.07 .07 -.11 .11 .15 -.18 .26 .05 -.21 .63a PV19 .09 -.16 -.11 .09 -.14 .11 -.04 .01 .02 -.01 .03 -.00 .16 -.10 .02 -.08 -.03 -.57 .75a PV20 .06 .00 .08 -.06 -.48 -.14 -.07 .13 -.16 .02 -.05 .03 -.02 -.02 .02 .01 .04 -.07 .07 .58a PV21 .05 -.08 .00 -.01 .27 -.28 .13 -.04 -.04 -.02 -.07 .00 -.01 .00 .03 .02 .02 .20 -.16 -.27 .45a PV22 -.05 .01 .02 .02 .06 .28 .01 -.07 .13 .02 -.04 .01 .03 .04 -.03 -.02 -.01 .01 .01 -.48 -.24 .48a PV23 -.20 .17 -.03 -.05 .05 -.05 -.13 -.11 .15 .07 .20 -.00 -.10 .11 -.18 -.09 -.81 .15 -.17 -.06 -.06 .07 .57a PV24 .04 -.02 .08 -.09 .04 -.28 -.00 -.06 .09 -.07 -.05 .04 .01 -.03 -.09 .06 .03 .07 -.09 .08 .50 -.25 -.03 .37a PV25 -.24 .13 .01 -.12 .00 .12 -.05 -.31 .02 .30 .27 -.09 -.79 .57 -.41 -.29 -.15 -.18 -.04 -.05 -.06 .06 .07 -.08 .55a PV26 .03 .10 .05 -.05 -.01 .10 -.12 .01 -.03 -.03 .12 -.18 -.15 -.09 .01 .18 .21 -.18 -.08 -.07 -.11 -.04 -.15 -.05 .06 .72a PV27 .28 -.19 .06 -.09 -.16 .16 -.16 .22 -.12 -.14 -.09 .16 .04 -.17 .29 .06 .17 .07 .00 .11 .01 -.01 -.04 -.06 -.14 -.03 .68a PV28 -.26 .24 -.03 -.15 .03 -.12 -.10 -.17 -.01 .30 .13 .17 -.26 .11 -.01 -.30 -.22 .06 .02 .04 .04 .01 .19 .07 .16 -.52 -.08 .70a PV29 -.07 .11 -.06 -.03 .09 -.02 .02 -.01 .05 -.11 -.04 .10 .00 .08 .04 -.04 -.05 .01 -.09 -.05 -.01 .06 .10 .03 .05 -.02 .00 .01 .65a PV30 -.10 .04 -.02 .00 -.02 -.04 .15 -.10 .09 .13 .12 -.12 .16 -.05 -.04 .09 -.04 -.06 .04 .00 -.11 .01 -.01 -.11 -.13 .13 -.20 -.20 -.10 .74a PV31 -.18 .08 -.17 .11 .16 -.09 .02 -.15 .13 .16 .10 -.02 -.04 .01 .09 -.11 -.06 -.04 -.04 -.07 -.03 -.03 .10 -.05 .03 -.08 -.11 .17 .07 .06 .64a PV32 .09 -.02 .07 025 -.16 -.01 -.08 .18 -.16 -.16 -.25 .09 -.13 -.01 .11 -.06 .08 .00 -.07 .22 .06 -.09 -.09 .14 .13 -.07 .09 .14 .00 -.63 -.15 .77a PV33 .17 -.13 -.01 -.11 .12 .05 -.12 .00 .05 -.07 -.01 .11 .03 -.11 .02 .10 -.00 .09 .09 -.20 .11 .07 .06 .06 -.04 .03 .14 -.05 .11 -.56 -.06 -.17 .83a PV34 .13 -.06 -.08 .04 .24 -.03 -.09 .09 -.14 .01 .01 .10 .02 -.11 .19 .03 -.07 .19 -.09 .01 .08 -.32 .07 -.11 -.14 -.04 .17 .08 -.00 -.11 .09 .03 .08 .48a PV35 .10 -.14 .03 .01 .04 .18 -.03 .07 -.19 .07 -.02 .05 -.11 .15 .03 -.10 -.14 .14 -.04 .05 -.29 .24 .12 -.36 .18 -.14 .09 .03 .04 -.10 -.02 .07 -.01 -.04 .35a

Note: Measures of Sampling Adequacy (MCA) are on the diagonal, partial correlations in the off-diagonal.

77

5.3.3 Factor Analysis following Varimax Rotation

Principal components analysis (PCA) was used with varimax rotation given that the

primary purpose was to identify the underlying factors. Initially all 30 variables were

allowed to load freely on various factors so long as they had eigenvalue greater than

one. This approach, together with the scree plot generated (figure 5.6) enabled the

researcher to fix the number of factors to be extracted at six. Therefore, while

identifying the final factors underlying the Key Performance Indicators (KPIs), the

process was subjected to four conditions: (i) the number of factors fixed at six, (ii)

deletion of items with loadings of less than 0.5 or cross loadings of greater than 0.5,

(iii) retention of only those factors with at least two items and (iv) the number of

factors extracted should account for at least 60% of the variance (Field, 2005; Hair et

al. 2006; Malhotra and Dash, 2011).

Figure

5.6: Scree Plot of performance measurement variables

Based on these conditions, Factor analysis was iteratively repeated and items deleted

sequentially resulting in a final instrument of 27 items. The 27- item 6-factor instrument

accounted for 73.023% of the variance in the dataset.

78

Table 5.8: Results of the Factor Analysis of performance measurement variables

Components

1 2 3 4 5 6 Cronbach’s alpha ( α ) 0.867 0.869 0.918 0.875 0.966 0.699 TVP1: Timely delivery of resources .862 TVP2: Harmonious relationship on site. .832 TVP3: A clear plan was formulated. .800 TVP4: No delays in securing funds. .772 TVP5: No effect of weather and climatic conditions. .734 TVP6: No design changes. .586 TVP7: At handover there were no apparent defects .572 CVP1: Equipments at pre budgeted rates. .875 CVP2: Stable labour costs .863 CVP3: No increase materials cost .854 CVP4: Minimum variations cost. .806 CVP5: Adverse effect on quality of groundwater level. .586 CVP6: No financial claims at completion. .508 DVP1: No serious dispute due to specifications. .951 DVP2: Disputes due to the frequent changes .922 DVP3: No incidences of trade union agitation .845 DVP4: Dispute resolution meetings .788 EVP1: Project has led to air pollution. .884 EVP2: Increased solid waste. .855 EVP3: Utilised environmentally friendly technology. .826 EVP4: Project has led to depletion natural resources. .810 QVP1: Right material was used for the construction work.

.933

QVP2: A sound QMS adhered to. .919 QVP3: Workers were trained on positive attitudes .911 SVP1: Accidents were reported. .835 SVP2: Fatalities did occur. .783 SVP3: Near misses occurred. .726

Eigenvalue 4.128 3.854 3.705 3.045 3.031 1.953

Percentage of variance explained 15.289 14.275 13.721 11.279 11.225 7.234

Cumulative percentage 15.289 29.564 43.285 54.564 65.789 73.023 Extraction Method: Principal Component Analysis. Rotation Method: Varimax with Kaiser Normalization. Rotation converged in 6 iterations.

Kaiser-Meyer-Olkin Measure of Sampling Adequacy=0.69, Bartlett’s Test of Sphericity=4137.533, Significance =0.000

79

From the analysis, it is evident that seven variables loaded under factor 1 seem to be

associated with project time performance. The second factor comprises six variables

which reflect the cost dimension of project performance. The four variables under

factor 3 represent construction project performance relating to site disputes whereas

the three variables under factor 4 attempt to capture environmental impact dimension

of project performance. The three variables under factor 5 are associated with project

quality and the remaining three variables that load on factor 6 reflect safety of a

project.

The above table reveals that ‘Time performance factor’ is the most important measure

of construction project performance, having the highest eigenvalue of 4.128 and

accounting for 15.289% of the variance in the dataset. This is followed by the measure

‘Cost performance factor’ with an eigenvalue of 3.854 which explains 14.275% of the

total variance. The third most important performance measure was found to be ‘site

disputes factor’ with an eigenvalue of 3.705 and explaining 13.721% of the variance

while the fourth important measure turns out to be ‘Environmental impact factor’ with

an eigenvalue of 3.045 and contributing to 11.279% of the total variance. The last

two performance measures in order of importance were ‘Quality performance factor’

and ‘Safety performance factor’ with an eigenvalue of 3.031 and 1.953 respectively.

The variance explained by these two factors is 11.225% and 7.234% respectively.

These six constructs of performance constitute the KPIs of CDF construction projects.

5.3.4 Validation of the KPIs

5.3.4.1 Reliability of KPIs scale: Reliability of the scale comprising KPIs was

established through Cronbach’s alpha coefficient which tested internal consistency of

the items. The 27- item scale had a reliability of 0.817 (standardised value of 0.808)

which is well above 0.70 recommended for similar studies (Hair et.al. 2006; Malhotra

and Dash, 2011). The Cronbach’s alpha coefficient for each factor was as follows:

Time performance measure: 0.867; Cost performance measure: 0.869; Site Disputes

measure: 0.917; Quality performance measure: 0.916; Safety performance measure:

0.699; and Environmental Impact measure: 0.875. This demonstrates that the factors

extracted from the analysis are considered adequate in the performance measurement

of CDF construction projects.

80

5.3.4.2 Content validity: The content validity of the instrument measuring KPIs was

achieved while designing the survey instrument. This was carried out through

extensive literature review followed by securing opinions from the experts comprising

academics and practitioners through in-depth interviews. This is discussed in detail in

section 4.3.

5.3.4.3 Convergent and Discriminant validity: In order to assess the convergent and

discriminant validity of the 27-item scale, the researcher made use of the correlation

matrix provided in table 5.9. The inter-item correlation of the scale had a mean of

0.100, while the smallest inter-item correlation within each performance measure are

as follows: Time performance factor: 0.100, Cost performance factor: 0.280, Site

Disputes factor: 0.573, Environmental Impact factor: 0.438, Quality performance

factor:0.875 and Safety performance factor: 0.338. These correlations are significantly

greater than zero (p<0.000), providing evidence for convergent validity.

To assess discriminant validity, the correlates under each factor in the correlation

matrix were counted to find out the number of times they had higher correlations with

items of other factors than items of its own factor in the correlation matrix. For

discriminant validity to be present, the count should be less than one half of the

potential comparisons (Wang et al., 2007). Examination of the correlation matrix in

table 5.9 reveals that there are 88 violations of discriminant validity out of 378

possible comparisons. Further, promax rotation of factors resulted in low correlations

amongst the factors, an indication of the presence of discriminant validity. The

statistical results show that the variables that loaded under each of the factors

adequately explained the same, i.e. had high convergence. Similarly, each factor was

distinct as evidenced by the correlations.

81

Table 5.9: Correlation matrix of performance measurement variables after grouping according to factor analysis TPV

1 TPV2

TPV3

TPV4

TPV5

TPV6

TPV7

CPV1

CPV2

CPV3

CPV4

CPV5

CPV6

DPV1

DPV2

DPV3

DPV4

EPV1

EPV2

EPV3

EPV4

QPV1

QPV2

QPV3

SPV1

SPV2

SPV3

TVP1 1 TVP2 .62 1 TVP3 .73 .66 1 TVP4 .77 .57 .45 1 TVP5 .56 .57 .53 .47 1 TVP6 .41 .52 .43 .44 .19 1 TVP7 .40 .32 .43 .30 .64 .10 1 CVP1 .23 .19 .13 .30 .28 -.03 .01 1 CVP2 .18 .01 .04 .21 -.04 -.07 -.16 .75 1 CVP3 .24 .20 .09 .34 .29 -.04 .04 .81 .74 1 CVP4 .14 .01 .07 .16 .17 -.11 -.05 .87 .68 .70 1 CVP5 -.23 -.18 -.16 -.09 -.26 -.08 -.11 .35 .40 .30 .28 1 CVP6 .10 .22 .15 .18 .21 .13 .12 .42 .26 .45 .33 .52 1 DVP1 -.19 -.06 .00 .02 .13 -.08 .32 -.15 -.27 -.05 -.15 .24 .34 1 DVP2 -.17 -.01 .04 .03 .21 -.04 .36 -.08 -.25 .01 -.08 .17 .31 .92 1 DVP3 -.11 .03 .00 .10 .22 -.03 .28 .13 .05 .25 .11 .25 .65 .75 .72 1 DVP4 -.07 -.15 -.02 .03 -.01 -.13 .18 .07 .06 .16 .09 .25 .19 .77 .69 .57 1 EVP1 -.14 -.12 .02 -.00 -.05 -.17 .05 -.07 .03 -.04 -.11 .05 .09 .20 .15 .21 .11 1 EVP2 -.25 -.12 .00 -.12 -.15 -.24 .12 -.05 .13 -.05 -.03 .13 .04 .21 .16 .20 .12 .62 1 EVP3 -.07 -.03 .04 .07 -.03 -.04 .10 -.06 -.00 .00 -.11 .01 .05 .18 .12 .20 .11 .86 .54 1 EVP4 -.17 -.10 .06 -.05 -.06 -.30 .16 .04 .18 .02 .02 .16 .13 .23 .18 .24 .12 .57 .79 .44 1

QVP1 .08 .12 .08 .10 .15 .12 .17 .02 -.09 .00 -.01 -.03 .09 .01 .07 .03 -.09 -.01 -.07 .04 -.06 1 QVP2 -.01 .02 -.02 .02 -.02 .06 .08 -.07 -.08 -.05 -.07 .00 .08 .00 -.01 .02 -.09 -.06 -.04 -.05 -.09 .52 1 QVP3 .05 .04 .01 .05 .07 .01 .21 -.01 -.03 .01 -.03 .08 .04 .05 .08 -.02 -.01 .03 .05 .07 -.03 .45 .34 1 SVP1 .19 .04 .26 .12 .27 -.11 -.05 .46 .37 .33 .44 .08 .27* -.08 -.04 .11 .02 .05 -.04 -.02 .07 .01 -.06 -.09 1 SVP2 .18 .05 .29 .08 .23 -.12 -.01 .40 .33 .30 .39 .10 .36 .02 .04 .22 .11 .07 .02 .02 .12 -.03 -.06 -.11 .92 1 SVP3 .24 .06 .28 .16 .29 -.06 -.03 .49 .39 .34 .46 .07 .29 -.06 -.02 .15 .06 -.02 -.12 -.08 .00 .04 -.05 -.11 .92 .88 1

Correlation coefficient and p values are as follows: ρ > 0.15 denotes p-value <0.05 or significant at 5% level; ρ > 0.20 denotes p-value <0.01; or significant at 1% level. KMO= 0.692, Bartlett test of sphericity: 4137, Significance: 000 Note; Shaded areas represent variables grouped together by factor analysis

82

5.3.5 Theoretical Framework of KPIs

KPIs determined through factor analysis of performance variables and validated

through appropriate tests enabled the researcher to develop a theoretical framework of

construction project performance linking the performance metrics and overall project

performance. This is shown in figure 5.7.

Figure 5.7: Proposed theoretical framework of key performance indicators

(KPIs)

This framework (figure 5.7) demonstrates that the project performance can be

described in terms of Time variables (TY1 ...TY6), Cost variables (CY1…CY6),

Quality variables (QY1….QY5), Safety variables (SY1...SY3), variables relating to

Site disputes (DY1 ...DY6) and Environmental impact (EY1…EY4). A brief

description of the factors constituting the above variables is given below.

Factor 1 represents Time performance measure

Time performance measure, as shown in table 5.8, is considered to be the most

important factor amongst all six constructs. In this construct, the highest loading is

83

observed in “timely delivery of project resources” (0.862) while the lowest one is

found in “at handover there were no apparent defects (0.572). Theoretically, the

variable “at handover there were no apparent defects” should have been loaded under

Quality performance measure but results of factor analysis reveal that it loaded under

Time performance measure. A closer look at the survey instrument indicates that the

respondents perceived defects in project to be a quality-related attribute but this

ultimately leads to delay in project handover and consequently its use. This might be

the possible reason why the above variable loaded under Time performance measure.

Similarly, the item “Harmonious relationship on site” is widely thought to be

associated with disputes during construction. In the current study, this item loaded on

time. The respondents perceive disharmony at workplace giving rise to disruptions of

work that eventually lead to delay in certain activities of the project. Lim and

Mohamed (2000) considered project completion time to be the first criterion for

project success. Other researchers (Kamrul and Indra, 2010; Khosravi and Afshari,

2011) have termed time to be the most important factor in the performance

measurement of construction projects. CDF projects, being community based, utmost

importance is given to time dimension because the funding of these projects is always

done annually based on its progressive performance.

Factor 2 represents Cost performance measure

As mentioned earlier, this factor is considered the second most important performance

measure of CDF projects. The highest loading is observed in “Equipment at budgeted

rates” (0.875) as revealed in Table 5.8. The table, further, shows that the variable

“adversely affected the quality of groundwater level”, loaded on this factor with a

loading of 0.586 despite it being reflective of environmental impact measure. This

implies that the project stakeholders would require more resources to minimise the

negative impact of the project on groundwater level thereby leading to an escalation

in project cost. Another variable “no financial claims at completion” loaded on cost

performance measure with a loading of 0.508, which theoretically should have loaded

under ‘Site Disputes’. However, this variable seems to have financial implications on

the project in terms of penalties and interests that would accrue to the project

implementing body. Construction cost has been identified as an important measure of

84

performance in almost all studies relating to the performance of construction projects

(Chan and Chan, 2004; Zou et al., 2007; Kaliba et al., 2008). In their study, Khosravi

and Afshari (2011) ranked cost as the second most important measure of project

performance. The current study puts much emphasis on regular monitoring of CDF

projects with a view to finding out how the funds allocated to a construction project

are spent.

Factor 3 represents Site Disputes measure

This factor comes third in order of explaining the variance in the dataset. The variable

‘no serious disputes on the project’ had the highest loading of 0.951 on this factor

while the variable ‘dispute resolution meetings’ was found to have the least loading

(0.788). Project stakeholders have the responsibility to minimise disputes amongst

themselves and formulate strategies to govern their relationships during project

construction. David (2009) and Tabish and Jha (2011) have observed that project

performance measurement should also consider the level of work related disputes

encountered during construction and after. According to Abidin (2007), construction

disputes are common and could have serious implications on performance of

construction projects. CDF construction projects are characterized by many

stakeholders whose relationships are likely to create disputes. These disputes, if not

checked, could derail project construction and hinder attainment of project objectives.

Factor 4 represents Environmental Impact measure

This factor comes fourth in order of the total amount of variance explained by the

same. The variable “the project has led to air pollution in the adjoining areas” had the

highest loading (0.884) on this factor while the variable “the project has led to the

depletion of natural resources” had the least loading (0.810). Chan and Chan (2004)

reported that environmental issues in construction have become a global concern and

therefore, should be considered an integral part of construction. A few other

researchers (Gangolells et al., 2009; Medineckiene et al., 2010; Shen et al., 2010;

Chen et al., 2010; Tan et al., 2011) have also acknowledged the importance of

environmental impact in the performance of construction projects. All construction

projects should address environmental issues for the purpose of achieving sustainable

development.

85

Factor 5 represents Quality performance measure

Though this factor was ranked the second least amongst six performance measures, it

is indispensable in the performance evaluation of CDF projects. The highest loading

for this factor was found on “right material was used for the construction work”

(0.933) while the item “workers were trained on positive attitude and methods” had

the lowest loading (0.911). The inclusion of quality in the performance measurement

of construction projects has been reported by several researchers including Jha & Iyer

(2006), Palaneeswaran et al. (2007), Ogano and Pretrius (2010), Love et al. (2010)

and Yung and Yip (2010). This measure of project performance was, however, ranked

third by Khosravi and Afshari (2011) in their study of success measurement amongst

power plant, utility and cogeneration construction projects. Chan and Chan (2004)

observed that quality is an important measure of project performance because it

constitutes the guarantee that the project will serve its purpose. Poor quality in

projects results in numerous reworks which unnecessarily undermine other project

performance indicators. Supervision of project quality is, therefore, the most

important activity which needs to be undertaken by all project stakeholders.

Factor 6 represents Safety performance measure

This factor comes last in order of its explanatory power of explaining the total

variance. The highest loading of this factor is observed on “accidents were often

reported” (0.835) and the least one is associated with “near misses occurred” (0.726).

Chan and Chan (2004) acknowledged the role of safety in construction and stated that

it is important for all project stakeholders to ensure that there are no accidents during

the entire construction period. Haslam et al. (2005), Billy et al. (2006) and Zuo (2011)

indicated that project safety should always be considered due to the risky nature of

construction activities when evaluating the performance of construction facilities. It is

important for every project organisation to focus on safety during construction

because if accidents occur, both contractors and clients may be subject to legal claims,

financial loss and delay in the overall completion of construction project.

86

5.4 Exploratory Factor Analysis (EFA) of project success variables for Critical

Success Factors (CSFs) Scale

In this section, the same dataset containing 175 responses was utilized to carry out

EFA on the success variables in order to identify the CSFs influencing the success of

public sector construction projects. The process followed is described below.

5.4.1 Descriptive statistics of project success variables

The maximum score, minimum score, mean and standard deviation of each of the 30

project success variables was computed in order to find out their importance in

influencing the success of public sector construction projects. Table 5.10 summarises

the descriptive of the above variables.

Table 5.10: Descriptive statistics of project success variables SUCCESS VARIABLES (SV) Mini-

mum Score

Maxi mum Score

Mean Score

Std. Dev

SV1: The location and site conditions did not affect the construction of this project.

1 5 2.98 1.408

SV2: Design complexity of project (type, size, nature and number of floors) has influenced the project cost and time.

1 5 2.90 1.307

SV3: Project planning, Scheduling and control were adequately done on this project

1 5 3.34 1.337

SV4: The client secured necessary funds for the project and hence there were no delays in material acquisition and payments to contractor.

1 5 2.53 1.461

SV5: The client got the design documents approved on time for this project.

1 5 2.82 1.356

SV6: The client had adequate experience on similar kind of projects.

1 5 2.27 1.452

SV7: Information sharing and collaboration among project participants were adequate in the current project.

1 5 2.90 1.123

SV8: The construction work adhered to the requisite Quality standards.

1 5 2.90 1.298

SV9: Continuous monitoring of actual expenditures and project time and their comparison with the budget and schedules was done regularly.

1 5 3.00 1.208

SV10: There was a formal organization structure for dispute resolution within the project organization.

1 5 3.02 1.259

SV11: Site Managers possessed requisite skills necessary for the kind of projects executed.

1 5 3.18 1.232

SV12: The contractor had adequate technical skills and experience on similar type of projects.

1 5 3.33 1.214

SV13: The contractor used latest construction methods in the project.

1 5 3.51 1.372

SV14: The community did not raise any social, political or cultural 1 5 3.02 1.293

87

issues against construction of the current project.

SV15: The project execution was adversely affected by the surrounding weather and climatic conditions.

1 5 3.26 1.114

SV16: Macro- economic conditions (such as interest rates, inflation) did not significantly affect the execution of this project.

1 5 3.38 1.226

SV17: The project was affected by the Governance policy of the relevant government agencies which affects project success.

1 5 3.24 1.213

SV18: The consultant was highly committed to ensuring construction work according to design specifications.

1 5 2.78 1.343

SV19: There were adequate drawings, design specifications and documentations for the use of contractor.

1 5 2.81 1.284

SV20: The client emphasized on completing the current project very fast without any reference to quality.

1 5 2.38 1.367

SV21: The client tended to purchase construction materials at cheaper rate which led to the dilution of other project objectives.

1 5 2.28 1.449

SV22: No variations in original design took place in the current project during construction phase.

1 5 2.49 1.245

SV23: The level of technological sophistication considered in the project was satisfactory.

1 5 3.32 1.250

SV24: There were no incidences of disagreements resulting from industrial relations prevailing at the time of project implementation.

1 5 3.34 1.038

SV25: The physical and ecological conditions surrounding the project were favourable to project execution.

1 5 3.31 1.082

SV26:There were very few internal procurement challenges 1 5 3.37 .985 SV27: The client’s decisions were timely and objective. 1 5 3.45 1.148 SV28: Right equipments were available in the construction site of this project.

1 5 3.47 .921

SV29: The project faced stringent insurance and warranty contractual requirements.

1 5 3.33 1.215

SV30: Working capital was adequate. 2 5 4.10 .736

From Table 5.10 it can be observed that the minimum score among the variables was

1 whereas the maximum was 5. Only one project success variable “working capital

was adequate” had a minimum score above 1. However, the highest score on all the

project success variables was 5. These scores indicate that the respondents used the

entire 5 point survey scale, implying adequate variability amongst the responses. The

highest mean score was 4.10 (Working capital was adequate) while the lowest was

2.27 (adequate experience on similar projects). This indicates that all the project

success variables were important as evidenced by high mean scores (above 2.25) for

majority of the project success variables. All the values of standard deviations were

found to be above 1 except in two variables; “few internal procurement challenges”

(0.985) and “working capital was adequate” (0.736). These values are relatively

close to 1 and hence they varied considerably amongst the respondents.

88

5.4.2 Assessing the factorability of project success variables

Assessment of factorability of project success variables was done based on correlation

matrix shown in Table 5.11. It was observed that the correlation matrix had a chi-

square value of 5466.934 and significant level of .000 based on Bartlett’s sphericity

test. This suggested that inter-correlation matrix contained sufficient common

variance to allow for factor analysis. Similarly, the KMO value for the entire matrix

was found to be above the suggested threshold of 0.500 (Hair et al., 2006).

However, observation of the anti image correlation matrix revealed that three success

variables had individual KMO values below 0.5, which indicated that the dataset, in

its current form, was still not suitable for factor analysis (Hair et al., 2006). These

values were sequentially eliminated one after another, starting with the one whose

KMO value was lowest, until 27-item scale with an overall KMO value of 0.802 and

individual KMO value of at least 0.5 was obtained for each item.

89

Table 5.11: Original Correlation Matrix of project success variables SV

1 SV 2

SV 3

SV 4

SV 5

SV 6

SV 7

SV 8

SV 9

SV 10

SV 11

SV 12

SV 13

SV 14

SV 15

SV 16

SV 17

SV 18

SV 19

SV 20

SV 21

SV 22

SV 23

SV 24

SV 25

SV 26

SV 27

SV 28

SV 29

SV 30

SV1 1 SV2 .72 1 SV3 .61 .62 1 SV4 .30 .44 .17 1 SV5 .16 .24 .11 .79 1 SV6 .32 .44 .25 .88 .67 1 SV7 .69 .69 .51 .31 .17 .29 1 SV8 .72 .99 .63 .45 .25 .45 .69 1 SV9 .69 .88 .56 .37 .21 .39 .63 .87 1 SV10 .70 .89 .55 .40 .26 .40 .65 .88 .82 1 SV11 .32 .21 .08 .10 .06 .10 .15 .20 .22 .16 1 SV12 .01 .02 -.12 .04 -.01 .02 -.08 .02 .00 -.07 .71 1 SV13 .46 .41 .35 -.04 -.08 .01 .27 .41 .39 .39 .63 .31 1 SV14 -.24 -.25 -.09 .06 .05 .10 -.13 -.25 -.27 -.25 .06 .22 -.15 1 SV15 -.07 -.15 -.01 .22 .09 .25 .00 -.14 -.16 -.19 -.01 .08 -.11 .73 1 SV16 -.12 -.13 -.03 .03 .00 .09 -.04 -.14 -.17 -.15 .06 .18 -.11 .74 .53 1 SV17 -.14 -.15 .03 -.02 -.08 -.03 .06 -.15 -.15 -.16 -.07 .06 -.23 .62 .68 .45 1 SV18 .21 .28 -.04 .29 .26 .24 .34 .27 .28 .33 .38 .17 .20 -.00 -.15 .03 -.14 1 SV19 .15 .22 .06 .34 .33 .40 .23 .21 .22 .28 .20 .07 .00 .07 -.05 .07 -.15 .51 1 SV20 .31 .44 .25 .77 .62 .90 .32 .44 .38 .41 .08 -.01 .04 .09 .22 .07 -.00 .25 .38 1 SV21 .33 .48 .25 .87 .66 .99 .32 .48 .41 .44 .12 .04 .03 .10 .24 .09 -.02 .26 .42 .91 1 SV22 .25 .31 .12 .44 .37 .50 .33 .29 .25 .37 .13 -.03 -.08 .17 .02 .15 -.06 .56 .78 .48 .52 1 SV23 -.10 -.19 -.12 .04 .05 .04 .03 -.18 -.19 -.17 -.36 -.31 -.15 .38 .48 .25 .30 -.20 -.09 .09 .04 .00 1 SV24 -.15 -.12 -.06 .28 .28 .28 -.05 -.11 -.11 -.12 -.11 -.03 -.23 .47 .39 .29 .34 .04 .06 .26 .27 .15 .72 1 SV25 -.26 -.30 .03 -.12 -.07 -.13 .07 -.30 -.27 -.30 -.32 -.17 -.24 .54 .53 .37 .57 -.19 -.11 -.07 -.12 -.16 .64 .53 1 SV26 .14 .22 .26 -.13 -.10 -.06 .16 .21 .21 .23 .03 -.14 .31 -.13 -.13 -.16 -.17 .26 .12 -.03 -.06 -.01 -.11 -.13 .07 1 SV27 -.06 -.04 -.16 -.09 -.03 -.12 -.10 -.05 -.05 -.02 .02 -.03 .04 -.05 -.05 -.05 -.04 .05 .01 -.10 -.11 -.00 -.02 -.01 -.06 .03 1 SV28 .18 .20 .16 -.12 -.10 -.07 .16 .19 .19 .20 .07 -.09 .28 -.14 -.19 -.15 -.21 .27 .14 -.05 -.06 .01 -.13 -.17 -.01 .85 .04 1 SV29 .15 .21 .33 -.23 -.22 -.19 .26 .20 .22 .23 .01 -.18 .38 -.08 -.06 -.04 -.05 .24 -.01 -.15 -.18 -.11 -.06 -.11 .22 .72 .05 .57 1 SV30 .01 .01 .00 .05 .03 .01 -.00 .01 -.01 .04 .00 .00 .03 -.04 -.03 -.03 -.00 .07 .04 -.06 -.01 .05 -.02 -.02 -.06 -.05 .19 .01 -.05 1 Correlation coefficient and p values are as follows: ρ > 0.15 denotes p-value <0.05 or significant at 5% level; ρ > 0.20 denotes p-value <0.01; or significant at 1% level Overall measure of sampling adequacy: 0.771, Bartlett test of sphericity: 5466.934, Significance: 000

90

5.4.3 Factor Analysis following Varimax Rotation

Having established that factor analysis could be applied on the 27 project success

variables, principal component analysis (PCA) was employed with varimax rotation

in order to identify the underlying structure of relationships. Due to lack of a priori

basis on the number of factors to be extracted, initially all 27 variables were allowed

to load freely on various factors so long as they had eigenvalue greater than one.

Further a scree plot for different components was obtained (as shown in figure 5.8) in

order to have an idea about the amount of variance explained by each factor.

Figure 5.8: Scree Plot of project success factors

91

Observation of the shape of the scree plot generated (Figure 5.8) revealed that six

factors could adequately capture variance amongst the success variables. While

conducting factor analysis, the process was subjected to the four conditions as

discussed in section 5.3.3 beforehand (page 78)

During factor analysis, all success variables loaded appropriately based on the four

conditions (already mentioned in section 5.3.3) which yielded a 6-factor 27-item

instrument, accounting for 78.510% of the variance in the dataset. In this study,

factors were named as Project related, Client related, Environment related, Supply

chain related, Consultant related and Contractor related factor. Table 5.12

summarizes the factor loadings for the 27-item instrument and the labelling of those

items, i.e project success variables.

The factor analysis results shown in table 5.12 reveal that ‘Project Related Factor’ is

the most important construct of project success having the highest eigenvalue of 5.606

and accounting for 20.763% of the variance in the data set. This is followed by `Client

Related Factor’ with an eigenvalue of 4.490, which explains 16.630% of the total

variance. The third most important critical success factor is found to be ‘External

environment Related Factor’ with an eigenvalue of 3.775 and explaining 13.983%`of

the variance while the fourth important factor turns out to be ‘Supply Chain Related

Factor’ with an eigenvalue of 2.673 and contributing to 9.900% of the total variance.

The last two CSFs in order of importance are ‘Consultant Related Factor’ and

‘Contractor Related Factor’ with an eigenvalue 2.335 and 2.298 respectively and the

variance explained of 8.722% and 8.511% respectively. The six factors extracted

indicate different dimensions of success amongst CDF construction projects. The

significant loadings of all the items on a single factor indicate unidimensionality while

the absence of cross loading items supports discriminant validity of the instrument.

92

Table 5.12: Results of the Factor Analysis of project success variables Component

1 2 3 4 5 6 Cronbach’s alpha (α) 0.945 0.954 0.868 0.869 0.826 0.780

PSV1: Influence of design complexity. .895 PSV2: Adhered to the requisite Quality standards. .893 PSV3: Continuous monitoring of actual expenditures. .844 PSV4: Formal dispute resolution structures. .842 PSV5: Effect of location and Site conditions. .818 PSV6: Adequate information sharing and collaboration.

.797

PSV7: Adequate project planning and, scheduling. .749 CSV1: Adequate experience on similar projects. .911 CSV2: Cheap materials were used. .896 CSV3: Project funds secured on time. .882 CSV4: Client’s emphasis on time rather than quality. .855 CSV5: Design documents approved on time. .797 ESV1: Community had no issues against the project. .873 ESV2: Adversely affected by the surrounding weather. .828 ESV3: Effect of the Governance policy. .815 ESV4: Favourable physical and ecological conditions. .759 ESV5: Effect of macro- economic conditions. .736 ESV6: No incidences industrial unrests. .552 LSV1: Few internal procurement challenges .932 LSV2: Right equipments were available. .858 LSV3: Effect of stringent insurance/warranty rules .806 SSV1: No variations were incorporated. .841 SSV2: Adequate designs/specifications and documentations.

.829

SSV3: Adequate commitment of consultant to the project.

.728

RSV1: Site Managers possessed requisite skills. .914 RSV2: Contractor had adequate technical skills. .857 RSV3: Contractor used latest construction methods. .647

Eigenvalue 5.606 4.490 3.775 2.673 2.335 2.298

Percentage of variance explained 20.763 16.630 13.983 9.900 8.722 8.8511

Cumulative percentage 20.763 37.394 51.376 61.277 69.999 78.510 Extraction Method: Principal Component Analysis. Rotation Method: Varimax with Kaiser Normalization. Rotation converged in 6 iterations. Kaiser-Meyer-Olkin Measure of Sampling Adequacy=0.802. Bartlett's Test of Sphericity=5117.857 Significance =0.000

93

5.4.4 Validation of the CSFs

5.4.4.1 Reliability of CSFs scale: The 27- item CSFs scale had a reliability coefficient

of 0.846 which is above the recommended value of 0.70 (Hair et.al. 2006; Malhotra &

Dash 2011). The Cronbach’s alpha coefficient for each factor was as follows: Project

related factor=0.945; Client related factor= 0.954; Consultant related factor=0.826;

Contractor related factor=0.780; Supply chain related factor=0.826; and

Environmental related factor=0.868. This demonstrates that the factors extracted from

the analysis are considered adequate in the successful implementation of CDF

construction projects.

5.4.4.2 Content validity: The content validity of the instrument measuring CSFs was

achieved while designing the survey instrument. This was carried out through

extensive literature review followed by securing opinions from the experts comprising

academics and practitioners through in-depth interviews and the pilot survey amongst

30 representative respondents. This is discussed in detail in the Research

Methodology section (Chapter 4, section 4.3), page 50.

5.4.4.3 Construct validity: In order to assess construct validity, it was important to

examine convergent and discriminant validity of the 27-item scale, based on the

correlation matrix provided in Table 5.13. The inter-item correlation of the scale had a

mean of 0.176, while the smallest inter-item correlations within each success factor

are as follows: Project related factor=0.51, Client related factor= 0.62, Consultant

related factor=0.51, Contractor related factor=0.31, Supply chain related factor=0.57

and Environmental factor=0.29. These correlations are significantly greater than zero

(p<0.000) providing evidence for convergent validity and large enough to warrant

discriminant validity.

Further, the correlates under each factor in the correlation matrix in table 5.13 were

counted to assess the discriminant validity as described in section 5.3.4.3 (page 81).

It was found that there were 12 violations of discriminant validity out of 378 possible

comparisons. This indicates the presence of adequate discriminant validity.

94

Table 5.13: Correlation matrix of project success variables after grouping according to factor analysis PS

V1 PS V2

PS V3

PS V4

PS V5

PS V6

PS V7

CS V1

CS V2

CS V3

CS V4

CS V5

ES V1

ES V2

ES V3

ES V4

ES V5

ES V6

LS V1

LS V2

LS V3

SS V1

SS V2

SS V3

RS V1

RS V2

RS V3

PSV1 1 PSV2 .99 1 PSV3 .88 .87 1 PSV4 .89 .88 .82 1 PSV5 .72 .72 .69 .70 1 PSV6 .69 .69 .63 .65 .69 1 PSV7 .62 .63 .56 .55 .61 .51 1 CSV1 .44 .45 .39 .41 .32 .29 .25 1 CSV2 .48 .48 .41 .44 .33 .32 .25 .99 1 CSV3 .44 .45 .37 .40 .30 .31 .17 .88 .87 1 CSV4 .44 .44 .38 .41 .31 .32 .25 .90 .91 .77 1 CSV5 .24 .25 .21 .26 .16 .17 .11 .67 .66 .79 .62 1 ESV1 -.25 -.25 -.27 -.25 -.24 -.13 -.09 .10 .10 .06 .09 .05 1 ESV2 -.15 -.14 -.16 -.19 -.07 .00 -.01 .25 .24 .22 .22 .09 .73 1 ESV3 -.15 -.15 -.15 -.16 -.14 .06 .03 -.03 -.02 -.02 -.00 -.08 .62 .68 1 ESV4 -.30 -.30 -.27 -.30 -.26 .07 .03 -.13 -.12 -.12 -.07 -.07 .54 .53 .57 1 ESV5 -.13 -.14 -.17 -.15 -.12 -.04 -.03 .09 .09 .03 .07 .00 .74 .53 .45 .37 1 ESV6 -.12 -.11 -.11 -.12 -.15 -.04 -.06 .28 .27 .28 .26 .28 .47 .39 .34 .53 .29 1 LSV1 .22 .21 .21 .23 .14 .16 .26 -.06 -.06 -.13 -.03 -.10 -.13 -.13 -.17 .07 -.16 -.13 1 LSV2 .20 .19 .19 .20 .18 .16 .17 -.07 -.06 -.12 -.05 -.10 -.14 -.19 -.21 -.01 -.15 -.17 .85 1 LSV3 .21 .20 .22 .23 .15 .26 .33 -.19 -.18 -.23 -.15 -.22 -.08 -.06 -.05 .22 -.04 -.11 .72 .57 1 SSV1 .31 .29 .25 .37 .24 .33 .12 .50 .52 .44 .48 .37 .17 .02 -.06 -.16 .15 .15 -.01 .01 -.11 1 SSV2 .22 .21 .22 .28 .15 .22 .06 .40 .42 .34 .38 .33 .07 -.05 -.15 -.11 .07 .06 .12 .14 -.01 .78 1 SSV3 .28 .27 .28 .33 .21 .34 -.04 .24 .26 .29 .25 .26 -.00 -.15 -.14 -.19 .03 .04 .26 .27 .24 .57 .51 1 RSV1 .21 .20 .22 .16 .32 .15 .08 .10 .12 .10 .08 .06 .06 -.01 -.07 -.32 .06 -.11 .03 .07 .01 .13 .20 .38 1 RSV2 .02 .02 .00 -.07 .01 -.08 -.12 .02 .04 .04 -.01 -.01 .22 .08 .06 -.17 .18 -.03 -.14 -.09 -.18 -.03 .06 .17 .71 1 RSV3 .41 .41 .39 .39 .46 .27 .35 .01 .03 -.04 .04 -.08 -.15 -.11 -.23 -.24 -.11 -.23 .31 .28 .38 -.08 .00 .20 .63 .31 1

Correlation coefficient and p values are as follows: ρ > 0.15 denotes p-value <0.05 or significant at 5% level; ρ > 0.20 denotes p-value <0.01; or significant at 1% level Kaiser-Meyer-Olkin Measure of Sampling Adequacy=0.802. Bartlett's Test of Sphericity=5117.857, Significance =0.000

95

5.4.5 Theoretical Framework of CSFs

CSFs determined through factor analysis of success variables of Public sector

construction projects and validated through appropriate tests facilitated development

of a theoretical framework linking the CSFs to project success. This is demonstrated

in Figure 5.9.

Figure 5.9: Proposed theoretical framework of critical success factors (CSFs)

This framework (Figure 5.9) demonstrates the CSFs namely project related factor

(PSV1………..PSV7), Client related factor (CSV1.....CSV5), Consultant related factor

(SSV1……..SSV3), Contractor related factor (RSV1……….RSV3), Supply chain

related factor (LSV1.......LSV3) and External environment related factor

(ESV1………..ESV6) influence the success of public sector construction projects.

The findings so obtained and the validation process followed provide evidence to the

fact that the six CSFs influence success of public sector construction projects and that

the project success scale is appropriate for determination of successful completion of

96

construction projects. Identifying CSFs is important as it allows firms to focus their

efforts on building their capabilities to meet the CSFs. A brief description of the CSFs

extracted is given below.

Factor 1: Project related factor

Project related factor as shown in Table 5.12 is the most important factor than the

other five CSFs amongst CDF construction projects in Western province, Kenya. This

shows that all stakeholders involved in the construction of CDF projects consider

characteristics of the project itself to be significant in the successful implementation

of construction projects. The findings reveal that this particular factor captures the

unique characteristic features of the project not covered by any other factors. Seven

project characteristics were found to load on this factor as indicated in the factor

analysis results. The results reveal that the highest loading is found in “Influence of

Design Complexity” (0.895), while the lowest one is observed in “Adequate Project

planning and scheduling” (0.749). This emphasises the importance of project design

in determining the success of construction projects.

Factor 2: Client related factor

This factor is ranked second amongst six factors. The highest factor loading is

observed in “Client had adequate experience on similar projects” (0.911) whereas the

least is found in “Design documents were approved on time” (0.797). Owner

interference in terms of change or variation in orders and imposition of unrealistic

contract conditions affect project success (Murali, 2007; Sweis et.al, 2007). The

construction process starts with the client realizing the need for a construction product

(a constructed facility) which could be in the form of a new building or refurbishment

of an existing facility. Therefore, the client will give the direction that the project will

follow in terms of its construction.

Factor 3: External environment related factor

External environment related factor is the third ranking factor. “Community did not

raise issues against the project” had the highest loading of 0.873 while the lowest

loading was found in “No incidences of disagreements resulting from industrial

relations” (0.552). Litsikakis (2009) argues that external environment is said to be

the combination of ecological, political, economic, socio-cultural and technological

97

(EPEST) context in which the project is executed. Long et al. (2004) recommended

that as an immediate check, project stakeholders could simply examine the project

environment and make a subjective assessment of the potential success of their

projects. According to the provisions in the CDF act (2003), CDF construction

projects in a particular constituency are identified by the community based on their

needs after considering economic, social and ecological environment prevailing in the

same region.

Factor 4: Supply chain related factor

Three variables loaded on the fourth component namely supply chain related factor:

few internal procurement challenges (0.932), right equipments were available (0.858)

and effect of stringent insurance/warranty rules (0.806). According to Vrijheof and

Koskela, (2000), the concept of Supply Chain Management (SCM) is used to analyze,

reengineer, coordinate, and constantly improve construction supply chain. This leads

to efficiency in construction through reduction of lead-time and inventory held by an

organization. Koushiki et al. (2005) and Ahsan and Gunawan (2000) emphasised the

need for an effective procurement system in project construction in order to improve

performance. Similarly, shortage of skilled manpower, delay in material delivery and

modifications in material specifications (Sweis et.al, 2007), labour supply and labour

productivity (Murali and Yau, 2007) affect project success. Therefore, the flow of

materials, labour and equipment in the site has a significant bearing on the pace and

quality of the construction work.

Factor 5: Consultant related factor

This factor, regarded as consultant related factor, ranked fifth amongst the success

factors. Of all the variables, “no variations were incorporated” had the highest

loading (0.841) while “the consultant was highly committed to project construction”

had the lowest loading (0.729). Consultants are responsible for advising the client and

contractor at various stages of the construction project especially on necessary

changes and variations. Accordingly the client and contractor take a pragmatic

decision on incorporating necessary modifications into the construction projects (Al-

Tmeemy et.al, 2011; Ahadzie et.al, 2008; Chan and Kumaraswamy, 1997). All

98

construction work take place based on the designs provided by the consultants. Hence

it is important to consider consultant related factor.

Factor 6: Contractor related factor

Though this component is ranked least amongst the six components, it is

indispensable in contributing success to construction projects. The highest loading is

observed on the “Site Managers possessed requisite skills” (0.914) and the least

loading is found on the “Contractor used latest construction methods” (0.647).

Murali and Yau (2007) found that contractor related factor significantly contributes to

time overrun in an organisation. Al-Kharashi and Skitmore (2008) found that

contractor performance is important when determining overall project performance.

Construction contractors undertake construction work in accordance with the

prescribed technical, managerial and contract specifications as stipulated by the CDF

act (2003). It is, therefore, important to consider their technical and managerial

capabilities in project construction.

5.5 Conceptual framework of project performance evaluation

Project success and overall project performance constructs were assessed for

nomological validity in order to develop a conceptual framework of project

performance evaluation. Nomological validity of a construct is the degree to which a

construct behaves as it should within a system of related constructs called a

nomological net (Hair et al., 2006). In reference to performance evaluation of

construction projects, literature reveals that the two concepts, project success and

project performance have been used interchangeably. However, a few researchers

have been able to differentiate them on the basis of their focus within a performance

evaluation framework. Barclay and Osei-Bryson (2010) reported that because of

stakeholders’ vested interests in the activities and outcome of the project, project

success would be viewed differently by different stakeholders, but project

performance is based on how well the outcome of the project are attained. Similarly,

Shenhar (2001) affirms that different stakeholder interests lead to different

perceptions of success and how the project performed. Further, Cooke-Davies (2002)

argue that CSFs are the necessary factors that influence project success whereas

overall project performance reflects the extent to which the project has been

99

successful. According to Takim and Akintoye (2002), project success is affected by

CSFs based on various managerial activities, whereas project performance refers to

the extent to which the various project outputs have been attained. The focus of

project success is, therefore, on construction management whereas project

performance relates to the measurement of project outcomes in terms of various

performance indicators.

Because the previous analyses indicate that there are relationships between CSFs and

project success and relationships between overall project performance and the KPIs,

the researcher predicted positive relations between project success and overall project

performance. Theoretically, there exists an association between overall project

performance and project success. This pattern of relations is one part of the

nomological net permitting the researcher to test an objective measure of overall

project performance and the factors that influence project success. Thus a

performance evaluation framework is conceptualised for public sector construction

projects as shown in figure 5.10.

Influence Predicted through

Influences In terms of

Mediated through

Figure 5.10: Conceptualised relationship between project success and overall project performance

In the performance evaluation framework (figure 5.10), six CSFs namely project

related, client related, consultant related, contractor related and supply chain related

factors influence project success both directly and through external environment.

Critical Success factors ( ) Project related Client related Consultant related Contractor related Supply chain related

Key Performance indicators Project cost Project time Project quality Project safety Site disputes Environmental

impact

External Environment

Social Economic Ecological

Overall Project performance

Project success

100

Besides the mediation role, external environment related factor also influences project

success. Further, the framework shows that project success is predicted through overall

project performance in terms of six KPIs namely project cost, project time, project

quality, project safety, site disputes and environmental impact.

101

CHAPTER 6: RESEARCH METHODOLOGY (PHASE II):

CONFIRMATORY STUDY

6.0 Introduction

Data collected in the first phase was examined, tabulated and analysed through EFA.

The outcome of phase I of the study provided two different measurement scales: one

consisting of 27- performance measurement variables for KPIs scale and the other

with 27-project success variables for CSFs scale. The measurement scales of both

KPIs and CSFs were further examined and confirmed by administering the scale to a

different set of respondents. This necessitated a confirmatory study.

6.1 Key Issues

This confirmatory phase of the study aims at

Examine the extent of differences in the occurrence of cost overrun, time

overrun and quality defects across different types of construction projects

(Educational, Healthcare, Industrial Estates and Agricultural Markets).

Examine the association between the project procurement approaches followed

in public sector construction projects and occurrence of cost overrun, time

overrun and quality defects.

Examine the association between stakeholders’ (client, consultant and

contractor) experience in construction projects and occurrence of cost overrun,

time overrun and quality defects.

To confirm the KPIs identified in the exploratory study and examine the

association between the confirmed KPIs and overall project performance.

To confirm the CSFs identified in the exploratory study and examine the

influence of the confirmed CSFs on project success.

To examine the association between overall project performance and project

success.

102

6.2 Theoretical framework and Statement of Hypotheses for performance

evaluation of public sector construction projects

Based on the key issues mentioned in section 6.1 as well as the conceptual framework

developed in Chapter 5 (Figure 5.10), the following relationships are hypothesized for

performance assessment of public sector construction projects (Figure 6.1).

Figure 6.1: Hypothesized performance assessment model for public sector

construction projects

It is hypothesized that CSFs have positive influence on project success. Accordingly,

six CSFs proposed were project-related, client-related, consultant-related,

contractor-related, supply chain-related and external environment-related factors.

Besides having a direct influence on project success, it has been hypothesized that

external environment related factor mediates the influence of the remaining five CSFs

103

on project success. Further, there is an association between project success and overall

project performance which is related to six KPIs namely time, cost, quality, safety,

site disputes and environmental impact.

Project construction is a complex activity that requires proper coordination of efforts

by various participants in a systematic manner (Chan, Scott & Chan, 2004; Long,

Ogunlana, Quang & Lam, 2004; Murali & Yau, 2007). One must identify the factors

that are crucial to the success of a project and put in efforts in building capabilities to

meet the success factors. The project related factor reflects the characteristics of a

project which include project design, site conditions and project management

procedures. Favourable project conditions will lead to its success. Public sector

construction projects are unique in terms of their sizes (Kerzner, 2006; Pheng &

Chuan, 2006), complexity (Kerzner, 2006) and type (Chan & Chan, 2004; Fortune &

White, 2006) which present a big challenge to many contractors. Therefore, project

related factor provide a basis upon which other decisions relevant to the project can be

made regarding construction activities. These activities eventually influence project

success.

Hypothesis 1a: Project related factor has a positive influence on the success of

public sector construction projects.

The construction process starts with the client realising the need for a construction

product which could be in the form of a new building or refurbishment of an existing

facility. Client related factor refers to the client related activities which includes

giving direction to the project implementing agencies in terms of construction related

activities. These include client’s experience and how the client executes his/her role

on the project during construction, e.g. material procurement and approval of designs.

The client is central to project implementation because he involves himself in

selecting a suitable contractor/s and constantly supervises the progress of the

construction work. The nature and type of the client (whether belonging to public or

private sector), the clarity of the project mission, the competency of the client in terms

of his ability to brief, make decisions, and define roles have been found to

significantly affect the performance of the client. Project financing is vital in the

performance of construction projects (Koushki et al., 2005; Kaliba et al., 2009), which

104

is arranged by the client. Client’s financial position and experience would most likely

determine the kind of materials, labour and equipment to be used for construction.

According to Walker (1995), the influence of the client or client’s representative

contribute significantly to the performance of construction projects. This viewpoint is

supported by Pheng and Chuan (2006), who argued that poor project performance

cannot be attributed to any other party to construction but the client itself. They

emphasized that “clients’ actions before, during and after the project can affect the

performance of a project.” Given the various advantages of active client participation

in construction, lack of client involvement can lead to poor performance of

construction projects on many metrics including cost, time, quality and conflicts

(Fortune & White, 2006; Toor & Ogunlana, 2006). Therefore, for successful project

performance, the clients must play an active role at all phases of project construction

(Blyth & Worthington, 2001; Pheng & Chuan, 2006). Client’s knowledge, confidence

and experience with different types of projects exert significant influence on the

success of public sector construction projects.

Hypothesis 1b: Client related factor has a positive influence on the success of public

sector construction projects.

Consultants are responsible for advising the client and contractor at various stages of

the construction project especially on necessary changes and variations. Therefore,

consultant related factor such as the experience and commitment of consultants

significantly affect project performance. In many occasions, the consultant (architect

or engineer) acts as the project coordinator. His or her role is to design the works,

prepare the specifications, produce construction drawings, administer the contract,

tender the works, and manage the works from inception to completion

(Ratnasabapathy, 2008). The detailed drawings also include the specifications of

construction materials on the basis of which materials are procured from vendors. In

addition, the consultant also prepares detailed documents of project design and

provides the same to the contractor which serves as guidelines in construction work

(Saqib et al, 2008; Kaliba et al, 2009; Alwaer & Clements-Croome, 2010). In project

performance literature, issues such as complexity of designs and the accompanying

105

documents have been cited to influence the success of a project (Long et al., 2004;

Alwaer & Clements-Croome, 2010).

Hypothesis 1c: Consultant related factor has a positive influence on the success of

public sector construction projects.

In many developing countries, contractors are usually private firms or individuals who

undertake construction of a project under certain terms and conditions as prescribed

by the client while agreeing to comply with the design and specifications provided by

the consultant. Construction contractors undertake the construction work in

accordance with the prescribed technical, managerial and contract specifications

(Wang & Huang, 2006), which essentially influence the success of construction

projects. According to Alzahrani and Emsley (2013), contractors play an important

role in the realisation of quality of a construction project through their workmanship

and conformance to specifications. Respondents surveyed in their study reported that

contractors had a great impact on achieving success in their project. Chua et al. (1999)

while focusing on contractor related factor, identified capability of contractor key

personnel, competency of contractor proposed team, contractor team turnover rate,

contractor top management support and contractor track record as having a significant

effect on overall project success. Inadequate contractor experience, improper planning

and poor site management by contractor, problems with subcontractors affect success

of public sector construction projects.

Hypothesis 1d: Contractor related factor has a positive influence on the success of

public sector construction projects.

Acquiring the necessary labour force, tools, material and equipment is important in

project construction. This ensures that workers are always engaged, thereby,

enhancing worker productivity and construction efficiency (Pheng & Chuan, 2006),

because materials and supplies of a project have an important impact on the

productivity and the success of a project

In relation to project construction, supply chain related factor consists of all the

construction business processes, from the demands placed by the client, regarding

conception, design and construction to maintenance, replacement and eventual

decommission of building, and organizations (Xue, Wang, Shen, & Yu, 2007). They

106

include procurement challenges in respect of material, equipment and labour. Many

construction organizations have adopted supply chain management (SCM) practices

to facilitate movement of materials, labour and equipment within the organization.

SCM play major roles in construction by ensuring availability of construction

resources at the right cost, right time and the right quality, thereby, coordinating and

integrating the construction processes. According to Vrijhoef and Koskela, (2000)

SCM also seeks to minimise logistics costs and decrease lead-time and inventory

across the supply chain. Azhar et al. (2002) in their study concluded that “supply

chain management (SCM) has a great potential in the construction industry in

reducing cost and time thereby improving its profitability. Specifically, a construction

supply chain (CSC) leads to efficient coordination that addresses problems of high

fragmentation, low productivity, cost and time overrun and conflicts, and eventually

leads to attainment of project success. However, supply chain process in the

construction industry is extremely dynamic due to frequent changes in the design and

plans of construction projects (Tae-Hong, Sangyoon, Su-Won & Soon-Wook, 2011).

Therefore, despite great potential SCM in construction projects, Segersted and

Olofsson, (2010) argue that organizations are still unable to realise all project

objectives. Unless project resources arrive at the right time and right place, achieving

success of a construction project becomes very difficult.

Hypothesis 1e: Supply chain related factor has a positive influence on the success of

public sector construction projects.

The construction industry is considered to be the backbone of many economies. Its

uniqueness throughout the world is determined by the external environment in which

it operates. By nature, construction projects are exposed to various factors arising out

of their external environment. This requires that decisions and risks associated with

various projects should, therefore, incorporate the effect of environment factor in a

project. Enshassi, Mohamed and Ekarriri (2009) emphasize that contractors should

consider political and business environment risks while estimating project costs and

schedule because improper planning for these risks could lead to delays and cost

escalation because of closures due to materials shortages. Pheng and Chuan (2006)

categorised project environment into two groups: immediate environment and

107

external environment. The immediate environment refers to the investors, customers,

suppliers, consultants and contractors. This environment is more or less specific to a

project. The external environment of a project includes social, political, technological,

legal and economic factors and their implications on the project. Litsikakis (2009) and

Saqib et al. (2008) argue that external environment can be said to be the combination

of ecological, political, economic, socio-cultural and technological (EPEST) context

in which the project is executed. Long et al. (2004) recommended that as an

immediate check, project stakeholders could simply examine the project environment

and make a subjective assessment of the effect of environment on project success.

Whereas these environments are dynamic, their impact will certainly influence project

success.

Hypothesis 1f: External Environment related factor has a positive influence on the

success of public sector construction projects.

The operating environment of projects is characterised by high degree of uncertainty

and complexity, when compared to the operating environment of general business

operations. Same types of projects in different environments are likely to differ in

their performance due to varying economic, political, social and ecological

environments. Environmental effects are sometimes said to be indirect since they

have to combine with some other characteristics in the project environment.

Therefore, external environment interferes with project related factor and is assumed

to play a significant role in mediating the influence of project related factor on project

success.

Hypothesis 2a: External environment mediates the influence of project related factor

on the success of public sector construction projects.

Every government has certain environmental regulations for construction projects

which every client must adhere to while undertaking construction. While designing a

construction project for a particular location, the consultant has to keep in mind the

ecological and political environments of that location and accordingly has to comply

with the statutory guidelines for designing the project. He should design such projects

which will minimize environmental degradation, avoid depletion of raw materials and

encourage the use of environmentally friendly methods (Ding, 2005; Tsoulfas &

108

Pappis, 2008; Ortiz, Castells, & Sonnemann, 2009; Tan et al., 2011) within statutory

government regulations. In every country, government provides environmental codes

to guide construction of new projects (Ngowi, 2001; Tsoulfas & Pappis, 2008; Ortiz

et al., 2009; Tan et al., 2011) which the contractors are expected to comply with. Thus

it is observed that although the activities of client, consultant and contractor have

direct influence on project success, these three broad stakeholders have to operate in a

specific environment in which the project is undertaken. These stakeholders are

required to comply with the environmental codes and regulations. Environmental

factor combines with client related, consultant related and contractor related factors

and is considered to mediate the influence of these factors on project success.

Hypothesis 2b: External environment mediates the influence of client related factor

on the success of public sector construction projects.

Hypothesis 2c: External environment mediates the influence of consultant related

factor on the success of public sector construction projects.

Hypothesis 2d: External environment mediates the influence of contractor related

factor on the success of public sector construction projects.

Further, the materials, labour and equipment used in construction come from the

environment. Similarly the funding agencies involved in provision of resources in the

construction projects are political institutions whose interests are part of the political

environment. Because of this, the environment plays an important role in the

construction process in terms of uninterrupted supply of inputs (Shen et al., 2010).

According to Briscoe and Dainty (2005), the interplay between the external

environment and supply chains affect the overall project success.

Hypothesis 2e: External environment mediates the influence of supply chain related

factor on the success of public sector construction projects.

Project success and overall project performance are two concepts in project

management literature that have been used interchangeably. Whereas project success

is assessed on the basis of management effort to complete the project, performance is

a comparison of project outcomes against the objectives of the project. According to

Cooke-Davies (2002), a project performance criterion provides a benchmark upon

which success or failure of a project is measured whereas success factors are

109

management inputs and systems that would lead to project success. Therefore, project

success is reflected through overall project performance on KPIs. Previously,

Westerveld (2002) attempted to link success criteria (overall projects performance)

and success factors. He explained that such a link was necessary as it would enable

project implementing agencies to manage project progress towards attaining success

and monitor overall project performance. It can, therefore, be hypothesised that;

Hypothesis 3 Overall project performance is positively associated with the success of

public sector construction projects.

The cost construct the cost of project resources and the extra cost incurred due to the

project construction. A project will be considered to have performed well if it is

completed within the budgeted cost (Chan et al., 2004; Long et al., 2004). According

to Azhar et al. (2008), cost is amongst the major considerations throughout project life

cycle and can be regarded as one of the most important parameters of a project and

driving force to overall project performance. Further, Memon et al. (2012) report that

cost is one of the fundamental dimension upon which project performance is assessed

during construction. Failure to address project cost during construction has been

reported to lead to negative effect on the project (Ali & Kamaruzzaman 2010). It is on

this basis that many organizations have attempted to develop approaches that could

help in control of project costs. However, Olawale and Sun (2010) have argued that

despite the availability of control techniques and project control software, many

project organizations are still unable to achieve cost objectives. This is reflected

through poor performance of construction projects. Therefore, a project is considered

to have performed well in terms of cost when overall performance is satisfactory.

Hypothesis 4a: Cost performance is positively associated with the overall

performance of public sector construction projects.

Every project is planned to take a specified time based on its characteristics and the

number of activities involved. All these activities must be undertaken within the time

frame if the project objectives are to be realised. It is the desire of project stakeholders

to complete the project within the scheduled time (Kamrul & Indra, 2010; Williams,

2003).The time construct focuses on resource delivery schedules, timely availability

of funds, ability to monitor actual progress of activities against the planned ones in

110

view of conflict and ever changing weather conditions. Although most of these

processes have been automated, projects still experience time overrun (Oluwale &

Sun 2010). Time overrun affects delivery of intended services to the beneficiaries and,

therefore, has a bearing on overall project performance (Memon et al., 2012, Bon-

Gang, Xianbo, & Si Yi, 2013). Alternatively, a project achieves a satisfactory

progress on time performance when overall project performance turns out to be

adequate.

Hypothesis 4b: Time performance is positively associated with the overall

performance of public sector construction projects.

The quality construct measures the extent to which the final project matches the

specifications set out at its inception. It is mainly concerned with the adherence of the

project to the prescribed quality standards and is measured in terms of reworks that

are necessary in order to meet requisite quality standards (Jha & Iyer, 2006; Ogano &

Pretorius, 2010). Palaneeswaran, Ramanathan and Tam (2007) emphasized the

importance of quality in construction projects when they concluded that uncontrolled

rework occurrence in construction projects have serious impact on overall project

performance. According to Hamad and Sangwon (2013), because of multiplicity of

causes, defects can have significant effect on performance of a construction project.

Further, Love et al. (2010) stated that compliance with quality specifications is an

important performance measure of any construction project.

Hypothesis 4c: Quality performance is positively associated with the overall

performance of public sector construction projects.

Borvorn (2011) reports that occurrence of disputes on construction project sites have

been found to proliferate in the construction industry resulting in drawbacks and

disharmonization in the completion of construction projects. Therefore, while

considering overall project performance, it is important to consider the site disputes

construct in order to establish whether there were work disruptions during project

construction due to the issues affecting the interest of community. The project site

should remain free from disputes (David, 2009; Tabish & Jha, 2011). According to

the American Bar Association, if construction disputes are not resolved in time, they

become very expensive in terms of finances, personnel, time, and opportunity costs.

111

Because of this, there is need to avoid and resolve such disputes if the project

objectives are to be realised (Skene & Shaban, 2002). Al-Momani (2000) suggested

that there is need for special attention to the main causes of project delay in order to

avoid contract disputes. However, Cheung et al. (2000) argues that since resolving

disputes has become part of routine management functions in an organisation, dispute

resolution satisfaction should be considered as a significant measure of overall project

performance since it impacts on the attainment of project objectives.

Hypothesis 4d: Occurrence of Site disputes is negatively associated with the overall

performance of public sector construction projects.

The safety construct evaluates the incidences of fatalities and accidents at the

construction site. Some of the factors that contribute to poor safety performance in the

construction industry in developing countries are a largely unskilled labour force,

harsh operative environments due to lack of necessary equipment and strenuous

physical tasks necessary within the construction sector. Yakubu and Bakri (2013)

reported that a construction process is risky with frequent occurrences of injuries and

illness due to poor safety. They attribute the increase in the rate of accidents to

increased allocation to the construction sector owing to the importance of the sector in

national development. Accidents in the construction sites may lead to stoppage of

work thereby lowering staff morale and eventually lead to a negative impact on the

productivity. The contemporary findings (Ortega, 2000; Haslam et al., 2005; Billy et

al., 2006) suggest that safety should be accorded high priority. Further, safety is

considered a priority for contractors because their employees are exposed to great risk

during the construction phase of the project (Saqib et al., 2008). It is, therefore,

important to consider safety of the project while assessing performance of public

sector construction projects.

Hypothesis 4e: Safety performance is positively associated with the overall

performance of public sector construction projects.

The environmental impact construct evaluates the extent to which the project

construction affects the environment surrounding it and the future sustainability of the

constructed facility. According to Gangolells et al. (2009), a project organization

should incorporate environmental analysis in the entire project construction process.

112

The emphasis is on the impact of the project on the surrounding physical and

ecological environment (Ding, 2005; Shen et al., 2005). Alba et al. (2013) report that

though considerable effort has been made towards reducing the negative

environmental impact of construction processes, construction sites are still a major

source of pollution. These problems undermine the realisation of the benefits of

public sector construction projects.

Hypothesis 4f: Environmental impact of a project is negatively associated with the

overall performance of public sector construction projects.

6.3 Process followed in Research Methodology (Phase II)

The process followed in carrying out research in phase II is depicted in Figure 6.2.

Administer the questionnaire to different set of respondents (Survey Phase II)

Assess Measurement models Assess Structural Model (Hypotheses testing) - using SEM: Confirmatory Factor Analysis & Path Analysis

Figure 6.2: Sequence of research followed in Study Phase II

6.4 Design of Survey Instrument

Based on the findings of exploratory study (phase I), the researcher conceptualized

construction project performance evaluation framework as encompassing six different

Scale Purification and Model Testing

PHASE II:

CONFIRMATORY

PHASE

Data Collection II

Outcome of Study in Phase I-27-performance measurement variables for KPIs scale

-27-project success variables for CSFs scale

Expected Outcome: -Measurement Model for KPIs scale

-Measurement model for CSFs scale

-Structural Equation model (SEM) exhibiting the relationship between

CSFs, project success, overall project performance and KPIs.

113

dimensions of KPIs namely time, cost, quality, site disputes, safety and environmental

impact as well as six CSFs, project related, client related, consultant related,

contractor related, supply chain related and external environment related factors.

Each KPI and CSF had a number of items that loaded on it as shown in the

exploratory phase (Phase I).

The Questionnaire had three sections. The first section of the questionnaire contained

questions relating to the demographic information of the respondents and

characteristics of the project. Section B contained questions pertaining to 27

performance measurement variables of the KPIs scale, whereas section C had

questions pertaining to 27 project success variables of the CSFs scale. In the last two

sections (section B and C) a five-point Likert scale was used as a response format for

different variables with the assigned values ranging from 1 = Strongly Disagree to 5 =

strongly Agree. These two sections were intended to secure respondent perceptions

regarding performance measurement variables and project success variables

respectively on the basis of a specific project they had been involved in. The

questionnaire containing revised items was further checked for inconsistencies and

clarity in the way they were framed.

6.5 Study site and identification of target Population

The study site for the confirmatory study (phase II) is the same as discussed in section

4.5 of chapter 4. This site had 922 original respondents out of which 196 respondents

had already been covered in the exploratory study (Phase I). These 196 respondents

were excluded from 922 thereby reducing the target population to 726. This

population contained all the three strata of respondents required for this study. Given

that this population was relatively small, a decision was made to consider all the 726

respondents in the Study. This was, therefore, a census study. The researcher put in

maximum efforts to collect data from all the three strata in the population.

6.6 Data Collection

The purpose of data collection in the study in phase II was to facilitate analysis so as

to confirm the identified performance variables for the KPIs scale and the identified

success variables for the CSFs scale. The 24 research assistants who had been

involved in data collection in phase I of the study were again requested to collect data

114

in the phase II, directly from clients, consultants and contractors. Given that they had

already been trained, the researcher felt that they were familiar with the data

collection instrument and its administration. Based on prior arrangement, the field

investigators conducted face to face interviews with respondents.

This survey was undertaken from the first week of August, 2012 through the end of

October, 2012. At the end of the period lasting 12 weeks, data was summarised, ready

for analysis.

115

CHAPTER 7: RESEARCH FINDINGS AND DISCUSSION (PHASE II-

CONFIRMATORY STUDY)

7.0 Introduction

This chapter discusses the results of confirmatory factor analysis (CFA) and tests of

hypotheses. It presents a brief overview of the responses received and describes the

process of data screening employed. It is followed by a description of projects’

characteristics, status of the CDF projects and respondents’ profile. The chapter also

presents the results of both ANOVA and Chi-Square tests conducted to examine the

associations of project characteristics and respondents’ demographic profiles with the

occurrence of time overrun, cost overrun and quality defects among public sector

construction projects. The next section reports on the CFA of KPIs and CSFs. The last

sub section reports the results of Structural Equation Modelling (SEM) and the tests

of hypotheses.

7.1 Screening of collected data

At the end of eleven weeks, the field investigators were able to submit 227 completed

questionnaires, out of which 16 questionnaires were found either incomplete or

improperly filled. Thus the total number of effective response came out to be 211,

indicating a valid response rate of 22.9%. Once the data was received, it was checked

for missing values, inconsistency and negatively framed responses. The scores on

negatively framed questions were suitably reversed and all the scores were fed into

SPSS software (version 20). Given below is an overview of the demographic profile

of the projects and respondents and the related descriptive statistics. Finally the results

of CFA carried out through AMOS software (version 20.0) are presented. Maximum

Likelihood estimation (MLE) method was employed for carrying out CFA.

7.2 Demographic characteristics of respondents and projects

This section gives an overview of project characteristics and respondents’

demographic profile. It also reports on the status of CDF projects surveyed in terms of

the cost overrun, time overrun and quality defects. Further it tests the relationships

between project types as well as project procurement approaches used and the

occurrence of cost overrun, time overrun and quality defects amongst CDF

construction projects. The objectives of this sub-section are

116

• To examine the extent of differences in the occurrence of cost overrun, time

overrun, and quality defects across different types of construction projects.

• To examine the association between the project procurement approaches

followed in public sector construction projects and the occurrence of cost

overrun, time overrun and quality defects.

• To examine the association between stakeholders’ (client, consultant and

contractor) experience in construction projects and the occurrence of cost

overrun, time overrun and quality defects.

7.2.1 Project characteristics and brief profile of the respondents

Projects are described in terms of the type of projects, procurement approaches

followed in projects and the value of the projects. Further, the respondents are

classified on the basis of years of experience in construction projects and value of

projects they have worked on in the last 3 years. Table 7.1 summarises the project

characteristics and respondents’ demographic profile.

Table 7.1 Project characteristics and brief profile of the respondents Responses

Variable Educational

facilities

Health

Care

Industrial

Estate

Agricultural

Market

Total

Respondent group

Clients 46 (44.2%) 31(29.8%) 12 (11.5%) 15 (14.4%) 104

Consultants 16 (32.7%) 11(22.4%) 8 (16.3%) 14 (28.6%) 49

Contractors 16 (27.6%) 22(37.9%) 7 (12.1%) 13 (22.4%) 58

Respondents’ Experience in Construction projects

Below 3 years 9 (24.3%) 15(40.8%) 4 (10.8%) 9 (24.3%) 37

3-6 years 39 (38.2%) 33 (324%) 15 (14.7%) 15 (14.7%) 102

7and above 30 (41.7%) 16(22.2%) 8 (11.1%) 18 (25.0%) 72

Procurement approaches followed in respondents’ project

Design/Bid/Build 0 (0.0%) 1(100.0%) 0 (0.0%) 0 (0.0%) 1

Design/Build 3 (15.0%) 9 (45.0%) 1 (5.0%) 7 (35.0%) 20

Competitive bid 33 (42.9%) 15(19.5%) 10 (13.0%) 19 (24.7%) 77

Negotiated gen.

Contract 42 (37.2%) 39(34.5%) 16 (14.2%) 16 (14.2%) 113

Value of CDF projects worked on in the last 3 years in Ksh.

> 15,000,000 24 (44.4%) 14(25.9%) 4 (7.4%) 12 (22.2%) 54

10,000,000-

15,000,000 19 (37.3%) 13(25.5%) 9 (17.6%) 10 (19.6%) 51

< 10,000,000 35 (33.0%) 37(34.9%) 14 (13.2%) 20 (18.9%) 106

TOTAL 78 64 27 42 211

117

A preliminary analysis of the data revealed that the sample was fairly balanced in

terms of the type of the projects and provided a fair representation of cross sectoral

distribution of CDF construction projects. A total of 78 projects (37.0%) in the sample

were Educational whereas 64 (30.3%) projects were related to Health Care, 27

(12.8%) related to Agricultural Markets, and 42 (19.9%) fell under Industrial Estates.

However, majority of these projects were small with an average value of less than

ksh. 10,000,000.

The most common project procurement method among CDF construction projects

was negotiated general contracts (53.55%), followed by competitive bid (36.49%).

This was again followed by design/build 20, (9.48%). Only one project (0.5%) was

procured through design/bid/build method.

With regard to the respondents, 104 (49.3%) were clients whereas 49 (23.2%) were

consultants and 58 (27.5%) were contractors. On average, respondents had experience

of 3-6 years in construction industry and majority had been involved in the

construction of CDF projects for over 3 years. This information indicates that apart

from having adequate experience in terms of years the respondents have been

involved in construction projects, respondents had handled projects of different sizes.

7.2.2 Status of CDF construction projects

This section describes the incidences of occurrence of cost overrun, time overrun and

quality defects amongst CDF construction projects surveyed in this study. The status

of different types of projects is presented in Table 7.2.

The findings in the table indicate that 184 amongst 211 projects surveyed (87.2%) in

this study experienced time overrun ranging from less than six months to more than

12 months. However, much of the delay was for less than 6 months (62.1%). The

table shows the magnitude of time overrun across all four kinds of projects and

reveals that the proportion of time overrun was maximum amongst Agricultural

Markets (approx. 90.5%) and minimum amongst Educational projects (84.6%).

118

Table 7.2: Incidences of time overrun, cost overrun and quality defects Project classification

Incidences Variable Educational Health

Care

Industrial

Estate

Agricultural

Market

Total

Time

overrun on

respond-

ents’

project

None 13 (48.1%) 7 (25.9%) 3 (11.1%) 4 (14.8%) 27

< 6 months 51 (38.9%) 39 (29.8%) 15 (11.5%) 26 (19.8%) 131

6-12 months

> 12 months

10 (25.6%)

4 (28.6%)

12 (30.8%)

6 (42.9%)

8 (20.5%)

1 (7.1%)

9 (23.1%)

3 (21.4%)

39

14

Cost overrun

on

respondents’

project in

Ksh

None 44 (38.6%) 30 (26.3%) 14 (12.3%) 26 (22.8%) 114

< .100,000 19 (30.2%) 26 (41.3%) 8 (12.7%) 10 (15.9%) 63

100,001-

300,000 13 (48.1%) 4 (14.8%) 5 (18.5%) 5 (18.5%)

27

> 300,000 2 (28.6%) 4 (57.1%) 0 (0.0%) 1 (14.3%) 7

Percentage

of Quality

defects on

project

None 53 (39.8%) 38 (28.6%) 20 (15.0%) 22 (16.6%) 133

Less than 20% 21 (30.9%) 23 (33.8%) 6 (8.8%) 18 (26.5%) 68

20% and more 4 (40.0%) 3 (30.0%) 1 (10.0%) 2 (20.0%) 10

TOTAL 78 64 27 42 211

In this table, 97 out of 211 projects surveyed (46%) incurred cost overrun during their

implementation in the range of less than Ksh. 100,000 to Ksh.300, 000. While

considering cost over-run across the types of projects, the table further indicates that

the same was maximum (53.1%) in case of Health Care Facilities and minimum

(38.1%) in case of Agricultural Markets. In addition, 43.6% of Educational projects

and 48.1% of Industrial Estates experienced cost over-run.

In the current study, 133 projects (63.0%) were found to have been free from apparent

defects with only 10 projects (4.7%) recording quality defects of 20% or more. Of

those projects that suffered from quality defects, majority were Health Care projects

(26) followed by Educational (25), Agricultural Markets (20) and finally Industrial

Estates (7).

119

7.2.3 Relationships amongst project characteristics, respondents’ profile and

incidences of time overrun, cost overrun and quality defects

This section reports on the comparisons of groups of responses for differences in their

means regarding project characteristics, respondents’ profile and incidences of time

overrun, cost overrun and quality defects.

7.2.3.1 The extent of differences in the occurrence of time overrun, cost overrun

and quality defects across different types of construction projects

In order to examine any significant differences in respect of time overrun, cost

overrun and quality defects across different types of projects namely Educational,

Healthcare facilities, Industrial Estates and Agricultural Markets, a one way Analysis

of Variance (ANOVA) was carried out. The results are presented in the following

tables.

Table 7.3: Results of ANOVA test between the types of projects and time

overrun, cost overrun and quality defects

Project status Source of variation

Sum of Squares

Df Mean Square

F Sig.

Time overrun Between Groups 1.949 3 .650 1.196 .312

Within Groups 112.468 207 .543

Total 114.417 210

Cost overrun Between Groups .748 3 .249 .361 .781

Within Groups 142.996 207 .691

Total 143.744 210

Quality defects Between Groups .176 3 .059 .191 .903

Within Groups 63.493 207 .307

Total 63.668 210

With regard to the differences in time overrun across different types of projects, the

ANOVA results indicate that the significance level is 0.312 (p=.312). Since this value

is above 0.05, there is no statistically significant difference in the occurrence of time

overrun among different types of CDF construction projects. This implies that the

occurrence of time overrun was similar amongst all types of construction projects.

120

ANOVA results on the occurrence of cost overrun across different types of

construction projects revealed a significance level of 0.781 (p=.781) which indicates

that there is no statistically significant difference in the occurrence of cost overrun

across four types of projects surveyed.

Further, quality defects were examined to find out whether it differed significantly

across different types of construction projects. It was found that the significance level

is 0.903 (p = .903), which again indicates that there is no statistically significant

difference in the occurrence of quality defects across the four types of projects

constructed.

7.2.3.2 The association between the project procurement approaches used and the

occurrence of time overrun, cost overrun and quality defects amongst public sector

construction projects

To identify the association between project procurement approaches used and the chi-

square test of independence (also known as Pearson’s chi-square test or chi-square

test of association) was employed. The results are presented in the Table 7.4.

Table 7.4: Results of the Chi-square test between project procurement

approaches and time overrun, cost overrun and quality defects

Project status Test statistic Value df Asymp. Sig. (2-sided)

Time overrun Pearson Chi-Square 7.545 9 .581

Likelihood Ratio 8.961 9 .441

Linear-by-Linear Association .029 1 .864

N of Valid Cases 211

Cost overrun Pearson Chi-Square 20.161 9 .017

Likelihood Ratio 23.130 9 .006

Linear-by-Linear Association .449 1 .503

N of Valid Cases 211

Quality defects Pearson Chi-Square 8.744 6 .188

Likelihood Ratio 9.201 6 .163

Linear-by-Linear Association .008 1 .927

N of Valid Cases 211

121

The association between procurement approach and time overrun show that the

probability (p) of the chi-square test statistic (chi-square value of 7.545) at 9 degrees

of freedom turned out to be 0.581. This being greater than the alpha level of

significance of 0.05, implies that the occurrence of time overrun on CDF construction

projects has no statistically significant association with the procurement method used.

This implies that the occurrence of time overrun on CDF construction projects does

not depend on the kind of method employed in procuring the project.

Similarly, a Chi square test to examine the association between procurement approach

and the occurrence of cost overrun revealed that the probability (p) of the chi square

statistic (chi-square=20.161) at 9 degrees of freedom came out to be 0.017 (p=.0.017).

This being less than the alpha level significance of 0.05 indicates that the occurrence

of cost overrun on CDF construction projects has a statistically significant association

with the procurement method used. Therefore, cost overrun would depend on the

project procurement method used.

The Chi-square test of the relationship between project procurement approaches and

occurrence of quality defects show that the probability (p) of the chi square statistic

(chi-square=8.744) at 6 degrees of freedom is 0.188. This being more than the alpha

level significance of 0.05 indicates that the occurrence of quality defects on CDF

construction projects has no statistically significant association with the procurement

method used. Therefore, the occurrence of quality defects does not depend on the

project procurement method used in securing project contractors and consultants.

Given that the result of Chi-square test between procurements approaches and cost

overrun was significant, a post hoc procedure was conducted to determine which

frequencies differed. The results are represented in Table 7.5.

122

Table 7.5: Post hoc Chi Square tests between procurement approach used and

occurrence of cost overrun

Cost overrun

PROCUREMENT APPROACHES

None Less than Ksh.100,000

Ksh.100,001-Ksh.300,000

Ksh.300,001-Ksh. 500,000

Total

Design/Bid/Build Count 0 1 0 0 1 Residual -.5 .7 -.1 .0 Std. Residual -.7 1.3 -.4 -.2

Design/Build Count 12 8 0 0 20 Residual 1.2 2.0 -2.6 -.7 Std. Residual .4 .8 -1.6 -.8

Competitive bid Count 38 29 5 5 77 Residual -3.6 6.0 -4.9 2.4 Std. Residual -.6 1.3 -1.5 1.5

Negotiated general contract

Count 64 25 22 2 113 Residual 2.9 -8.7 7.5 -1.7 Std. Residual .4 -1.5 2.0 -.9

TOTAL 114 63 27 7 211

Table 7.5 shows that for the Design/Bid/Build approach, three cells were under-

represented while one cell was over-represented. Similarly two cells, were under-

represented and two others over- represented for the remaining approaches namely

Design/Build, Competitive bid and Negotiated general contracts. However, all the

cells were significant except the one representing Negotiated general contract and

Ksh. 100,000-Ksh. 300,000. This is because the value of standardised residuals was

less than 1.96, the critical z-value corresponding to 0.05, alpha level of significance.

Therefore, the occurrence of cost overrun depended on the project procurement

method.

7.2.3.3 The association between respondents’ experience in construction projects

and occurrence of time overrun, cost overrun and quality defects

To examine the association between respondents’ experience and the occurrence of

time overrun, cost overrun and quality defects, a chi square test of association was

used. The results are presented in the Table 7.6.

123

Table 7.6: Results of the Chi-square test between respondents’ experience and time overrun, cost overrun and quality defects

Project status Test statistic Value Df Asymp. Sig. (2-sided)

Time overrun Pearson Chi-Square 6.781 6 .342

Likelihood Ratio 9.539 6 .145

Linear-by-Linear

Association .002 1 .961

N of Valid Cases 211

Cost overrun Pearson Chi-Square 7.690 6 .262

Likelihood Ratio 9.323 6 .156

Linear-by-Linear

Association .063 1 .802

N of Valid Cases 211

Quality defects Pearson Chi-Square 2.412 4 .661

Likelihood Ratio 2.364 4 .669

Linear-by-Linear

Association .888 1 .346

N of Valid Cases 211

For time overrun, the probability (p) of the chi-square test statistic (chi-square value

of 6.781) at 6 degrees of freedom represented was 0.342. This indicates that there is

no statistically significant association between respondents’ experience and time

overrun. Therefore, the number of years that a stakeholder has been involved in the

project construction sector does not have influence on the extent of time overrun

amongst construction projects.

A test of whether cost overrun is associated with the respondents’ experience revealed

that the probability (p) of the chi-square test statistic (chi-square value of 7.690) at 6

degrees of freedom was 0.262. This implies that there is no association between the

extent of cost overrun and respondents’ experience among public sector construction

projects.

Further, the probability (p) of the chi-square test statistic (chi-square value of 2.412)

at 4 degrees of freedom was 0.661. This again being greater than alpha level of

significance of 0.05, indicates that there is no statistically significant association

between respondents’ experience and occurrence of quality defects.

124

7.3 Confirmatory factor analysis (CFA) of performance measurement variables

for KPIs Scale

The study employed a two step CFA approach to confirm and validate the

measurement scale (Wang et al., 2007) with the help of AMOS software (version

20.0). First the performance evaluation model was assessed using the first order CFA.

In the next stage, construction project performance measurement was operationalised

as a second order model (structural model); wherein it is demonstrated that the six

constructs are governed by a higher order construct, namely overall project

performance. Subsequently, the relationship between the higher order construct and

the first order constructs is investigated. The purpose of this analysis is to confirm the

KPIs identified and examine the relationship between the confirmed KPIs and overall

project performance.

7.3.1 Validation of performance measurement variables

In phase II of the study, CFA was used to assess how well the observed variables

reflect unobserved or latent constructs in the hypothesized structure. The results of the

study in Phase I have provided a strong priori basis for the need of carrying out CFA

in evaluating the performance of CDF construction projects. The measurement

properties of the performance evaluation framework were first tested using reliability

and item-to-total correlation analysis followed by CFA (Wang et al., 2007). The

lowest item-to-total correlation was 0.334 while the highest was 0.951. Though the

lowest item-total correlation is slightly below the 0.35 proposed by Saxe and Weitz

(1982 cited in Coursaris et al., 2008), the rest of the total correlations were relatively

high suggesting a reasonable fit of the latent factors to the data collected. The

reliability test and item-to-total correlation analysis results provided in table 7.7

suggest a reasonable fit of the latent factors to the data collected. Cronbach α value

for five of the six factors of performance evaluation are greater than 0.85 with only

one factor, safety, falling below the recommended 0.7, which was, however, just

below 0.6 considered acceptable in exploratory studies (Hair et al., 2006). This

construct was, thus, retained because of its perceived importance in construction

projects. The details are shown in Table 7.7.

125

Table 7.7: Summary of measurement results of Key Performance Indicators

(KPIs) Factors Number

of itemsMean S.D α Range of item-to-

total correlationTime performance (TPV) 7 3.188 1.228 0.882 0.461-0.791

Cost performance (CPV) 6 2.970 1.197 0.855 0.369-0.835

Quality performance (QPV) 3 3.573 1.119 0.959 0.899-0.951

Site Disputes (DPV) 4 2.831 1.255 0.906 0.703-0.906

Safety performance (SPV) 3 3.540 1.128 0.574 0.334-0.462

Environmental Impact (EPV) 4 2.942 1.173 0.869 0.663-0.680

A series of CFA was conducted between each pair of the six factors to assess the

discriminant validity of the factors using the chi-square difference tests (Zhu, Sarkis

& Lai, 2008) as shown in Table 7.8. This process requires that the measurement items

of each pair of factors are forced into a single underlying factor. Discriminant validity

is said to be present if there is a significant drop in the chi-square value of two-factor

model from the same one-factor model. The drop in chi-square values in ten pairs is

very high compared to the same in the remaining five pairs. However, the differences

in these five pairs are also significant and hence discriminant validity is evident. All

the above five pairs are linked to safety construct. Table 7.8 further reveals that this

construct seems to be closer to site disputes. However, the literature suggests that it

should be treated separately (Patrick, 2011).

Table 7.8: Discriminant validity checks: Chi-square differences Factors 1 2 3 4 5

1. Time performance (TPV)

2. Cost performance (CPV) 694.5

3. Quality performance (QPV) 731.3 634.8

4. Site Disputes (DPV) 612.6 596.6 719.1

5. Environmental Impact (EPV) 406.8 418.6 741.1 361.6

6. Safety performance (SPV) 59.2 58.5 60.3 34.0 56.5

7.3.2 First order measurement model of KPIs

In the first order model, the constructs including cost, time, quality, safety, site

disputes and environmental impact are all shown to be correlated forming a project

performance measurement scale. This measurement scale was assessed through CFA

126

utilizing the MLE method. The initial 27 observable items of project performance

were incorporated into the model for testing purposes. These items were evaluated on

the basis of various criteria, including items standardised regression weights, squared

multiple correlations, standardised residual covariances and the modification indices

as well as the reliability of the items and that of the construct as a whole.

Additionally, the researcher also considered the logic and consistency of the sampled

data with the theoretical underpinnings in construction project management.

The initial model proposed for the measurement of construction project performance

indicated poor model fit on all recommended goodness of fit (GOF) indices as

provided in Table 7.9. This necessitated item purification through CFA, thereby

eliminating items based on theoretical reasons and empirical examination (Wang et

al., 2007). To ensure that the data consistently conform to theory, items were deleted

one at a time. The deletion of items are based on whether they differ from existing

theory of project performance evaluation literature, whether there exists strong

conceptual linkages as evidenced by modification indices and standardised multiple

correlations and finally whether they are conflicting in their interpretation. For

instance,

• Variables CPV5: Adverse effect on quality of groundwater level, CPV6: No

financial claims at completion and SPV3: Near misses occurred were

eliminated on the basis of their low regression weights and their squared

multiple correlations values were also the lowest among the 27 variables. The

standardised regression weights (and squared multiple correlations) for these

variables were; CPV5- 0.287 (0.082), CPV6-0.383 (0.147) and SPV3-0.412

(0.170)

• Further, standardized residual covariances were used to eliminate three more

variables TPV5: No effect of weather and climatic conditions, TPV7: At

handover there were no apparent defects and CPV3: No increase in materials

cost. In eliminating these variables, the researcher also considered its

regression weights, squared multiple correlations and estimated error

variances.

127

• Modification indices (M.I) were also instrumental in the pruning EPV4:

Project has led to depletion natural resources, DPV4: Dispute resolution

meetings, TPV4: No delays in securing funds and TPV6: No design changes.

The high modification index between e19 and e21 indicated that there was a

strong relationship between variables EPV2 and EPV4. When these two

variables were compared, it was found that the removal of EPV4 results in a

higher improvement on the model fit hence it was deleted. Similarly, e9 was

found to have high M.I with quality performance, cost performance, e12 and

e10. Further e17 had high M.I with cost performance and so was e10 with cost

performance. This implies that variables TPV6, DPV4 and TPV4 were cross

loading to other constructs. Based on the suggestion by Kohli et al. (1993) to

avoid cross loading, items TPV6, DPV4 and TPV4 were deleted.

At the end of item purification, a total of 10 performance measurement variables had

been removed from the construct, leaving 17 items for analysis of performance of

public sector construction projects. The final first order performance measurement

model is represented in Figure 7.1.

The final first order measurement model reveals that the constructs of cost, time,

quality, site disputes, safety and environmental impact are correlated. Some constructs

are found to be positively correlated while others are negatively correlated among

themselves. The measurement items used to measure each construct are shown using

the arrows from each of the constructs. Further, the loadings are shown on the arrows

emanating from each construct. For instance, three performance items, CPV1, CPV2

and CPV4 measure the cost performance construct and their standardised regression

weights were 1.00, 0.70 and 0.93 respectively.

128

Χ2=223.504, DF=105, Χ2/df=2.13, RMSEA=0.073, GFI=0.894, NFI Value=0.920, IFI=0.956, CFI=0.955, PNFI=0.710 and PCFI=0.738.

Figure 7.1: First order KPIs measurement model (Final)

The regression weights show the change that will occur in the individual items as a

result of a unit change in the construct on which they load in terms of standard

deviations. For instance, when cost performance changes by 1 standard deviation,

CPV2 changes by 0.70 standard deviations. Table 7.9 displays the recommended

levels of the GOF, the relevant values for initial first order model and those of the

final first order model.

129

Table 7.9: Results of Goodness of fit indices (GOF) of the KPIs scale Evaluation

index

Goodness of Fit

(GOF) measure

Recommended Level of

GOF measure

Initial first

order

measurement

model

Final first

order

measurement

model

Absolute fit

index

Χ2/ Degrees of

freedom

<3 4.80 2.13

P Value <0.05 0.000 0.000

RMR Value <0.05 0.170 0.091

RMSEA Value <0.10 0.135 0.073

GFI Value 0 (no fit)-1 (perfect fit) 0.707 0.894

Relative fit

index

NFI Value 0 (no fit)-1 (perfect fit) 0.699 0.920

IFI Value 0 (no fit)-1 (perfect fit) 0.746 0.956

CFI Value 0 (no fit)-1 (perfect fit) 0.743 0.955

Parsimonious

fit index

PNFI Value >0.5 0.617 0.710

PCFI Value >0.5 0.657 0.738

Hoelter CN Value >=200 53 134

Cross

validation

Akaike AIC The least 1625.498 319.504

ECVI The least 7.740 1.521

The above results show that the re-specified first order model fits better than the

initial first order model in terms of χ2/degrees of freedom, RMSEA value, and GFI.

The three indices indicate an acceptable fit to the data and hence the first order model

is supported for the performance measurement construct. Furthermore, all other

essential indices namely CFI, NFI and IFI had values greater than 0.90, providing

evidence of acceptable fit between the measurement model and data (Jin, Doloi &

Gao, 2007). It further reveals that the performance of CDF construction projects in

Western province in Kenya consists of six constructs and may be measured by 17

items using a five point Likert scale. A snapshot of the items is provided in Table 7.10

130

Table 7.10: Dimensions of performance evaluation among CDF construction projects

Key Performance Indicators

Performance Variables

Time performance TPV1: Timely delivery of resources

TPV2: Harmonious relationship exists on site

TPV4: No delays in securing funds

Cost Performance CPV1: Equipments available at pre budgeted rates

CPV2: Stable labour costs

CPV3: No increase in materials cost

Site Disputes DPV1: No serious protests by the community due to the

nature of the project

DPV2: Disputes due to frequent changes in designs

DPV3: No incidences of trade union agitation

Environmental Impact EPV1: Project has led to air pollution

EPV2: Project has given rise to increase in solid waste

EPV3: Utilised environmentally friendly technology

Quality Performance QPV1: Right material was used for the construction work

QPV2: A sound QMS was adhered to

QPV3: Workers were trained on positive attitudes

Safety Performance SPV1: Accidents were reported.

SPV2: Fatalities did occur.

Time performance is measured through three items: timely delivery of resources,

harmonious relationships on site and no delays in securing project funds. Cost

performance is measured through three statements: availability of equipment at pre

budgeted rates, labour costs and materials cost. The site disputes factor is considered

on the basis of three site disputes related issues. This factor attempts to capture the

issues raised by the community due to the nature of the project, conflict of interest

between the management and union and also the conflicts occurring among project

stakeholders. Environmental impact captures the issues relating to the physical and

ecological environment. The fifth dimension of project performance reflects

performance on quality. Safety performance was measured using the occurrence of

accidents and fatalities on the project. The summary of the measurement outputs of

the final first order model are presented in table 7.11.

131

Table 7.11: Loadings of First-order CFA of KPIs’ performance variables Variable R2 Standard first order loadings a

Cost Performance

Time Performance

Site disputes Performance

Environmental imp-act perfo-rmance

Quality Performance

Safety perform

CPV1 0.994 .997*** CPV2 0.484 .696 (13.27) CPV4 0.860 .927 (26.91) Cost Performance

0.435b -0.282b -0.063b 0.671b -0.006b

TPV1 0.678 .824*** TPV2 0.645 .803(12.93) TPV3 0.812 .901(14.03) Time Performance

-0.041b -0.130b 0.228b 0.047b

DPV1 0.989 .994*** DPV2 0.765 .875(20.27) DPV3 0.590 .768(15.30) Site Dis. Perf.

0.519b -0.096b 0.102b

EPV1 0.952 .976*** EPV2 0.440 .663(10.54) EPV3 0.651 .807(13.39) Environ impact perf.

0.159b 0.146b

QPV1 0.984 .992*** QPV2 0.835 .914 (29.1) QPV3 0.851 .923(30.52) Quality Perform

0.008b

SPV1 0.302 .549*** SPV2 0.493 .702*** Safety perf. Notes: a Standard first-order loading is the standardized regression weight of the individual variables’ loading on to one of the component factors. Figures in parentheses are critical ratios from the unstandardised solutions. b Standard first-order loading for component factors (i.e. time performance, cost performance, quality performance, site disputes performance, safety performance and environmental impact performance) is the covariance between any two of these component factors; *** The critical ratio is not available, because the regression weight of the first variable of each component factor is fixed at 1; Χ2=223.504, Df=105, Χ2/df=2.12, RMSEA=0.073, GFI=0.894, NFI Value=0.920, IFI=0.956, CFI=0.955, PNFI=0.710 and PCFI=0.738

132

In table 7.11, the standardised regression weights for various variables range from

0.549 to 0.997 while the squared multiple correlations (R2) are 0.302 to 0.994. Both

standardised regression weights and squared multiple correlations exceed the

threshold values of 0.5 and 0.25 respectively (Hair et al., 2006). Squared multiple

correlations show the proportion of variance that can be attributed to the construct.

For instance, the squared multiple correlation of CPV1 is 0.994 which implies that up

to 99.4% of the variance in CPV1 can be explained by the cost performance construct

Similarly, the critical ratios (t values in brackets) of the variables are all above 1.96

implying that all standardised regressions weights of the measurement items are

statistically significant at 5% significance level. Covariances show the level and

nature of shared variation among different constructs. For instance, the covariance of

0.435 relating cost performance with time performance shows that an increase in cost

performance is accompanied by an increase in time performance and vice versa.

7.3.3 Second order measurement model of KPIs

The structural equation modelling was conducted at the second stage of the model to

test the relationships between the first order constructs and the second order construct

namely overall project performance. The test of the second order model illustrated in

Figure 7.2 implies that project performance, a higher order latent factor governs the

correlations amongst first order constructs: cost, time, quality, site disputes, safety and

environmental impact. The second order model yielded the following results of test

statistics: χ2 statistics = 255.737, Degrees of freedom = 114, χ2/degrees of freedom =

2.243, RMSEA Value = 0.077, GFI Value = 0.880, NFI Value = 0.908, IFI Value =

0.947, CFI Value = 0.947, PNFI Value = 0.761 and PCFI = 0.794.

These estimated model fit indexes were adequate. The second order loadings on

overall project performance are 0.967 for cost, -0.10 for safety, and 0.317 for time, -

0.488 for quality, -0.041 for environmental impact and -0.176 for site disputes. This

indicates that when overall project performance increases by 1 standard deviation

(SD), cost performance and time performance increase by 0.967 and 0.317 SDs

respectively, whereas safety performance, quality performance, environmental impact

performance and site dispute performance decreases by 0.10, 0.488, 0.041 and 0.176

SDs respectively. These findings are consistent with those of Nidumolu (1996) and

133

Nurul and Ng (2011) who argued that tightly controlled processes adhering to strict

time and cost may sometimes compromise on quality. Furthermore, the actual

beneficiaries (i.e. the surrounding community) of CDF construction projects do not

contribute anything towards construction costs of the project.

Χ2=255.737, DF=114, Χ2/df=2.243, RMSEA=0.077, GFI=0.880, NFI Value=0.908, IFI=0.947, CFI=0.947 PNFI=0.761 and PCFI=0.794

Figure 7.2: Second order KPIs measurement model (Final)

The ratio of Chi-square to the degrees of freedom (DF) differs slightly from the first

order model due to the additional number of DF brought about by the incorporation of

the second order model. The target coefficient compares the Chi-square of the first

order model to the Chi-square of the second order model (Wang et al., 2007). This

coefficient was 0.95 indicating that the second order construct explains 95% of the

variation in the first-order constructs, which demonstrates that overall project

performance is a satisfactory second order construct.

134

These results show that cost, time and quality are strongly correlated with overall

project performance, whereas site disputes, safety and environmental impact do not

significantly correlate with the same. However, due to the adequacy of the model fit,

overall project performance can be conceptualised as a second order construct

consisting of all six first order constructs.

7.3.4 Evaluation of constructs in KPIs measurement model

To validate the performance measurement construct, the final model was

systematically evaluated for dimensionality, reliability and validity.

7.3.4.1 Unidimensionality and face validity: At the beginning of the study, literature

was extensively reviewed in order to identify the performance related variables. These

variables were then discussed with experts in the field of construction management

who also provided valuable insights to the performance measurement among public

sector construction projects. This was followed by a questionnaire design whose

responses were analysed using exploratory factor analysis. The development of the

first order performance constructs was based on the findings of an exploratory study.

Further related literature was reviewed and views of experts were also sought when

developing the constructs. All the items generated were checked for their

appropriateness. Subsequently, through CFA, items were purified based on their

empirical findings and theoretical underpinnings so as to maximise the face and

content validity. The items retained through purification loaded on single constructs

supporting the existence of unidimensionality.

7.3.4.2 Construct Reliability: Reliability measures the internal consistency of the

observed variables. Table 7.12 reveals that the values for construct reliability range

from 0.57 to 0.96. According to Hair et al. (2006) and Lim and Mohamed (2000), the

rule of thumb for reliability estimate is 0.7 or higher. It further suggests a reliability

estimate of 0.6 as acceptable. In this study, five out of the six constructs had reliability

estimates above 0.7 while only one construct had a reliability estimate of just below

0.6. This demonstrates that the five constructs are highly reliable with the sixth one

being reasonably reliable. The table further reveals that the items constituting quality

construct exhibit the highest reliability followed by the constructs of cost and site

disputes.

135

Factor loadings are similar to standardised regression weights whereas item

reliabilities are the same as squared multiple correlations, R2. The delta values, also

known as the standardised error variances, describe the proportion of the indicator

variable that cannot be attributed to the specific construct. The eigenvalue of the

constructs shown in Table 7.12 indicate the variance extracted by each construct in

absolute terms. These values are then used to compute average variance extracted

(AVE) by the constructs, which demonstrates the average variance that a construct is

able to extract from each measurement item that loads on it. In other words, this

indicates the explanatory power of the constructs.

Table 7.12: Reliability test of performance measures among CDF construction

projects Variable Cost Time Site

Disputes.

Environmental impact.

Quality Safety Item reliabilities

Eigen Value

Delta

CPV1 .997 0.994 0.006 CPV2 .696 0.484 0.516 CPV4 .927 0.860 2.338 0.140 TPV1 .824 0.678 0.322 TPV2 .803 0.645 0.355 TPV3 .901 0.812 2.135 0.188 DPV1 .994 0.989 0.011 DPV2 .875 0.765 0.235 DPV3 .768 0.590 2.344 0.410 EPV1 .976 0.952 0.048 EPV2 .663 0.440 0.560 EPV3 .807 0.651 2.043 0.349 QPV1 .992 0.984 0.016 QPV2 .914 0.835 0.165 QPV3 .923 0.851 2.670 0.149 SPV1 .549 0.302 0.698 SPV2 .702 0.493 0.795 0.507 Average Variance Extracted

77.9% 71.2% 78.1% 68.1% 89.0% 40.0%

Construct Reliability

0.91 0.88 0.91 0.86 0.96 0.57

Factor Loadings

Squared factor loadings (communalities)

2.338/3

Delta (standardised error variance) =1-item reliability e.g 1-.994= .006.

(.997+.696+.927)2/[(.997+.696+.927)2+(.006+.516+.140)]=0.91

136

Table 7.12 indicates that quality construct possesses the highest explanatory power as

evidenced by AVE (89%), followed by site disputes (78%), cost (78%), time (71%),

environmental impact (68%) and safety (40%).

An AVE of 0.89 in quality construct indicates that up to 89% of the variation in the

measurement items relating to quality can be explained by the quality construct.

7.3.4.3 Construct Validity: This seeks to determine the extent to which the measures

capture the essence of the construct being measured in the study. It addresses two

types of validity:

(i) Convergent validity: This validity requires that the indicator variables of a

given construct should share a high proportion of variance in common. The six

constructs in the KPIs scale mentioned above have AVE ranging from 0.40 to

0.89. This shows that the variables of every construct share high proportion of

variance among them except in one construct, safety whose AVE is, however,

just below 0.5 (Hair et al., 2006; Ng, Wong & Wong, 2010). Therefore,

convergent validity may be considered reasonably good based on the AVE as

shown in the Table 7.12.

(ii) Discriminant validity: This is a measure of how a construct is distinct from

other constructs in the same model.

Table 7.13: Discriminant Validity of KPIs Construct Cost Time Site

Disputes Environmental impact

Quality Safety

Cost 0.883 Time 0.306 0.843 Site Disputes -0.170 -0.056 0.883 Environmental impact -0.040 -0.013 0.007 0.823 Quality -0.472 -0.155 0.086 0.020 0.943 Safety -0.009 -0.003 0.002 0.000 0.005 0.632 Av. Variance Extracted 0.78 0.71 0.78 0.68 0.89 .40 Diagonal elements are the square root of average variance extracted (AVE) and the other matrix

entries represent correlations between constructs.

Items associated with a construct correlate more with each other than with the items

of other constructs in the model. The square root of AVE of each construct is

compared to the correlation between each construct and other constructs. For

discriminant validity to exist, the values representing the square root of AVE (the

137

diagonals in Table 7.13) for all the constructs should be greater than the correlations

between the constructs (off-diagonals).

All the values of AVE estimates in Table 7.13 are larger than the corresponding

correlations between the constructs. This implies that the indicators have more in

common with the construct they are associated with than they do with other

constructs. Therefore, the six construct CFA model demonstrates discriminant

validity.

(iii) Nomological validity: Nomological validity seeks to determine whether there is

evidence that the structural relationships among the constructs is consistent with

other studies that have been measured with validated instruments and tested

against a variety of other settings, times and methods. Its main focus is on the

correlations among the constructs with a view to establishing whether the

correlations are consistent with the existing theories and whether they are

significant. The estimates for correlations among the constructs should be

consistent with construct formulation and significant. Based on KPI theory, the

constructs can be either positively or negatively related to demonstrate

nomological validity. However, not all the covariances among the six constructs

were found to be significant.

7.4 Confirmatory Factor Analysis (CFA) of project success variables for CSFs

Scale

Based on the responses on all the 27 items identified as observable project success

variables for public sector construction projects were incorporated into the

measurement model and tested with help of AMOS software (version 20.0). The

fitness of this measurement model was assessed based on standardised regression

weights, squared multiple correlations, standardised residual covariances and the

modification indices. The reliability of the items and that of the construct as a whole

was also assessed and the model was accordingly re-specified. The re-specified

measurement model was again assessed for its fitness and consequently

operationalised as a second order model based on re-specified model construct.

138

7.4.1 Validation of project success variables

Confirmatory Factor Analysis (CFA) was used to assess how well the observed

variables, i.e. success items reflect unobserved or latent variables in the hypothesized

structure. Before commencing CFA, the measurement properties of the CSFs were

tested using reliability and items to total correlation analysis followed by CFA (Zhu et

al., 2008). The reliability test and item-to-total correlation analysis results provided in

table 7.14 suggest a reasonable fit of the latent factors to the data collected. Cronbach

α values for all six factors of project success are greater than 0.82. Further item

loadings on all the factors are acceptable because they are greater than 0.518. The

details are shown in Table 7.14.

Table 7.14: Summary of measurement results of Critical Success Factors (CSFs) Factors Number

of items Mean S.D α Range of

item-to-total Project related factor (PSV) 7 2.982 1.209 0.931 0.601-0.912

Client related factor (CSV) 5 2.830 1.514 0.954 0.797-0.925

Contractor related factor (RSV) 3 3.313 1.275 0.829 0.603-0.824

Environment related factor (ESV) 6 3.349 1.173 0.876 0.518-0.857

Consultant related factor (CSV) 3 2.817 1.247 0.825 0.542-0.824

Supply chain related factor (LSV) 3 3.367 0.972 0.882 0.723-0.868

To assess discriminant validity, CFA was conducted among the pairs of the six factors

as described in section 7.3.1 (page 123). The results in Table 7.15 show that all the 15

pairs of factors recorded a significant drop in chi-square values, hence discriminant

validity is present.

Table 7.15: Discriminant validity checks: Chi-square differences Factors 1 2 3 4 5

1.Project related factor (PSV)

2.Client related factor (CSV) 1022.4

3.Contractor related factor (RSV) 221.3 262.8

4.Environmental related factor (ESV) 576.2 578.1 262.8

5.Consultant related factor (CSV) 279.0 254.1 248.8 286.5

6.Supply chain related factor (LSV) 393.3 392.3 245.7 396.1 291.3

139

7.4.2 First order measurement model of CSFs

The first order model reveals that project related, client related, consultant related,

contractor related, supply chain related and external environment related are all

correlated factors that constitute a scale for CSFs for construction projects. This

critical success factor scale was assessed through CFA utilizing MLE method. In

refining the model, the researcher also considered the logic and consistency of the

data with theoretical underpinnings in construction project management.

The initial model proposed for the success of construction projects indicated poor

model fit on all recommended goodness of fit indices as provided in Table 7.16. This

necessitated item purification through CFA, thereby eliminating items, one at a time,

based on theoretical reasons and empirical examination as stated above (Wang et al.,

2007). The deletion of items are based on whether they differ from existing theory of

project management literature, whether there exists strong conceptual linkages as

evidenced by modification indices and standardised multiple correlations and finally

whether they were confusing in their interpretation.

At the end of item purification, a total of 10 measuring items were removed from the

construct, leaving 17 items for construction project success construct. The final first

order CSFs model is represented in Figure 7.3.

Figure 7.3 shows that project related, client related, consultant related, contractor

related, supply chain related and environment related factors are correlated. Table

7.16 displays the recommended level of the Goodness of fit indices (GOF), the

relevant values for initial first order model and those of the final first order model.

The results show that the re-specified first order model fits better than the original

first order model in terms of χ2/degrees of freedom, RMSEA value and GFI value.

The three indices indicate an acceptable fit to the data, and hence the first order model

is supported for CSFs influencing the performance of construction projects.

140

Χ2=261.549, DF=107, Χ2/df=2.444, RMSEA=0.083, GFI=0.877, NFI Value=0.913, IFI=0.947, CFI=0.946, PNFI=0.719 and PCFI=0.745 Figure 7.3: First order CSFs measurement Model (Final)

Furthermore, all other essential indices namely CFI, NFI and IFI had values greater

than 0.90, providing evidence of acceptable fit between the measurement model and

data (Jin et al., 2007).

The GOF indices for both first order measurement model and second order

measurement model are summarised in table 7.16.

141

Table 7.16: Results of Goodness of fit indices (GOF) of CSFs scale Evaluation index

Goodness of Fit (GOF) measure

Recommended Level of GOF measure

Initial first order measurement model

Final first order measurement model

Absolute fit

index

Χ2/ Degrees of

freedom

<3 4.465 2.444

P Value <0.05 0.000 0.000

RMR Value <0.05 0.755 0.084

RMSEA Value <0.10 0.128 0.083

GFI Value 0 (no fit)-1 (perfect

fit)

0.697 0.877

Relative fit

index

NFI Value 0 (no fit)-1 (perfect

fit)

0.747 0.913

IFI Value 0 (no fit)-1 (perfect

fit)

0.792 0.947

CFI Value 0 (no fit)-1 (perfect

fit)

0.790 0.946

Parsimonious

fit index

PNFI Value >0.5 0.662 0.719

PCFI Value >0.5 0.700 0.745

Hoelter CN Value >=200 57 116

Cross

validation

Akaike AIC The least 1522.632 353.549

ECVI The least 7.251 1.684

Results of the analysis then suggest that the success of CDF construction projects in

Western province, Kenya depend on six factors and may be measured by 17 items

using a five point Likert scale. The six factors are project related, client related,

consultant related, contractor related, supply chain related and external environment

related factors.

A snapshot of the items is provided in Table 7.17.

142

Table 7.17: Critical success factors among CDF construction projects Critical Success Factors Success Variables ( SV)

Project Related Factor PSV1: Influence of Design Complexity

PSV2: Adherence to the requisite Quality standards

PSV3: Continuous monitoring of actual expenditures

PSV4: Formal dispute resolution structures

Client Related Factor CSV2: Cheap materials were used

CSV4: Client’s emphasis on time rather than quality

CSV5: Design documents approved on time

Environmental Related

Factor

ESV1: Community had no issues against the project

ESV2: Adversely affected by the surrounding weather

ESV3: Effect of the Governance policy

Supply Chain Related

factor

LSV1: Few internal procurement challenges

LV2: Right equipments were available

LSV3: Effect of stringent insurance/warranty rules

Consultant Related

factor

SSV1: No variations were incorporated

SSV2: Adequate designs/specifications and documentation

Contractor Related

factor

RSV1: Site Managers possessed requisite skills

RSV2: Contractor had adequate technical skills.

Project related factor captures the uniqueness of a project in terms of its size, value

and activities as well as the urgency of a project outcome. Client related factor,

consultant related factor and contractor related factor focus on the role of clients,

consultants and contractors respectively on the construction project. Supply chain

related factor is concerned with the availability of project resources and their

acquisition whereas the environmental factor reflects the ecological, economic and

community issues surrounding the construction projects. The summary of the outputs

of the final first order model is presented in Table 7.18.

In table 7.18, the standardised regression weights for various variables range from

0.730 to 0.996 with the squared multiple correlations (R2) being 0.532 to 0.962. This

shows that all the variables retained are important given that the standardised

regression weights exceed the threshold recommended value of 0.7 and the squared

multiple correlations exceed the threshold value of 0.5 (Hair et al., 2006).

143

Table 7.18: Loadings of First-order CFA of CSFs’ success variables Variable R2 Standard first order loadings a

Project related factor

Client related Factor

Environm- ent related Factor

Supply Chain related Factor

Consultant related Factor

Contrac-tor related Factor

PSV1 .992 .996*** PSV2 .897 .947*** PSV3 .753 .868(24.5) PSV4 .729 .854(23.1) Project related factor

0.509b -0.400 0.046 0.311 0.078

CSV2 0.985 .992(13.4) CSV4 0.827 .909(13.7) CSV5 0.532 .730*** Client related Factor

0.212 -0.090 0.566 0.067

ESV1 0.777 .881*** ESV2 0.724 .851(13.9) ESV3 0.579 .761(12.4) Environment related factor

0.067 0.204 -0.020

LSV1 0.986 .993(14.2) LSV2 0.647 .804(12.9) LSV3 0.592 .770*** Supply Chain related Factors

-0.066 -0.246

SSV1 0.831 .912*** SSV2 0.776 .881*** Consultant related Factor

0.080

RSV1 0.688 .830*** RSV2 0.791 .889*** Contractor related Factor

Notes: a Standard first-order loading is the standard regression weight of the individual variables’ loading on to one of the component factors. Figures in parentheses are critical ratios from the unstandardised solutions; b Standard first-order loading for component factors (i.e. project-related, client-related, consultant-related, contractor-related, supply chain-related and external environment-related) is the covariance between any two of these component factors; *** The critical ratio is not available, because the regression weight of the first variable of each component factor is fixed at 1; Χ2=261.549, Df=107, Χ2/df=2.444, RMSEA=0.083, GFI=0.877, NFI Value=0.913, IFI=0.947, CFI=0.946, PNFI=0.719 and CFI=0.745

144

7.4.3 Second order measurement model of CSFs

The structural equation modelling was conducted at the second stage of the model to

test the relationships between the first order constructs and the second order construct,

namely project success (Figure 7.4)

χ2 statistics =3.190, RMSEA Value=0.1023, GFI Value=0.835, CFI Value=0.910, PNFI Value=0.759 and PCFI=0.790. Figure 7.4: Second order CSFs measurement model (Final)

As shown in Figure 7.4, the six constructs: project related, client related, consultant

related, contractor related, supply chain related and external environment related are

correlated and they load on project success construct. The estimated model fit indices

shown below the second order measurement model (figure 7.4) were found to be

adequate and the variable loadings were similar to the first order loadings. The second

order loadings on project success are 0.529 for project related factor, 0.551 for

environmental related factor, 0.495 for consultant related factor, 0.475 for contractor

145

related factor, 0.448 for client related factor and 0.410 for supply chain related factor.

The loadings of the other five CSFs on external environment related factor were very

low except on project related factor (-0.427) and client related factor (0.317). These

means that project related factor and client related factor have significant relationship

with external environment related factor.

The target coefficient of the second order measurement model is 0.766. Therefore, the

second order constructs (project success) explain 76.6% of the variation in the first-

order factors, the required evidence that project success is a second order construct.

7.4.4 Evaluation of constructs in CSFs measurement model

Validation of the constructs of CSFs, involved a systematic evaluation of the final

KPIs model it terms of dimensionality, reliability and validity. Whereas

unidimensionality is evaluated on the basis of item analysis, both reliability and

validity requires further analysis. The validation process is described below.

7.4.4.1 Unidimensionality and face validity: The development of the initial CSF

construct followed a thorough and extensive literature review. Views of experts

consisting mainly of academicians and practitioners were also sought when

developing the construct. All the items generated were checked for their

appropriateness. Further, through CFA, items were purified based on their empirical

findings and theoretical underpinnings so as to maximise face and content validity.

The remaining items after item purifications loaded on single constructs supporting

the existence of unidimensionality.

7.4.4.2 Construct Reliability: Reliability measures the internal consistency of the

observed variables. Table 7.19 reveals the values for construct reliability which range

from 0.85 to 0.96. According to Hair et al. (2006), the rule of thumb for reliability

estimate is 0.7 or higher. These findings demonstrate that the six constructs are highly

reliable. The table further reveals that the items constituting project related factor

exhibit the highest reliability followed by the client related factor.

146

Table 7.19: Reliability test of CSFs among CDF construction projects Variable Project

related Factor

Client related Factor

Enviro-nment related Factor

Supply Chain related Factor

Consultant related Factor

Contractor related Factor

Item

reliab

ilities

Eigen Value

Delta

PSV1 .996 0.992 0.008 PSV2 .947 0.896 0.104 PSV3 .868 0.753 0.247 PSV4 .854 0.730 3.371 0.270 CSV2 .992 0.985 0.015 CSV4 .909 0.827 0.173 CSV5 .730 0.532 2.344 0.468 ESV1 .881 0.777 0.223 ESV2 .851 0.724 0.276 ESV3 .761 0.579 2.080 0.421 LSV1 .993 0.986 0.014 LSV2 .804 0.647 0.353 LSV3 .770 0.593 2.226 0.407 SSV1 .912 0.831 0.169 SSV2 .881 0.776 1.607 0.225 RSV1 .830 0.689 0.311 RSV2 .889 0.790 1.479 0.210

Average Variance Extracted

84.28% 78.13% 69.33% 74.17% 80.30% 73.95%

Construct Reliability

0.96 0.91 0.87 0.89 0.89 0.85

In table 7.19, factor loadings are similar to standardised regression weights whereas

item reliabilities are the same as squared multiple correlations, R2. The delta values,

also known as the standardised error variances, describe that proportion of the

indicator variable that cannot be attributed to the specific construct. The eigenvalue of

the constructs shown in Table 7.19 indicate the variance extracted by each construct

in absolute terms. These values are then used to compute average variance extracted

(AVE) by the constructs, which demonstrates the average variance that a construct is

able to extract from each measurement item that loads on it. In other words, this

indicates the explanatory power of the constructs

Table 7.19 indicates that the project related construct possesses the highest

explanatory power as evidenced by AVE (84.28%), followed by consultant related

Squared factor loadings (communalities) Factor Loadings

3.371/4

Delta (standardised error variance) =1-item reliability e.g 1-.992= .008.

(.996+.947+.868+.854)2/[(. 996+.947+.868+.854)2+(.008+.104+.247+.270)]=0.96

147

construct (80.30%), client related construct (78.13%), supply chain related construct

(74.17%), contractor related construct (73.95%) and the environment related construct

(69.33%). An AVE of 0.8428 in project related construct indicates that up to 84.28%

of the variation in the measurement items relating to the project can be explained by

the same construct.

7.4.4.3 Construct Validity: Construct validity was addressed through convergent

validity and discriminant validity.

(i) Convergent validity: The six constructs in the CSFs scale mentioned above

have Average Variance Extracted (AVE) ranging from 0.69 to 0.84. This

reveals that the variables of every construct share high proportion of variance

amongst them. Therefore, convergent validity is considered adequate because

all values of AVE are above 0.5 (Hair et al., 2006).

(ii) Discriminant validity: The square root of AVE calculated for each construct

is compared with the correlation between each construct and other constructs

as shown in Table 7.20.

Table 7.20: Discriminant Validity of CSFs Construct Project

related factor.

Client related factor

Environment related factor

Supply chain related. factor

Consult-ant related factor

Contractor related factor

Project related factor 0.917 Client related factor .419 0.883 Environment related factor -.285 .179 0.830 Supply chain related factor .047 -.107 .069 0.860 Consultant related factor .231 .496 .154 -.071 0.894 Contractor related factor .060 .061 -.016 -.275 .066 0.860 Average Variance Extracted

0.84 0.78 0.69 0.74 0.80 .74

Diagonal elements are the square root of average variance extracted (AVE) and the other matrix entries represent correlations between constructs.

For discriminant validity to exist, the values representing the square root of AVE (the

diagonals) for all the constructs should be greater than the correlations between the

constructs (off-diagonals).

All the values of AVE estimates in the above table are larger than the corresponding

correlations between the constructs. This implies that the indicators have more in

148

common with the construct they are associated with than they do with other

constructs. Therefore, the six construct CFA model demonstrates discriminant

validity.

7.5 Structural Equation Modelling (SEM)

In the previous sub sections, two measurement models: one for KPIs and the other

CSFs have been tested and validated.

7.5.1 A summary of CFA results

Measurement properties of the two measurement models (KPIs and CSFs) were

evaluated by examining convergent validity and discriminant validity Specifically, for

convergent validity to be significant: a) Standardised factor loadings for each

observed item should be at least 0.5, b) construct reliability (CR) for each construct be

at least 0.6 and c) average variance extracted (AVE) should be 0.5 or higher (Hair et

al., 2006). Whereas the standardised factor loadings are part of the output of AMOS

software, C.R for each construct is computed as the square of summation of factor

loadings divided by the sum of the square of summation of factor loadings and the

summation of error variances. AVE, on the other hand, is computed by taking the

total of all squared standardized factor loadings divided by the number of items. Table

7.21 shows the values of CR and AVE of each construct and standardised factor

loadings of each item used in the performance evaluation framework.

As shown in Table 7.21 the CR for 11 constructs was above 0.7 indicating adequate

reliability of these constructs (Hair et al, 2006). The CR for safety is, however, 0.57 a

value just below 0.6 recommended as an acceptable value of CR (Hair et al., 2006).

Thus, the results provide evidence to the fact that the scales are reliable. All of the

factor loadings are statistically significant at five percent level and exceed the

threshold value of 0.5 standard (Hair et al., 2006). AVE is more conservative than

Cronbach’s alpha (α) as a composite reliability measure, and its accepted value is 0.5

or above for a construct.

149

Table7.21: Summary of the results of Confirmatory Factor Analysis Construct Construct

Reliability Average Variance Extracted

Item Standardised Factor loadings

Project Related Factor

0.96 0.84 PSV1: Influence of Design Complexity. .996 PSV2: Adhered to the requisite Quality standards.

.947

PSV3: Continuous monitoring of actual expenditures.

.868

PSV4: Formal dispute resolution structures. .854 Client Related Factor

0.91 0.78 CSV2: Cheap materials were used. .992 CSV4: Client’s emphasis on time rather than quality.

.909

CSV5: Design documents approved on time. .730 Environment Related Factor

0.87 0.70 ESV1: Community had no issues against the project.

.881

ESV2: Adversely affected by the surrounding weather.

.851

ESV3: Effect of the Governance policy. .761 Supply chain Related Factor

0.89 0.74 LSV1:Few internal procurement challenges .993 LSV2: Right equipments were available. .804 LSV3: Effect of stringent insurance/warranty rules.

.770

Consultant Related Factor

0.89 0.80 SSV1: No variations were incorporated. .912 SSV2: Adequate designs/specifications/ documentations.

.881

Contractor Related Factor

0.85 0.74 RSV1: Site Managers possessed requisite skills. .830 RSV2: Contractor had adequate technical skills.

.889

Time Performance

0.88 0.71 TPV1: Timely delivery of resources .824 TPV2: Harmonious relationship on site. .803 TPV3: A clear plan was formulated. .901

Cost Performance

0.91 0.78 CPV1: Equipments at pre budgeted rates. .997 CPV2: Stable labour costs .696 CPV4: Minimum variations cost were incurred .927

Site Dispute Performance

0.91 0.78 DPV1: No serious dispute due to specifications. .994 DPV2: Disputes due to the frequent changes .875 DPV3: No incidences of trade union agitation .768

Environmental impact Performance

0.86 0.68 EPV1: Project has led to air pollution. .976 EPV2: Increased solid waste. .663 EPV3: Utilised environmentally friendly technology.

.807

Quality Performance

0.96 0.89 QPV1: Right material was used for the construction work.

.992

QPV2: A sound QMS adhered to. .914 QPV3: Workers were trained on positive attitudes

.923

Safety Performance

0.57 0.40 SPV1: Accidents were reported. .549 SPV2: Fatalities did occur. .702

150

As shown in the third column of Table 7.21, the 12 constructs in the two measurement

models represented in Table 7.21 have AVE ranging from 0.40 to 0.89. This shows

that the variables of every construct share high proportion of variance within each

construct except in one construct, safety whose AVE is, however, just below 0.5 (Hair

et al., 2006). This construct was, however, retained due to its theoretical importance in

of performance measurement among construction projects. Therefore, convergent

validity may be considered reasonably good based on the AVE as shown in the Table

7.21. AVE can also be used to establish discriminant validity of a measurement scale.

Once constructs are ascertained to have significant convergent validity, they are

retested for discriminant validity which measures the extent to which the conceptually

different constructs are distinct. To get satisfactory discriminant validity, the square

root of AVE of each construct should be greater than the correlation between the

constructs (Hair et al., 2006).

Discriminant validity evaluates whether the constructs are measuring different

concepts (Hair et al., 2006).The square root of the variance extracted for each

construct should be greater than the correlations between the construct and all other

constructs (Wang et al., 2007). Conceptually, this implies that the average variance

shared should be greater than the variance shared between the constructs themselves.

7.5.2 Evaluation of structural model

The proposed performance evaluation structural model is presented in Figure 7.5.

151

Figure 7.5: Initial performance evaluation model.

This structural model was analysed using SEM as provided by AMOS Version 20.0 in

order to test the hypotheses formulated earlier for the model fit. The performance

evaluation model was estimated using the maximum likelihood (ML) method. The

SEM results suggest that though the model meets several GOF indices, it can still be

refined. Modification indices confirmed the presence of interrelations between three

pairs of exogeneous constructs: project related factor and client related factor; client

related factor and consultant related factor and finally, supply chain related factor and

contractor related factor. Thus the model should be improved by adding these

interrelations. Figure 7.6 shows the final model while Table 7.22 highlights the results

152

of GOF tests of both the initial and final models. All fit indices of the final model fall

within the recommended intervals, a pointer to model reliability.

Figure 7.6:Re-specified performance evaluation model.

The GOF measures are shown in Table 7.22. The revised model is supported because

both the IFI and CFI are greater than 0.9.

153

Table 7.22: Goodness of fit tests of SEM Evaluation index Goodness of Fit Description of the

test Initial performance evaluation model

Re-specified performance evaluation model

Absolute fit index

Chi square The least 1133.423 1031.129 Degrees of freedom Number 521 518 Chi square/df <4 2.175 1.991 P Value >0.05 0.000 0.000 RMR Value <0.05 0.613 0.407 RMSEA Value <0.05 indicates

very good fit (Threshold level=0.10)

0.075 0.069

GFI Value 0 (no fit) to 1 (perfect fit)

0.787 0.798

Relative fit index NFI Value 0 (no fit) to 1 (perfect fit)

0.815 0.831

IFI Value 0 (no fit) to 1 (perfect fit)

0.890 0.908

CFI Value 0 (no fit) to 1 (perfect fit)

0.890 0.908

Parsimonious fit index

PNFI Value >0.5 0.757 0.768 PCFI Value >0.5 0.826 0.838 Hoelter CN Value >=200 107 117

Cross validation Akaike AIC The least 1281.423 1185.129 ECVI The least 6.102 5.643

Table 7.22 shows that the re-specified structural model has good fit with data based

on assessment criteria such as GFI, CFI, TLI, and RMSEA.

In reference to the performance evaluation framework (Figure 7.6), it is suggested that

six categories of factors should be considered by project stakeholders. Further, the

framework shows that performance of construction projects can be measured on the

basis of six dimensions. The figure also shows inter-correlations between project

related and client related factors; consultant related and client related factors; and

contractor related and supply chain related factors. The measurement items of all

constructs including CSFs and KPIs are shown in Table 7.23.

154

Table 7.23: Summary of the constructs and measurement items in the Structural Equation Model

Construct Measurement items

Project Related Factor (PSV) PSV1: Influence of Design Complexity.

PSV2: Adhered to the requisite Quality standards.

PSV3: Continuous monitoring of actual expenditures.

PSV4: Formal dispute resolution structures.

Client Related Factor (CSV) CSV2: Cheap materials were used.

CSV4: Client’s emphasis on time rather than quality.

CSV5: Design documents approved on time.

Environment Related Factor

(ESV)

ESV1: Community had no issues against the project.

ESV2: Adversely affected by the surrounding weather.

ESV3: Effect of the Governance policy.

Supply chain Related Factor (ESV) LSV1:Few internal procurement challenges

LSV2: Right equipments were available.

LSV3: Effect of stringent insurance/warranty rules.

Consultant Related Factor (SSV) SSV1: No variations were incorporated.

SSV2: Adequate designs/specifications/documentations.

Contractor Related Factor (RSV) RSV1: Site Managers possessed requisite skills.

RSV2: Contractor had adequate technical skills.

Time Performance (TPV) TPV1: Timely delivery of resources

TPV2: Harmonious relationship on site.

TPV3: A clear plan was formulated.

Cost Performance (CPV) CPV1: Equipments at pre budgeted rates.

CPV2: Stable labour costs

CPV4: Minimum variations cost were incurred

Site Dispute Performance (DPV) DPV1: No serious dispute due to specifications.

DPV2: Disputes due to the frequent changes

DPV3: No incidences of trade union agitation

Environmental impact

Performance (EPV)

EPV1: Project has led to air pollution.

EPV2: Increased solid waste.

EPV3: Utilised environmentally friendly technology.

155

Amongst the six categories of CSFs influencing project success in the performance

evaluation model (figure 7.6), project related factor with a standardised coefficient of

0.738 is the most important followed by consultant related factor, client related factor,

contractor related factor and then supply chain related factor (with standardised

coefficients =0.666, 0.663, 0.631, and 0.566, respectively). External environment

related factor with a standardised coefficient of 0.517 is the least important, though it

was found significant during project construction. Greater efforts should be made to

facilitate all supply chain related and external environment factors when constructing

development projects. Similarly, Figure 7.6 shows that the most important dimensions

of overall project performance are cost, quality, time and site disputes (with

standardised coefficients= 0.995, -0.715, 0.517 and -0.314 respectively) in order of

importance as perceived by project stakeholders. Whereas the coefficient for site

disputes is rightly negative that of quality performance is also negative, implying that

cost conformance is attained at the expense of quality.

Further the SEM results show that project success is related to overall project

performance as exhibited by a standardised loading of 0.690. This means that the

success of construction projects can be reflected through its overall performance. The

relationship between each of the CSFs and each KPI can be obtained by multiplying

the three standardised coefficients (for instance, the relationship between project

related factor and cost is 0.507= (0.738x0.690x0.995).

7.5.3 Tests of hypotheses and Discussion

Hypotheses relating to both direct effects and indirect effects were tested.

7.5.3.1 Test of direct impact of re-specified model

Thirteen hypotheses proposed in Chapter 6 section 6.2 are tested based on the direct

effects. These hypotheses relate to the influence of the six CSFs on projects success,

the association between project success and overall project performance and the

relationship between overall project performance and KPIs. Table 7.24 summarises

the results of tests of hypotheses based on standardised regression weights in the

performance evaluation model

156

Table 7.24 Direct impact of re-specified model based on standardized regression weights

Hypothesis Relationship between exogenous and endogenous

Std estimate

S.E C.R P-Value

H1a Support Client related factor Project success

.663 ** ** **

H1b Support Supply chains related factor Project success

.566 .** ** **

H1c Support Project related factor Project success

.738 ** ** **

H1d Support Consultant related factor Project success

.666 ** ** **

H1e Support Contractor related factor Project success

.631 .** ** **

H1f Support External environment related factor Project success

.517 ** ** **

H3 Support Project success Overall project performance

.690 ** ** **

H4a Support Overall project performance Cost performance

.995 .** ** **

H4b Support Overall project performance Site disputes performance

-.314 .076 -2.452 .014

H4c Reject Overall project performance Environmental impact performance

-.080 .071 -.592 .554

H4d Support Overall project performance quality performance

-.715 .063 -6.950 ***

H4e Reject Overall project performance Safety performance

-.018 .056 -.102 .919

H4f Support Overall project performance Time performance

.517 .069 4.057 ***

** This is a construct whose regression weight turned out to be 1.000 hence does not have standard error (S.E) and critical ratio (C.R). *** These are constructs that are significant at all values of p.

The test results of these 13 hypotheses reveal that 11 of them are supported whereas 2

are not supported on the basis of data collected on CDF construction projects. As

regards the influence of CSFs on project success, it was found that all the hypotheses

are supported. These imply that these factors significantly influence project success.

Similarly, four of the six hypotheses pertaining to relationship between overall project

performance and KPIs were supported. Whereas cost and time had a direct

relationship with overall project performance, the relationship of overall project

performance with site disputes and quality was negative but significant. The

relationship between site disputes and overall project performance is expected to be

negative because an increase in site disputes will definitely affect project in terms of

157

completion time and cost. An examination into the nature of CDF projects shows that,

project stakeholders working on CDF construction projects strive towards completing

the projects as per the funds disbursed by the government. Therefore, they endeavour

to achieve good performance in terms of the tangible performance dimension of time

and cost. The findings also positively support the association between project success

and overall project performance.

7.5.3.2 Test of indirect impact of re-specified model

Table 7.25 shows the indirect effect estimates to test the mediating effect of external

environment related factor on the remaining five factors as hypothesized in H2a to

H2e.

Table 7.25: Indirect impact of re-specified model based on standardized regression weights

Hypothesis Exogenous factor

Mediating factor

Endogenous factor

Indirect effect.

Direct effect.

Total effect.

H2a Reject Client related factor

External environment related factor

Project success

-.193 .663

.470

H2b Reject Supply chain related factor

External environment related factor

Project success

-.107 .566

.459

H2c Reject Project related factor

External environment related factor

Project success

-.264 .738

-.474

H2d Reject Consultant related factor

External environment related factor

Project success

.020 .666

.686

H2e Reject Contractor related factor

External environment related factor

Project success

-.074 .631

-.557

Accordingly, the re-specified model indicates that the indirect effects were

significantly small, compared to total effects for all the five constructs. Therefore, all

the hypotheses in this section, H2a, H2b, H2c, H2d and H2e are rejected. The external

environment related factor does not significantly mediate the relationships between

project success and the five CSFs.

158

CHAPTER 8: CONCLUSION

8.0 Introduction

This chapter presents the conclusion of the study in several sections. The first section

summarises the findings of the study in relation to the objectives. The second section

discusses the managerial implications of this study while the third section provides

recommendations. The fourth section highlights the limitations of the study and

finally, the last section suggests future research directions.

8.1 A snapshot of summary findings

The purpose of the current study was to develop a performance evaluation framework

for assessing performance amongst public sector construction projects in developing

countries. In order to realise this objective, the researcher first conducted an extensive

review of the relevant literature in order to identify the existing body of knowledge in

the domain of performance measurement of construction projects. Based on the

review, performance indicator variables and the variables that influence project

success were identified and discussed with the experts in the area of construction

management. The variables were refined and a survey instrument was designed. This

was subsequently administered to clients, consultants and contractors who had been

involved in the CDF projects in the Western province, Kenya. The demographic

statistics regarding project characteristics and respondents’ profile were analysed

using Chi-square test of independence and one way Analysis of Variance (ANOVA).

The relevance of the performance indicator variables and success related variables

amongst CDF construction projects in Kenya was established through EFA, CFA and

SEM.

The study resulted in a set of KPIs that reflect the economic, social and environmental

dimensions of public sector construction projects. Further, the study identified and

confirmed a set of CSFs based on the KPIs which would enable the projects to

achieve performance on the identified KPIs. Finally, based on the two scales, one for

KPIs and the other for CSFs, a performance evaluation framework was developed.

The relationships on the developed framework were hypothesised and analysed using

SEM.

159

These ensured that all the research objectives are addressed. A snapshot of summary

findings in relation to the objectives is given below.

The occurrence of time overrun, cost overrun and quality defects does not vary

on the basis of the type of CDF construction projects. All types of projects are

prone to these problems pointing towards the need for other factors to be

considered.

Respondents’ experience has no relationship with the occurrence of time

overrun, cost overrun and quality of defects on CDF construction projects.

Most of these projects are characterised by standard procedures which guide

the construction process.

The occurrence of time overrun and quality defects on CDF construction

projects does not vary with the project procurement method. However, the

occurrence of cost overrun varies across different procurement approaches.

This is because different procurement approaches have implications on how

project costs are computed and appropriated amongst different parties who are

responsible for undertaking construction.

Project performance of CDF construction projects are evaluated on the basis

of six KPIs namely project time, cost, quality, safety, site disputes and

environmental impact. These KPIs address the economic, social and

environmental dimensions of public sector construction projects.

Whilst not all the KPIs are significant in terms of their relationship with

project performance, there is significant evidence and support for

measurement of project performance on the basis of time, cost, quality and site

disputes.

There are six CSFs that influence success of public sector construction

projects: project-related factor, client-related factor, consultant-related factor,

contractor-related factor, supply chain related factor and external

environment-related factor.

All these six CSFs assessed are significant, providing empirical support for

considering them as factors that influence success of public sector construction

projects.

160

The external environment related factor does not mediate the influence of the

remaining CSFs on project success.

Client related and project related factors; client related and consultant related

factors; and contractor related and supply chain related factors are inter-

correlated.

Success of public sector construction projects has a significant positive

association with overall project performance on the various KPIs. This

supports inclusion of the two concepts in the performance evaluation

framework for assessing performance of public sector construction projects.

These findings are briefly described in the following sections.

8.1.1 Summary findings regarding the relationship between projects’

characteristics, respondents’ profile and occurrence of time overrun, cost

overrun and quality defects.

In the exploratory study, it was found that majority of the projects funded under CDF

were Educational in nature followed by Health Care facilities while the number of

Industrial Estates and Agricultural Markets turned out to be the same. Most of these

projects were found to have been procured through the negotiated general contract

approach. With regard to cost overrun, time overrun and quality defects, it was found

that majority of projects got delayed but in most cases they met budgetary allocations

and quality specifications. With regard to respondents’ profile, majority of the

respondents were clients owing to their number in the target population, followed by

contractors and then consultants. Most of these respondents were found to posses

several years of experience in which they worked on relatively large projects as

evidenced by the value of the projects. These findings were confirmed in the study in

phase II, except that unlike in the exploratory study where the number of projects

under Industrial Estates and Agriculture was the same, the number of Industrial

Estates came out to be the least.

While examining the occurrence of time overrun, cost overrun and quality defects

across different types of projects in Phase II, it was found that the extent of

occurrence of cost overrun, time overrun and quality defects did not differ across the

161

different types of projects. Similarly, it was found that project procurement approach

did not have any effect on the occurrence of time overrun and quality defects.

However, the occurrence of cost overrun was found to be dependent on the type of

project procurement approach. While examining the relationship between

respondents’ experience and the incidences of time overrun, cost overrun and quality

defects, the results show that respondents’ experience has no effect on the occurrence

of any of the three indicators of project performance.

8.1.2 Summary findings regarding KPIs

The KPIs of overall project performance of CDF construction projects were assessed

at three levels. First, based on literature review and discussion with experts, a list of

35 performance related variables (shown in table 8.1) was identified. At the second

level, performance measurement variables were refined through EFA. This resulted in

27 performance variables which loaded into six dimensions of overall project

performance namely time, cost, quality, safety site disputes and environmental impact

as can indicated in table 8.1. The empirical findings of the study and the subsequent

analyses suggest that the performance of public sector construction projects does not

merely depend on the traditional internal criteria of time, cost and quality. It also

depends on another internal measure, safety and two external measures namely site

disputes and environmental impact. At the exploratory level, it was found that project

time is the most important KPI followed by cost while safety comes last in the order

of importance.

In the third step, the 27-variable six-factor of KPIs scale was further analysed using

CFA. The analyses resulted in a 17-item six construct measurement scale for CDF

construction projects. Test statistics of both first order and second order measurement

models are acceptable for performance measurement amongst CDF construction

projects. Table 8.1 summarises the findings of the three steps used in assessing KPIs.

162

Table 8.1: Summary of the dimensions of KPIs and performance measurement variables in both survey I and survey II Literature review and discussion with experts (Performance variables)

Exploratory Study (Phase I) Confirmatory Study (Phase II)

PV1: There has not been any increase in the cost of raw materials during construction of this project. PV2: Labour costs more or less remained stable over the period of construction of the current project. PV3: The project experienced minimum variations and hence hardly any additional cost attributable to variations was incurred. PV4: The required equipments were available at pre budgeted rates. PV5: The amount/quantity of different type of resources required during the implementation phase matched with those estimated during planning stage. PV6: There were no incidences of fraudulent practices and kickbacks during project execution. PV7: There were no incidences of agitation by the trade unions in the current project. PV8: There were no serious dispute between the client and contractor due to non adherence to the specifications. PV9: Disputes were observed due to the frequent changes in the design of the current project. PV10: Dispute resolution meetings were often held during project execution. PV11: At time of project completion, there were no financial claims that remained unsettled from this project. PV12: This construction project has adversely affected the quality of groundwater level. PV13: All required resources for the project were delivered on time during execution of this project. PV14: A clear plan was formulated and an efficient planning and control system was designed to keep the current project up-to-date. PV15: No changes were introduced in the designs of the current during project execution. PV16: Harmonious relationship between labour and management existed in the project site and hence no work disruptions were reported during project

Dimension Items Dimension Items Time Performance (7)

TPV1: Timely delivery of resources TPV2: Harmonious relationship on site. TPV3: A clear plan was formulated. TPV4: No delays in securing funds. TPV5: No effect of weather and climatic conditions. TPV6: No design changes. TPV7: At handover there were no apparent defects

Time Performance (3)

TPV1: Timely delivery of resources TPV2: Harmonious relationship exists on site TPV4: No delays in securing funds

Cost Performance (6)

CPV1: Equipments at pre budgeted rates. CPV2: Stable labour costs CPV3: No increase materials cost CPV4: Minimum variations co CPV5: Adverse effect on quality of groundwater level. CPV6: No financial claims at completion.

Cost Performance (3)

CPV1: Equipments available at pre budgeted rates CPV2: Stable labour costs CPV3: No increase in materials cost

Site Disputes DPV1: No serious dispute Site Disputes DPV1: No serious

163

execution. PV17: This project has led to air pollution in the adjoining areas. PV18: This project has led to depletion of the precious natural and mineral resources in the surrounding areas. PV19: There has been an increase in solid waste due to the construction of the current project. PV20: Accidents were often reported during project construction. PV21: Near misses occurred quite often during construction. PV22: Fatalities did occur on this project during construction. PV23: The construction work utilised environmentally friendly technology. PV24: This project has led to the increased release of toxic material. PV25: No delays were experienced in securing funds during project implementation. PV26: At the time of handover, the current project was free from apparent defects PV27: The project contractors were often called back during the Defects Liability Period to repair defects. PV28: Weather and climatic conditions did not have much impact on delaying the project. PV29: The current project has utilised reusable and recyclable materials in construction work. PV30: The right material was used for the construction work. PV31: Employees working in the current project possessed requisite skills and most of them had worked on similar kinds of projects in the past. PV32: A sound quality management system was strictly adhered to during project execution phase of the current project. PV33: Training was imparted to the workers in order to develop a positive attitude and also to enable them to apply the right method of work. PV34: All stakeholders associated with the current project supervised the quality of the project in all its phases. PV35: Proper medical facilities were available for people working on the project

Performance (4)

due to specifications. DPV2: Disputes due to the frequent changes DPV3: No incidences of trade union agitation DPV4: Dispute resolution meetings

Performance (3) protests by the community due to the nature of the project DPV2: Disputes due to frequent changes in designs DPV3: No incidences of trade union agitation

Environmental impact Performance (4)

EPV1: Project has led to air pollution. EPV2: Increased solid waste. EPV3: Utilised environmentally friendly technology. EPV4: Project has led to depletion natural resources.

Environmental impact Performance (3)

EPV1: Project has led to air pollution EPV2: Project has given rise to increase in solid waste EPV3: Utilised environmentally friendly technology

Quality Performance (3)

QPV1: Right material was used for the construction work. QPV2: A sound QMS adhered to. QPV3: Workers were trained on positive attitudes

Quality Performance (3)

QPV1: Right material was used for the construction work QPV2: A sound QMS was adhered to QPV3: Workers were trained on positive attitudes

Safety Performance (3)

SPV1: Accidents were reported. SPV2: Fatalities did occur. SPV3: Near misses occurred.

Safety Performance (2)

SPV1: Accidents were reported SPV2: Fatalities did occur.

164

The results show that the cost construct has positive correlation with time construct

and negative correlation with quality construct. However, quality performance

deteriorates when cost performance improves. The second order measurement model,

shows that the quality constructs possesses the maximum explanatory power. It is

also the most reliable amongst the KPIs. However, all the other KPIs were also found

to have adequate explanatory power of overall project performance. This indicates

that the measurement items across all constructs may be considered as valid and

reliable which may be successfully utilized by the project managers while evaluating

construction projects. The CFA findings of the second order measurement model

reveal that cost is the most important followed by quality whereas safety comes last.

8.1.3 Summary findings regarding CSFs

The procedure of identifying and confirming CSFs was also carried out in three

stages, (literature review, exploratory phase and confirmatory phase), similar to the

stages enumerated in section 8.1.2. A list of 30 variables (shown in table 8.2)

influencing project success was identified based on literature review and discussion

with experts. These variables were subjected to EFA which yielded 27 success

variables loading in six components representing project success namely project

related, client related, consultant related, contractor related, supply chain related

and external environment related factors. Out of the six success factors, client

related, consultant related and contractor related factors are stakeholder based

whereas project related factor is based on project features and characteristics. Supply

chain related factor is based on management processes in terms of sourcing and

delivering of right materials and components in time and external environment

related factor addresses all environmental issues that affect project success. The

relative importance of the six CSFs varies. The results reveal that project related

factor is the most important factor followed by client related factor while contractor

related factor turns out to be the least in order of importance.

The 27-item six factor scale of CSFs was further analysed using CFA which resulted

in 17 item six construct scale of CSFs for CDF construction projects. Table 8.2

summarises the findings of the qualitative analysis, exploratory analysis and the

confirmatory analysis.

165

Table 8.2: Summary of the CSFs and success variables in both survey I and survey II. Literature review and discussion with experts (Success Variables)

Exploratory Study (Phase I) Confirmatory Study(Phase II)

SV1: The location and Site conditions did not affect the construction of this project. SV2: Design Complexity of project (Type, size, nature and number of floors) has influenced the project cost and time. SV3: Project planning, Scheduling and control were adequately done on this project SV4: The client secured necessary funds for the project and hence there were no delays in material acquisition and payments to contractor. SV5: The client got the design documents approved on time for this project. SV6: The client had adequate experience on similar kind of projects. SV7: Information sharing and collaboration among project participants were adequate in the current project. SV8: The construction work adhered to the requisite Quality standards. SV9: Continuous monitoring of actual expenditures and project schedules and their comparison with the budget was done regularly. SV10: There was a formal organization structure for dispute resolution within the project organization. SV11: Site Managers possessed requisite skills necessary for the kind of projects executed. SV12: The contractor had adequate technical skills and experience on similar type of projects. SV13: The contractor used latest construction methods in the project. SV14: The community did not raise any social, political or cultural issues against construction of the current project. SV15: The project execution was adversely affected by the surrounding weather and climatic conditions. SV16: Macro- economic conditions (such as interest rates, inflation) did not

Dimension Items Dimension Items Project Related Factor (7)

PSV1: Influence of Design Complexity PSV2: Adhered to the requisite Quality standards. PSV3: Continuous monitoring of actual expenditures. PSV4: Formal dispute resolution structures. PSV5: Effect of location and Site conditions. PSV6: Adequate Information sharing and collaboration. PSV7: Adequate Project planning and, Scheduling.

Project Related Factor (4)

PSV1: Influence of Design Complexity PSV2: Adhered to the requisite Quality standards PSV3: Continuous monitoring of actual expenditures PSV4: Formal dispute resolution structures

Client related factor(5)

CSV1: Adequate experience on similar projects. CSV2: Cheap materials were used. CSV3: Project funds secured on time. CSV4: Client’s emphasis on time rather than quality. CSV5: Design documents approved on time.

Client related factor (3)

CSV2: Cheap materials were used CSV4: Client’s emphasis on time rather than quality CSV5:Design documents approved on time

External environment related factor (6)

ESV1: Community had no issues against the project. ESV2: Adversely affected by the surrounding weather.

External environment related factor (3)

ESV1: Community had no issues against the project ESV2: Adversely

166

significantly affect the execution of this project. SV17: The project was affected by the Governance policy of the relevant government agencies which affects project success. SV18: The consultant was highly committed to ensuring construction work according to design specifications. SV19: There were adequate designs, specifications and documentations for the use of contractor. SV20: The client emphasized on completing the current project very fast without any reference to quality. SV21: The client tended to purchase construction materials at cheaper rate which led to the dilution of other project objectives. SV22: No variations in original design took place in the current project during construction phase. SV23: The level of technological sophistication considered in the project was satisfactory. SV24: There were no incidences of disagreements resulting from industrial relations prevailing at the time of project implementation. SV25: The physical and ecological conditions surrounding the project were favourable to project execution. SV26:There were very few internal procurement challenges SV27: The client’s decisions were timely and objective. SV28: Right equipments were available in the construction site of this project. SV29: The project faced stringent insurance and warranty contractual requirements. SV30: Working capital was adequate.

ESV3: Effect of the Governance policy. ESV4: Favourable physical and ecological conditions. ESV5: Effect of Macro- economic conditions. ESV6: No incidences industrial unrests.

affected by the surrounding weather ESV3: Effect of the Governance policy

Supply chain related factor (3)

LSV1:Few internal procurement challenges LSV2: Right equipments were available. LSV3: Effect of stringent insurance/warranty rules.

Supply chain related factor (3)

LSV1: Few internal procurement challenges LV2: Right equipments were available LSV3: Effect of stringent insurance/warranty rules

Consultant related factor (3)

SSV1: No variations were incorporated. SSV2: Adequate designs/specifications and documentations. SSV3: Adequate consultant committed to project.

Consultant related factor (2)

SSV1: No variations were incorporated SSV2: Adequate designs/specifications and documentation

Contractor related factor (3)

RSV1: Site Managers possessed requisite skills. RSV2: Contractor had adequate technical skills. RSV3: Contractor used latest construction methods.

Contractor related factor (2)

RSV1: Site Managers possessed requisite skills RSV2: Contractor had adequate technical skills.

167

Testing of the first order measurement model and the second order measurement

model (that includes mediation of external environment related factor) through

appropriate test statistics indicate that both models are acceptable. In the first order

model, some constructs are found to be positively correlated while others are

negatively correlated. For instance, project related construct has positive correlation

with client related construct and negative correlation with environment construct. This

probably indicates that the positive influence of project related factor is accompanied

by the positive influence on client related factor and vice-versa. However, the

influence of project related factor on environment is negative.

The first order model further shows that the project related construct possesses the

maximum explanatory power followed by consultant related construct while the

environment related construct has the minimum explanatory power. Further project

related construct is also has the highest reliability. Similarly the remaining five

constructs were also found to posses adequate scale reliability. This indicates that the

measurement items across all constructs may be considered as valid and reliable

which may be successfully utilized by the project managers for evaluating CSFs of

construction projects.

The second order construct and its relationships with the first order constructs enables

project managers to view the project success at a higher level. Due to this, the model

could reveal patterns of relationships among the constructs which are otherwise not

visible in the first order model. The second order model shows that all the six CSFs

are important in determining the success of CDF construction projects, as shown

through the standardised second order loadings. The external environmental related

factor possess the most influence on project success followed by project related factor

while supply chain related factor has the least influence.

8.1.4 Summary findings regarding the Performance Evaluation Framework

A SEM was developed to evaluate the impact of CSFs on project success. Further, it

was hypothesised that project success is positively associated with overall project

performance which is again expressed in terms of time, cost, quality, safety, site

disputes and environmental impact. The reliability of the twelve constructs and of the

168

model was found satisfactory. The GOF indices of the structural model were also

found quite satisfactory. However, not all the path coefficients were significant.

The influence of CSFs on project success

The results indicate that all the CSFs are appropriate success factors for CDF

construction projects since they have high factor loadings that are significant

at 5%. Based on the loadings of these CSFs on project success, it can be stated

that the most important CSF is project-related factor, followed by consultant-

related factor, client-related factor, contractor-related factor, supply chain-

related factor and external environment-related factor in descending order of

importance.

The results of the SEM model also suggest that mediation of external

environment related factor into the relationships between project success and

each of the CSFs is not fully supported.

The association between project success and overall project performance

Given that all the CSFs were found to influence the success of CDF

construction projects, the main challenge facing these projects is still

construction management which is undertaken by the client, consultants and

contractors. The success of construction management is reflected through

overall project performance. The association of project success and overall

project performance was found to be significant and positive indicating that

the two concepts are related in the assessment of project performance.

The relationship between overall project performance and KPIs

Results of SEM indicate that “cost” is the predominant indicator of overall

project performance followed by “quality”, “time” and “site disputes” in that

order. Three of these indicators cost, time and quality are well represented in

the literature on the “iron triangle” and have not been contradicted in the

current study. “Site disputes” being a contemporary measure of performance,

is an addition to the iron triangle emerging from the current study which seeks

to ensure harmony at the construction site (David, 2009; Tabish & Jha, 2011).

169

The remaining two performance indicators, safety and environmental impact

were not significant. The reason for this insignificant relationship of safety

with overall project performance seems to be its intangibility. Further, the

outcome of environmental impact of a project becomes evident long after the

construction process is completed. Because of this, it may not occur to the

project stakeholders that a project may have some adverse environmental

impact.

Whereas cost and time performances were positively related to overall project

performance, quality and site disputes performance were negatively related.

8.2 Managerial implications of the findings

The findings of the current study have several implications to the managers and

stakeholders involved in the implementation of public sector construction projects.

Below is a brief description of these implications.

The findings of the study on project characteristics and respondents’

demographic profile imply that some of the project procurement approaches

are more cost effective than others.

The findings of KPIs imply that public sector construction projects can be

evaluated on the basis of six KPIs namely cost, time, quality, site disputes,

safety and environmental impact. The positive and negative relationships

among the KPIs give important insights to the managers to the fact that when

performance on one KPI improves, the performance on the other KPIs might

improve or deteriorate.

The final findings of KPIs also imply that while measuring performance of

public construction projects, project cost is the most important performance

indicator, followed by time, quality and site disputes.

Findings reveal that cost and time performance are positively related to overall

project performance whereas quality and site disputes are negatively related to

overall project performance. This implies that improvement in cost and time

performance will improve overall project performance whereas insistence on

quality and site dispute resolution could undermine overall project

170

performance. Therefore project stakeholders consider pursuance of quality as

an effort that requires additional cost and time thereby impacting negatively

on overall project performance.

Further, the findings also imply that while implementing public sector

construction projects, there are six CSFs that influence the success of public

sector construction projects. Project success can therefore, be evaluated on the

basis of each individual success variables which may be used as a check list to

pinpoint areas of weaknesses which may need to be corrected in case of

unsatisfactory performance on a particular item.

Project related factor is relatively more important on success of public sector

construction projects implying that project characteristics are likely to have

significant impact on the project than the remaining factors. Therefore, the

findings provide insights to the managers in terms of how to monitor the

progress of public construction projects based on CSFs.

Further, the inter-correlations amongst three pairs of CSFs imply that project

stakeholders should take a holistic view of CSFs while determining their

influence on project success as one CSF is likely to be associated with another

CSFs

Similarly, the findings imply that project success and overall project

performance are distinct components of a performance evaluation framework.

They are however associated although each is captured through different

constructs.

8.3 Recommendations

The project stakeholders can use this performance evaluation framework to clarify

their understanding of performance of public sector construction projects during

construction and be able to take corrective action in order to improve overall

performance. It is therefore, recommended that project stakeholders should

Consider using those project procurement approaches which are cost effective

in order to avoid cost overrun on the projects.

171

Understand the needs of the community through proper involvement of the

representatives of the community and other stakeholders and accordingly

select suitable projects which would cater to their needs.

Understand the urgency of evaluating public sector construction projects on

multi-dimensional performance measures incorporating economic, social and

environmental aspects. Develop appropriate operational metrics to reflect the

three broad dimensions of performance of public sector construction projects.

Develop a holistic performance evaluation framework of public sector

construction projects consisting of the six KPIs with the help of 17 observable

performance related variables.

Allocate considerable amount of resources into the issues relating to project

time, cost, quality and site disputes of public construction projects. This is

because cost, time, quality and site disputes were relatively more important.

On the basis of KPIs, identify the CSFs that are appropriate for attainment of

success on the various KPIs and consider monitoring the progress of public

sector construction projects on the basis of CSFs.

Put more emphasis on project characteristics as they ranked higher in

importance among the CSFs influencing project success. However, the

contractors play an important role in the day-to-day management of the

construction activity. Thus even though the other factors were not ranked as

high as the project related factor, the managers should allocate sufficient

resources to the remaining factors as well which would enable them to

achieve satisfactory success on these CSFs for public sector construction

projects.

Distinguish between successful project implementation and overall project

performance and utilize the framework developed to compare success of

different types of construction projects on different CSFs. Similarly, project

managers could compare overall project performance of different projects

based on specific performance indicators.

8.4 Limitations of the study

The current study suffers from the following limitations

172

The responses to the questionnaire were based on perceptions of respondents

regarding the performance measurement variables and project success

variables. However, the frame of mind of the respondents may differ, and

hence, the responses provided are fraught with some element of subjectivity.

Secondly, the study was based on the perceptions of clients, consultants and

contractors but left out the community which actually benefits from the public

sector construction projects and for whom the projects are expected to be

relevant. The study did not consider community satisfaction with project

implemented though this is one of the desired outcomes of public construction

projects.

Further, there could be direct interactions between CSFs and the various KPIs.

The scope of the current study could not allow the researcher to examine such

direct relationships.

Similarly, the data for the development of the measurement instrument was

gathered in one province in Kenya. The prevailing circumstances in Western

province, Kenya could be different from the circumstances in other provinces

in Kenya and other developing countries.

Further these projects are characterized by the involvement of many

stakeholders with varying interests, numerous bureaucratic hassles and of

course, varying political interests, which facilitates corruption. Corruption

which includes bribery, embezzlement, kickbacks and fraud in construction

projects undermines the delivery of infrastructure services. These practices can

lead to increases in cost, extension of time and poor quality of constructed

facilities. The element of corruption has not been included in the present

study.

8.5 Directions for Future Research

This section recommends some potentially useful future research that can address

some of the limitations of this study.

Researchers could undertake a study in performance evaluation from the

perspectives of the community which constitutes the actual beneficiaries of the

173

projects. In such a study, the level of community satisfaction with the projects

implemented can be addressed.

Further future studies can attempt to identify the direct relationship between

the CSFs and KPIs through empirical studies. Also, future studies may

examine moderating factors that may have an effect on the relationship

between CSFs and project success.

Future researchers could advance the current construction project performance

evaluation scale and test its applicability within the context of other

constituencies in different regions in Kenya and those projects in other

developing countries. There is, therefore, an important need to undergo cross-

cultural validation of the instrument using data gathered from other provinces

of Kenya and other developing countries as well in order to enhance the

generalization of items.

Finally, a study incorporating the effect of corruption in performance

evaluation of public sector construction projects is of great importance. This is

because the intended objectives of public sector construction projects can be

properly realised in a corruption free environment. It is a well known fact that

these kinds of projects are severely affected by the scams prevalent in many

countries.

REFERENCES

Aaltonen, K., & Jaakko, K., (2010). A project lifecycle perspective on stakeholder

influence strategies in global projects. Scandinavian Journal of Management

(2010) 26, 381—397.

Abidin, A., (2007). The Profile of Construction Disputes. Unpublished Masters

Dissertations, Universiti Teknologi, Malaysia, Skudai

Abdul R. R., Taib W. B., Ahmad M. A., Nasid, N. A., & Zainordin Z.M. (2006).

Effect of procurement systems on the performance of construction projects.

International Conference on Construction Industry, Padang, Indonesia, 21-25th

June.

174

Abdul-Kadir, M. R., & Price, A. D. F., (1995). Conceptual phase of construction

projects International Journal of Project Management, Volume 13, Issue 6,

December 1995, Pages 387–393

Abdullah, M. R., Abdul, A. A. A., & Abdul, R.I., (2009). Potential effects on large

MARA projects due to construction delay. International Journal of Integrated

Engineering (Issue on Civil and Environmental Engineering) 1(2): 53-62.

Abudayyeh, O., Fredericks, T., Butt, S., & Shaar, A., (2006). An investigation of

management’s commitment to construction safety. International Journal of

Project Management, 24(2), pp. 167-174.

African Economic Outlook, (2012). Kenya Macroeconomic Policy. Retrieved from

www.africaneconomicoutlook.org/en..

Ahadzie, D.K., Proverbs, D. G., & Olomolaiye, P.O., (2008). Critical success criteria

for mass house building projects in developing countries. International Journal of

Project Management, 26 (6), 675–687.

Ahsan, K., & Gunawan, I., (2010). Analysis of cost and schedule performance of

international development projects, Original Research Article. International

Journal of Project Management, Volume 28, Issue 1, January 2010, Pages 68-78.

Alba F., Miquel, C., Marta, G., Nuria F., Marcel M., & Xavier R., (2013). An

Environmental Impact Causal Model for improving the environmental

performance of construction processes. Journal of Cleaner Production, 52

(2013).

Al Haadiri, S., & Panuwatwanich, K., (2011). Critical Success Factors for Safety

Program Implementation among Construction Companies in Saudi Arabia.

Procedia Engineering Volume 14, (2011), Pages 148-155.

Ali, A.S., & Rahmat, I., (2010). The performance measurement of construction

projects managed by ISO-certified contractors in Malaysia. Journal of Retail &

Leisure Property (2010) 9, 25–35.

Ali, A.S., & Kamaruzzaman, S.N., (2010). Cost Performance for Building

Construction Projects in Klang Valley. Journal of Building Performance, 1 (1),

110 - 118.

Al-Momani, A.H., (2000). Construction delay: A quantitative analysis, International

journal of Project Management, 18 (2000) 51-59.

175

Alwaer, H. & Clements-Croome, D.J., (2010). Key performance indicators (KPIs) and

priority setting in using the multi attribute approach for assessing sustainable

intelligent buildings, Building and environment 45 (2010) 799-807.

Al-Kharashi, A., & Skitmore, M., (2008). Causes of delays in Saudi Arabian public

sector construction projects. Construction Management and Economics, 27(1).

pp. 3-23.

Al-Tmeemy, S. M. H., Abdul-Rahman, H., & Harun, Z., (2011). Future criteria of

success of building projects in Malaysia. International Journal of Project

Management, 29 (3), 337-348.

Alwi, S., Hampson, K., & Mohamed, S., (2002). Waste in the Indonesian

Construction Project. Proceedings of the 1st International Conferences of CIB

W107 – Creating a Sustainable Construction Industry in Developing Countries,

11-13 November 2002, South Africa, ISBN: 0-7988-5544-4, pp. 305-315.

Alzahrani, J. I., & Emsley M. W., (2013). The impact of contractors’ attributes on

construction project success: A post construction evaluation. International

Journal of Project Management, 31 (2013) 313–322.

Ameh, O.J., Soyingbe, A.A., & Odusami, K.T., (2010). Significant factors causing

cost overrun in telecommunication projects in Nigeria. Journal of Construction in

Developing Countries, 15 (2), 49-67.

Ankrah, N. A., & Proverbs, D (2005). A framework for measuring construction

project performance:overcoming key challenges of performance measurement.

In: Khosrowshahi, F (Ed.), 21st Annual ARCOM Conference, 7-9 September

2005, SOAS, University of London. Association of Researchers in Construction

Management, Vol. 2, 959-69.

Assaf, S.A., & Al Hejji, S., (2006). Causes of delay in large construction projects.

International Journal of Project Management, Vol. 24, pp. 349-361.

Atkinson, R., (1999). Project management: cost, time and quality, two best guesses

and a phenomenon, it’s time to accept other success criteria. International

Journal of Project Management 17, 337–342.

Awiti, V.P., (2008). An Assessment of the use and management of Development

Funds. The case of Constituencies Development Fund in Kenya. Unpublished

176

masters dissertation submitted to the institute of Social Studies for MA in

Development Studies, Hague, Netherlands.

Azhar, S., Ahmed, S.M., & Ahmad, I., (2002). Supply chain management in

construction scope, benefits and barriers. Delhi Business Review Vol. 3, No. 1,

January - June 2002.

Azhar,N., Farooqui, R.U., & Ahmed, S.M., (2008). Cost overrun factors in

construction industry in Pakistan. First International Conference on Construction

in Developing countries (ICCIDC-I, advancing and integrating construction

education, research and practice).

Barasa, R. M., (2010). Review of Constituencies Development Fund Projects A North

Rift Case Study, October 2010 3rd Draft No.37. www.afrepren.org/Pubs/

WorkingPapers/wpp378_ sum.htm Accessed on 15/05/2012

Barclay, C., Osei-Bryson, K.M., (2010). Project performance development

framework: an approach for developing performance criteria & measures for

information systems (IS) projects. International Journal of Production Economics

124, 272–292.

Basheka, B. C., & Tumutegyereize, M., (2012). Measuring the performance of

contractors in government construction projects in developing countries:

Uganda’s context. African Journal of Business Management Vol. 6(32), pp.

9210-9217, 15 August, 2012.

Baskin, M., (2010). Constituency Development Funds (CDFs) as a tool of

Decentralised Development. 56th Commonwealth Parliamentary Conference,

Nairobi, Kenya, 10th-19th September.

Bassioni, H., Price, A., & Hassan T., (2004). Performance Measurement in

Construction. Journal of Management Engineering, 20(2), 42-50.

Beck, T., (2006). Evaluating humanitarian action using the OECD-DAC criteria: An

ALNAP guide for humanitarian agencies. London, UK: Overseas Development

Institute.

Billy, H., Cameron, I., & Duff, A.R., (2006). Exploring the integration of health and

safety with pre-construction planning. Engineering, Construction and

Architectural Management, 13(5): 438-450.

177

Blake, D.W., (2008). Scope for Improvement: A Survey of Pressure Points in

Australian Construction and Infrastructure Projects. A Report Prepared for the

Australian Constructors Association by Blake Dawson Waldron Lawyers,

Sydney, Australia. Retrieved from http: //www.constructors.com.au/

publications/sfi_2008/ACA_ Scope_for_Improvement_2008.pdf.

Blindenbach-Driessen, F., (2006). Innovation management in project-based firms,

Doctoral thesis, School of Management Erasmus University, Rotterdam.

Blyth, A. and Worthington, J. (2001). Managing the Brief for Better Design. Spon,

London.

Bon-Gang H., Xianbo Z., & Si Yi N., (2013). Identifying the critical factors

affecting schedule performance of public housing projects. Habitat

International 38, 214-221Online publication date: 1-Apr-2013.

Bordoli, D.W. & Baldwin, A.N., (1999). A methodology for assessing construction

project delays. Construction Management and Economics, Vol. 16, pp. 327-37.

Borvorn I.N. A., (2011). Common disputes related to public work projects in

Thailand. Songklanakarin Journal of Science and Technology, 33 (5), 565-573,

Sep. - Oct. 2011.

Briscoe, G., & Dainty, A., (2005). Construction supply chain integration: an elusive

goal? Supply Chain Management: An International Journal, Vol. 10 Iss: 4,

pp.319 – 326.

Bryde, D. J., & Robinson, L., 2005. Client versus contractor perspectives on project

success criteria. International Journal of Project Management, 23(8), 622—629.

Cao, Q., & Hoffman .J .J. (2011). A case study approach for developing a project

performance evaluation system. International Journal of Project Management 29

(2011) 155–164.

Chalabi, F.A. & Camp, D., (1994). Causes of delays and overrun of construction

projects in developing countries, CIB Proceedings, no. 2, pp. 723-34.

Chan, A. P.C., (2001). Design and build project success factors: multivariate analysis,

Journal of construction engineering and management 93–100 Mar/Apr.

Chan, A.P.C., & Chan, A.P.L., (2004). Key performance indicators for measuring

construction success. Benchmarking: An international journal 11, 203–221.

178

Chan, A.P.C., & Tam, C.M., (2000). Factors affecting the quality of building projects

in Hong Kong. International Journal of Quality & Reliability Management, 17

(4/5), 423 – 442.

Chan, D. W. M., & Kumaraswamy, M. M., (1997). A comparative study of causes of

time overrun in Hong Kong construction projects,’ International Journal of

Project Management, 15(1), 55–63.

Chen, Y., Okudan, G. E., & Riley, D. R.,(2010). Sustainable performance criteria for

construction method selection in concrete buildings, Automation in Construction

Article in Press, Corrected Proof, doi:10.1016/j.autcon.2009.10.004.

Chianca, T., (2008). The OECD/DAC Criteria for International Development

Evaluations: An Assessment and Ideas for Improvement. Journal of Multi-

Disciplinary Evaluation 2008; 5(9): 41-51.

Cooke-Davis, T., (2002). The ‘real’ success factors on projects. International Journal

of Project Management, Vol. 20, pp 185-190.

Constituency Development Fund (CDF) Act, (2003), Republic of Kenya.

Construction users roundtable (CURT), ( September, 2005 report). Construction

Measures: Key Performance Indicators. UP-101. Retrieved from

http://www.nwoglca.org/PDF_Files/Construction%20Measures_Key%

20Performance%20Indicators.pdf

Costa, D. B. & Formoso, C. T. (2004). Evaluating performance measurement systems

for construction companies, In: Aouad, G., Amaratunga, D., Kagioglou, M.,

Ruddock, L.and Sexton, M. (Eds.), The International Salford Centre for Research

and Innovation(SCRI) Research Symposium.

Coursaris, C.K., Sweirenga, S.J., & Watrall, E. (2008). An Empirical Investigation of

color Temperature and Gender Effects on Web Aeshetics. Journal of Usability

Studies, Volume 3, Issue 3, May 2008, pp. 103-117.

Datta, M., (2004). Challenges Facing the Construction Industry in Developing

Countries. http://citeseerx.ist.psu.edu/viewdoc/summary?doi=10.1.1.194.6404

accessed 07/06/2013.

David, W., (2009). Public-Sector Project Management. John Wiley and Sons, Inc.

Hoboken, New Jersey.

179

Diallo, A., & Thuillier, D., (2005). The success of international development projects,

trust and communication: An African perspective. International Journal of

Project Management, 23(3), 237—252.

Ding, G.K.C., (2005). Developing a multicriteria approach for the measurement of

sustainable performance. Building Research & Information, Vol. 33 No. 1, pp. 3-

16.

Enshassi, A.,Mohamed, S., and Ekarriri, A., (2009). Essential Skills and Training

Provisions for Building Project Stakeholders in Palestine. Journal of

Construction in Developing Countries, 14 (1), 31- 50.

Eriksson, P.E., & Westerberg, M., (2011). Effects of cooperative procurement

procedures on construction project performance: A conceptual framework.

International Journal of Project Management, 29 (2), 197-208.

Essam, K.Z., (2006). Construction claims in United Arab Emirates: Types, causes,

and frequency. International journal of Project Management vol. 24, no.5 pp

453-459, 2006.

Field, P.A., (2005). Discovering Statistics using SPSS, 2nd Edition. London. Sage.

Fortune, J & White, D., (2006). Framing of project critical success factors by a

systems model. International journal of Project management 24(2006) 53-65.

Frimpong, Y., Oluwoye, J. & Crawford, L., (2003). Causes of delays and cost overrun

construction of groundwater projects in developing countries, Ghana as a case

study, Journal of project management, 21, 321-326.

Gangolells M, Casals M, Gassó S, Forcada N, Roca X, & Fuertes A., (2009). A

methodology for predicting the severity of environmental impacts related to the

construction process of residential buildings. Building and Environment 2009;

44(3)

Gangolells M, Casals M, Gassó S, Forcada N, Roca X, & Fuertes A., (2011).

Assessing concerns of interested parties when predicting the significance of

environmental impact related to construction process of residential buildings.

Building and environment 46 (2011) 1023-1037.

Gardiner, K. S., (2000). Revisiting the Golden Triangle of Cost, Time, and Quality:

the Role of NPV in Project Control, Success, and Failure. International Journal

of Project Management 18 (4), 251-256.

180

Gemunden H., Salomo S. & Krieger A., (2005). The influence of project autonomy

on project success. International Journal of Project Management, 23 (2005), pp

366-373.

Global construction 2020, (2011). A report of Global construction perspectives and

Oxford Economics. www.globalconstruction2020.com (Accessed 27/03/2012).

Grace, F.M., (2010). Types of Construction Projects Article Source:

http://EzineArticles.com/?expert=Grace_F._M. Accessed o7/06/2013.

Halpin, D.W., & Woodhead, R.W., (2006). Construction management. 3rd Ed. New

York ; Chichester : Wiley.

Hamad A., & Sangwon H. (2013). Analysis of Causes of Construction Defects Using

Fault Trees and Risk Importance Measures. Journal of Construction Engineering

and Management 139:7, 870-880.

Harrison, P. (2007). Can measurement error explain the weakness of productivity

growth in the Canadian construction industry? International Productivity

Monitor, 14 (Spring): 53–70.

Haslama, R.A., Hidea, S.A., Gibbb, A.G.F., Gyia, D.E., Pavitt, T., Atkinsona, S., &

Duff, A.R. (2005). Contributing factors in construction accidents. Applied

Ergonomics 2005; 36:401–15.

Henricsson, P. & Ericsson, S. (2005). Measuring Construction Industry

Competitiveness: A Holistic Approach. Proceedings: The Queensland University

of Technology Research Week International Conference. Brisbane,Australia, 4–8

July.

Ibnu, A.M., 2006. Causes and Effects of delays in ACEH Construction Industry.

Unpublished MSc Thesis in construction management, Faculty of Civil

Engineering, University Technology Malaysia.

Ika L.A., Diallo A., & Thuiller D., (2012). Critical success factors for World Bank

projects. An Empirical Investigation. International journal of project

Management 30 (2012) 105-116.

ILO, (2001). The construction industry in the twenty first century: Its image,

employment prospects and skill requirements. International Labor Office,

Geneva.

181

Jahmane, A., Van Hoorebeke, D., & Louart, P., (2011). The link between financial

performance and the voluntary departure of personnel through a measurement

scale. Business and Management Review Vol. 1(6) pp. 48 – 61.

Jha N. K., & Iyer C.K., (2006). What attributes should a project coordinator possess’?

Journal of Construction Management and Economics, 24 (9), 977-988.

Jin X.H., Doloi, H., & Gao, S.Y. (2007). Relationship-based-determinants of building

project performance in China. Journal of Construction Management and

Economics, 25, 297–304.

Kaliba, C., Muya, M., & Mumba, K. (2009). Cost escalation and schedule delays in

road construction projects in Zambia. International Journal of Project

Management, 27 (5), 522-531.

Kaming, P. F., Olomolaiye, P. O., Holt, G. D., & Harris, F. C., (1997). Factors

influencing construction time and cost overrun on high-rise projects in Indonesia.

Construction. Management Economics, 15(1), 83–94.

Kamrul, A. & Indra, G., (2010). Analysis of cost and schedule performance of

international development projects Original Research Article, International

Journal of Project Management, Volume 28, Issue 1, January 2010, Pages 68-78.

Kenya National Bureau of Statistics (KNBS), (2010), Republic of Kenya.

Kerzner H., (2006). Project Management; A Systems Approach to Planning,

Scheduling, and Controlling, Ninth ed. John Wiley & Sons, Inc., Hoboken, New

Jersey.

Khan R.A., (2008). Role of Construction Sector in Economic Growth: Empirical

Evidence from Pakistan Economy. Proceedings of the first International

Conference on Construction in Developing Countries (ICCIDC–I) titled

‘Advancing and Integrating Construction Education, Research & Practice’,

August 4-5, Karachi.

Khosravi, S. & Afshari, H., (2011). A success measurement model for construction

projects. International conference on Financial management and economics

IPEDR Vol, 11 (2011) IACSIT Press Singapore www.ipedr.com vol.11/36-

wooo14.pdf. accessed 10/08/2012.

Kimani F., Nekesa P., & Ndung’u B., (2009). Best practices in Constituency

Development Fund (CDF). A paper prepared for the collaborative centre for

182

Gende and Development and International Development Research. Available:

www.ccentregd.org. Accessed 23/08/2012.

Kimenyi K. M., (2005). Efficiency and Efficacy of Kenya’s Constituency Development

Fund: Theory and Evidence. University of Connecticut, Department of

Economics Working Paper Series. Working Paper 2005-42 April 2005.

Koushki P.A., Al-Rashid, K., & Kartam N. (2005). Delays and cost increases in

construction of private residential projects in Kuwait. Journal of Construction

Management and Economics, 23(3), 285-294.

Kratzer J. Leenders R. & Van Engelen J. (2005). Informal contacts and performance

in innovation teams. International Journal of Manpower, 26 (6), pp. 513-528.

Kylindri, S., Blanes, G., Henriksen, L., & Tanev S., (2012). Measuring Project

Outcomes: A Review of Success Effectiveness Variables. Accessed 06/06/2012.

Available http://mibes.teilar.gr/proceedings/2012/ oral/Kylindri-Blana-

Henriksen-Tanev.pdf)

Leenders, R., Th. A. J., Van Engelen, J.M.L., & Kratzer J. (2003). Virtuality,

communication, and new product team creativity: social network perspective.

Journal of Engineering and Technology Management, 20, pp. 69-92.

Le-Hoai, L., Lee, Y.D., & Lee, J.Y. (2008). Delay and cost overrun in Vietnam large

construction projects: A comparison with other selected countries. Journal of

civil engineering; 12(6): 367-377.

Lim, C.S. & Mohamed, M.Z., (1999). Criteria for project success, an exploratory re-

examination. International Journal of Project management volume 17 no. 4 pp

243-248.

Litsikakis, D., (2009). Analysis of Project Success Criteria and Success Factors: How

to maximise success in your projects using meaningful criteria and factors.

Accessed on April 23, 2011. http://knol.google.com/k/dimitrios-litsikakis/

analysis-of-project-success-criteria/3ib8exvrc87n4/4.

Long, N.D., Ogunlana, S., Quang, T., & Lam K.C., (2004). Large construction

projects in developing countries: a case study from Vietnam. International

Journal of Project Management, 22 (7), 553–561.

183

Love P.E.D, Edwards, J.D., Watson, H & Davis, P., (2010). Rework in Civil

Infrastructure Projects: Determination of Cost Predictors, Journal of construction

Engineering and management, Volume 136, Issue 3, pp. 275-282 (March 2010).

Love, P.E.D., Iran, Z. & Edwards, J.D.A. (2004). Rework Reduction Model for

Construction Projects, IEEE transactions on engineering management, vol. 51,

no. 4, November 2004.

Malhotra, N.K. & Dash, S., 2011. Marketing research: An applied orientation. 6th

edn, Prentice Hall, New Jersey.

Mapesa, B. and Kibua, T., (2006). An Assessment of the Management and Utilization

of the Constituency Development Fund in Kenya. Discussion Paper No.076/2006.

IPAR Discussion Paper Series.

Marosszeky, R.T.M., Karim, K., David, S. & McGeorge, D., (2002). The importance

of project culture in achieving quality outcomes in construction. Paper presented

at the IGLC, Brazil, 2002. Retrieved from http://www.researchgate.net/

publication/ 228796833_ The_ importance_ of_project_culture_in_achieving_

quality_outcomes_in_construction.

Medineckiene, M ,Turskis, Z. & Zavadskas, E.K., (2010). Sustainable construction

taking into account the building impact of the environ, Journal of environmental

engineering and landscape management 18 (2), 118-127.

Memon, F.H., Ismail A. R., & Ade A. A. A., (2012). Time and Cost Perfomance in

Costruction Projects in Southern and Cenrtal Regions of Penisular Malaysia.

International Journal of Advances in Applied Sciences, Vol.1, No.1, March

2012, pp. 45~52.

Miles R.L., Greer, L., Kraatz, D. & Kinnear, S., (2008). Measuring community

wellbeing: A central Queensland case study. Australasian Journal of Regional

Studies, Vol. 14 No.4.

Murali, S., & Yau Wen, S., 2007. Causes and effects of delays in Malaysian

construction industry. International Journal of Project Management 25 517–526.

National Construction Corporation (NCC) Act, (1972, Republic of Kenya.

National Taxpayers Association, (2010). Citizen’s Constituency Development Fund

Report Card for Aldai Constituency, Nandi North District. DfID, March 10,

2009, pg. 22. 07/29/2010.

184

Ngacho, C., & Das, D., (2013a). A performance evaluation framework of public

construction projects: An Empirical study of Constituency Development Fund

(CDF) Projects in Kenya, International Journal of Project Management (Under

final revision for publication).

Ngacho, C., & Das, D., (2013b). A performance evaluation framework of construction

projects: insights from literature. International Journal of Project Organisation

and Management, Vol. X, No. Y, xxxx (Accepted for publication).

Ngacho, C., & Das, D., (2012). Development of a Performance Measurement

Framework for Evaluating Constituency Development Fund (CDF) Projects in

Kenya using Confirmatory Factor Analysis. XVI Annual International

Conference of the Society of Operations Management (SOM) on Advances in

Operations and Supply chain Management, Indian Institute of Technology, Delhi,

India, December 21-23, 2012.

Ngacho, C., & Das, D., (2011). Development of a Theoretical Framework for

Performance Evaluation of Construction Projects in Developing countries. XV

Annual International Conference of the Society of Operations Management

(SOM) on Sustainable Operations Management, Indian Institute of Management

Calcutta, India, December 16-18, 2011.

Ngacho, C., Das, D., & Makori, J., (2012). Evaluation framework for construction

projects performance in Developing countries-Development from Literature

Review. African International Business and Management (AIBUMA 2012)

Conference, University of Nairobi, School of Business, July 12-13, 2012.

Ngowi, A. B., (2000). Impact of culture on the application of TQM in the construction

industry in Botswana, International Journal of Quality &Reliability Management,

17, 442-452(11).

Nidumolu, (1996). Standardization, requirements, uncertainty and software project

performance, Information & Management, Vol.31, no. 3, pp. 135-150.

Nurul, I. A. & Poh K. N. (2011). The Role of Time, Cost and Quality in Project

Management. Industrial Engineering and Engineering Management (IEEM),

IEEE International Conference on Date of Conference: 6-9 Dec. 2011.

185

Odeh, A.M., & Battaineh, H.T.,(2002). Causes of construction delay: traditional

contracts. International Journal of Project Management, 20, 67-73.

Ofori, G., (2000). Challenges for construction industries in developing countries.

Proceedings, Second International Conference of the CIB Task Group

29,Gaborone, Botswana, November, pp. 1-11.

Ogano, N. O., & Pretorius, L., (2010). Quality performance: the case of construction

projects in the electricity industry in Kenya. South African Journal of Industrial

Engineering May 2010.

Okpala D.C., & Aniekwu, A.N., (1988). Causes of high costs of constructionin

Nigeria. Journal of Construction Engineering and Management, 114 (2), 233-

244.

Olawale, Y., & Sun, M., (2010). Cost and time control of construction projects:

Inhibiting factors and mitigating measures in practice. Construction Management

and Economics, 28 (5), 509 – 526.

Omoregie, A., & Radford, D., (2006). Infrastructure delays and cost escalation:

causes and effects in Nigeria. 3rd International Built a. Human Environment

Research Week, (), 03 Apr 2006 - 07 Apr 2006.

http://www.irbnet.de/daten/icconda/CIB8964.pdf accessed 01/05/2013.

Ortega, I., (2000). Systematic prevention of construction failure. Quality Management

and Technology 2000, 9:1-13.

Ortiz, O., Castells, F. & Sonnemann, G., (2009). Sustainability in the construction

industry: a review of recent developments based on LCA. Construction and

Building Materials, 23(1), 28-39.

Othman A. A, Torrance, J. V. & Hamid A., (2006). Factors influencing the

construction time of civil engineering projects in Malaysia. Engineering,

construction and Architectural management Vol. 13 No. 5 2006 pp 481-501. pp.

171-181.

Ozorrhon, B., Arditi, D., Dikmen I., & Birgonul M. T., (2007). Effect of host country

and project conditions in international construction joint ventures. International

Journal of Project Management, 25 (2007), 799-806.

186

Palaneeswaran, E Ramanathan, M. & Tam, C., (2007). Rework in Projects: Learning

from Errors, Surveying and Built Environment Vol 18 (2), 47-58 December 2007

ISSN 1816-9554.

Patanakul, P & Milosevic, D., (2009). The Effectiveness in Managing a group of

Multiple Projects: Factors of influence and Measurement Criteria. International

Journal of Project Management. 2009, 27, 216-233.

Patrick X. W. Z., (2011). Fostering a Strong Construction Safety Culture Leadership.

Journal of Management Engineering volume 11.

Pheng, L. S.; Chuan, Q. T. (2006). Environmental factors and work performance of

project managers in the construction industry. International Journal of Project

Management 24: 24–37. doi:10.1016/j.ijproman.2005.06.001.

PMI, (2008). Guide to Project Management Body of Knowledge. Project

Management Institute, New Square, PA, USA.

Poli, M. Cosic I. & Lalic B., (2010). Project Strategy: Matching Project Structure to

Project Type to Achieve Better Success. International Journal of Industrial

Engineering and Management 1(1), pp. 29-40.

Puspasari, T.R., (2006). Factors causing the poor performance of construction

project. Masters thesis, Universiti Technologi Malaysia, Faculty of Civil

Engineering.

Ratnasabapathy, S., (2008). Exploratory Study of External Environmental Factors:

Influencing the Procurement Selection in Construction. Viewed April 27, 2011,

<http://www.bear2008.org/post/49.pdf >.

Romero, G., (2009). Decentralization, Accountability and the MPs Election. The case

of the Constituency Development Fund in Kenya. A paper publishe in Publication

for improving Institutions for the Pre-Poor growth, University of Oxford.

Accessed 23/08/2012. Available www.iig.ox.ac.uk.

Salleh, R., (2009). Critical success factors of project management for Brunei

construction projects. Improving project performance. Unpublished PhD thesis,

Faculty of Built Environment and Engineering, Queensland University of

Technology.

187

Saparauskas, J. & Turskis, Z., (2006), Evaluation of construction sustainability by

multiple criteria methods, Technological and Economic development of Economy,

12: 4, 321-326.

Saqib, M., Farooqui, R.U., and Lodi, S.H. (2008).Assessment of Critical Success

Factors for Construction Projects in Pakistan. First International Conference on

Construction In Developing Countries (ICCIDC–I) “Advancing and Integrating

Construction Education, Research & Practice” August 4-5, 2008, Karachi,,

Pakistan

Segersted, A & Olofsson, T., (2010). Supply chains in the construction industry,

Supply Chain Management: An International Journal, 15 (5), 347-353.

Shao, J. & Müller, R., (2011). The development of constructs of program context and

program success: A qualitative study. International Journal of Project

Management, Dec 2011, Volume: 29 Issue: 8 pp.947-959.

Shen, L., Tam, V., Tam, L., & Ji, Y., (2010). Project feasibility study: the key to

successful implementation of sustainable and socially responsible construction

management practice. Journal of Cleaner Production, 18 (3), 254-259.

Shenhar, A. J., Asher, T., Dov, D., Stanislav, L., & Thomas, L., (2002). Refining the

search for project success factors: A multivariate typological approach. R & D

Management, 32(2), 111–126.

Shenhar, A.J., (2001). One size does not fit all projects: Exploring classical

contingency domains. Management Science, 47 (3), 394-414.

Shenhar, A.J., Levy, O., & Dvir, D., (1997). Mapping the Dimensions of Project

Success, Project Management Journal 28, no. 2 (1997): 5-13.

Skene, M. and Shaban, R., (2002). Strategies to Avoid and Resolve Construction

Disputes. Prepared for a conference held in Vancouver, B.C. hosted by Pacific

Business & Law Institute, March 6, 2002.

Sweis, G., Sweis, R., Abu Hammad, A., & Shboul, A., (2007). Delays in construction

projects: The case of Jordan. International Journal of Project Management, 26,

665–674.

Syed, M.A. Salman,A. Pragnya, K., & Dharam G., (2003). Delays in Construction: A

Brief Study of the Florida Construction Industry. Florida International University

Miami, FL, 2003.

188

Tabish, S.Z.S., & Jha, K.N., (2011). Analysis of irregularities in public procurement

in India. Journal of Construction Management and Economics. 29(3): 261-274.

Tae- Hong, C., Sangyoon, C., Su-Won, Y., & Soon-Wook, K. (2011). A service-

oriented integrated information framework for RFID/WSN-based intelligent

construction supply chain management. Automation in Construction Volume 20,

Issue 6, October 2011, Pages 706–715.

Takim, R., Akintoye A. & Kelly J., (2004). Analysis of measures of construction

project success in Malaysia. Association of Researches in Construction

Management, Vol.2, No.9, pp. 1123-113.

Takim, R & Akintoye, A., (2002). Performance indicators for successful construction

project performance. In: Greenwood, D (Ed.), 18th Annual ARCOM Conference,

2-4 September 2002, University of Northumbria. Association of Researchers in

Construction Management, Vol. 2, 545-55.

Tan, Y Shen,L.,& Yao, H., (2011). Sustainable construction practice and contractors’

competitiveness. A preliminary study, Habitat international 35 (2011) 225-230.

Toor, S.R. &, Ogunlana S.O., (2010). Beyond the iron triangle, Stakeholder

perception of Key performance indicators (KPIs) for large-scale public sector

development projects. International journal of project management 28 (2010)

228-236.

Tsoulfas, G.T. & Pappis, C.P., 2008. A model for supply chains environmental

performance analysis and decision making, Journal of cleaner production 16

(2008) 1647-1657.

Tyson Building Corporation, (2005). Selecting Project Delivery

www.tysonbuilding.com /images/SelectingProjectDelivery.pdf. Accessed

10/03/2012.

Walker, D.H.T., (1995). An investigation into construction time performance.

Construction Management and Economics, Vol. 13 No. 3, pp. 263-74.

Wang, X. & Huang, J., (2006). The relationships between key stakeholders' project

performance and project success: Perceptions of Chinese construction supervising

engineers. International Journal of Project Management, Vol. 24, PP. 253-260.

189

Wang, Y., Wang, H. & Shee, D.Y., (2007). Measuring e-learning systems success in

an organisational context: Scale development and validation. Computers in

Human Behaviour 23 (2007) 1792-1808.

Wanjiru G., (2008). The CDF Social Audit Guide, a Handbook for Communities,

Open Society Initiative of East Africa, February 2008. http://www.soros.org/

initiatives/ osiea/articles_publications/ publications/cdf_20080201/resource_

20080808.pdf accessed 23/10/20.

Wells, J., (1986). Construction Industry in Developing Countries: Alternative

Strategies for Development. London: Croom Helm.

Westerveld, E. (2002). The project Excellence Model®

: linking success criteria and

critical success factors. International Journal of Project Management, 6: 411-

418.

Willard, B.K., (2005). Project success-a different view. Accessed May 23, 2012 from

http:// maxwideman.com/guests/ metrics/view.htm.

Williams, T., (2003). Assessing Extension of Time delays on major projects Original

Research Article, International Journal of Project Management, Volume 21,

Issue 1, January 2003, Pages 19-26.

Willis, C.J. & Rankin, J.H., (2011). Measuring the Performance of Guyana’s

Construction Industry Using a Set of Project Performance Benchmarking Metrics

Journal of Construction in Developing Countries, Vol. 16(1), 19–40, 2011

Xiao, H. & Proverbs, D. (2003) Factors influencing contractor performance: an

international investigation, Engineering Construction and Architectural

Management, 10 (5), 322-332.

Xue, X., Wang, Y., Shen, Q., & Yu, X., (2007). Coordination mechanisms for

construction supply chain management in the Internet environment. International

Journal of Project Management 25 (2007) 150–157.

Yakubu, D.M., & Bakri I.M. (2013). Evaluation of Safety and Health Performance on

Construction Sites (Kuala Lumpur). Journal of Management and Sustainability;

Vol. 3, No. 2; 2013.

Yu J.H., & Kwon H.R., (2011). Critical Success Factors for Urban Regeneration

Projects in Korea. International Journal of Project Management. 29: 889‐899.

190

Yu, A. T. W., Shen, Q., Kelly, J., & Hunter, K., (2006). Investigation of critical

success factors in Construction project briefing by way of content analysis.

Journal of Construction Engineering and Management, ASCE, 132(11), 1178-

1186.

Yung, P. & Yip, B., (2010). Construction quality in China during transition: A review

of literature and empirical examination. International Journal of Project

Management, 28 (1), 79-91.

Zhao, Z, Zuo, J, Zillante, G, & Wang, X., (2010). Critical success factors for BOT

electric power projects in China: Thermal power versus wind power. Renewable

Energy 35 (2010) 1283–1291.

Zhu, O.J., Sarkis, L., & Lai, K., (2008). Confirmation of a Measurement Model for

Green Supply Chain Management Practices & Implementation. International

Journal of Production Economics, (111), pp. 261-273.

Zuo, P.X.W., Zhang, G & Wang, J., (2007). Understanding the key risks in

construction projects in China. International Journal of Project Management. 25

(6), 601-614.

191

APPENDICES

Appendix A1: Questionnaire for Exploratory Study (Phase I)

SECTION A: PROJECT AND RESPONDENT INFORMATION

1. Contract at: .......................................Constituency......................................................

2. Type of project: Educational Health Care Industrial Estates

Agricultural Market

3. Your position on the project: Client Consultant Contractor

4. Please indicate how long you have been involved in the construction of CDF

projects?

Below 3 years 3 – 6 years over 6 years

5. Which of these indicate the average quantity of building construction projects you

handle/year in the constituency

Up to 3 projects 4–6 projects 7 – 9 projects 10 projects and above

6. Please indicate the overall value of CDF construction projects that you have

worked on in the last 3 years? Over Ksh. 15 Millions (£175,000) Ksh. 10

Million to Ksh.15 Millions (£115,000-£175,000) Up to Ksh. 10 Million

s (£115,000)

7. Please indicate the procurement approach employed for this project (please tick)

Design/Bid/Build Design/Build Competitive bid

Negotiated general contract Build–Own–Operate–Transfer

Turnkey contract

8. Project dates and cost estimate.

Contract start on site: Original contract sum

Original completion date: Approved variations:

5

1

6

4

32

1 2 3

4

1 2 3

321

431

32

1

2

192

Actual completion date: Final project cost

SECTION B KEY PERFORMANCE INDICATORS

Based on your experience associated with the current as well as other construction

projects undertaken in the past, you are kindly requested to indicate your level of

agreement with each of the following performance measurement variables on 1 to 5

point Likert scale (1=strongly disagree, 2=Disagree, 3=Indifferent, 4=Agree and

5=strongly Agree).

PERFORMANCE VARIABLES (PV) LEVEL OF

AGREEMENT

There has not been any increase in the cost of raw materials during

construction of this project.

Labour costs more or less remained stable over the period of

construction of the current project.

The project experienced minimum variations and hence hardly any

additional cost attributable to variations was incurred.

The required equipments were available at pre budgeted rates.

The amount/quantity of different type of resources required during

the implementation phase matched with those estimated during

planning stage.

There were no incidences of fraudulent practices and kickbacks

during project execution.

There were no incidences of agitation by the trade unions in the

current project.

There were no serious dispute between the client and contractor due

to non adherence to the specifications.

Disputes were observed due to the frequent changes in the design of

the current project.

Dispute resolution meetings were often held during project

execution.

At time of project completion, there were no financial claims that

remained unsettled from this project.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

193

This construction project has adversely affected the quality of

groundwater level.

All required resources for the project were delivered on time during

execution of this project.

A clear plan was formulated and an efficient planning and control

system was designed to keep the current project up-to-date.

No changes were introduced in the designs of the current during

project execution.

Harmonious relationship between labour and management existed

in the project site and hence no work disruptions were reported

during project execution.

This project has led to air pollution in the adjoining areas.

This project has led to depletion of the precious natural and mineral

resources in the surrounding areas.

There has been an increase in solid waste due to the construction of

the current project.

Accidents were often reported during project construction.

Near misses occurred quite often during construction.

Fatalities did occur on this project during construction.

The construction work utilised environmentally friendly

technology.

This project has led to the increased release of toxic material.

No delays were experienced in securing funds during project

implementation.

At the time of handover, the current project was free from apparent

defects

The project contractors were often called back during the Defects

Liability Period to repair defects.

Weather and climatic conditions did not have much impact on

delaying the project.

The current project has utilised reusable and recyclable materials in

construction work.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

194

The right material was used for the construction work.

Employees working in the current project possessed requisite skills

and most of them had worked on similar kinds of projects in the

past.

A sound quality management system was strictly adhered to during

project execution phase of the current project.

Training was imparted to the workers in order to develop a positive

attitude and also to enable them to apply the right method of work.

All stakeholders associated with the current project supervised the

quality of the project in all its phases.

Proper medical facilities were available for people working on the

project.

SECTION C. FACTORS AFFECTING SUCCESS OF CDF FUNDED

CONSTRUCTION PROJECTS.

This section seeks to determine the factors that affect the performance of construction

projects. On basis of the project you were involved with, you are kindly requested to

indicate your level of agreement with each of the following project success variables on 1 to

5 point Likert scale (1=strongly disagree, 2=Disagree, 3=Indifferent, 4=Agree and 5=strongly

Agree).

SUCCESS VARIABLES (SV) AGREEMENT

The location and Site conditions did not affect the construction of this

project.

Design Complexity of project (Type, size, nature and number of

floors) has influenced the project cost and time.

Project planning, Scheduling and control were adequately done on

this project.

The client secured necessary funds for the project and hence there

were no delays in material acquisition and payments to contractor.

The client got the design documents approved on time for this

project.

The client had adequate experience on similar kind of projects.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

195

Information sharing and collaboration among project participants

were adequate in the current project.

The construction work adhered to the requisite Quality standards.

Continuous monitoring of actual expenditures and project schedules

and their comparison with the budget was done regularly.

There was a formal organization structure for dispute resolution

within the project organization.

Site Managers possessed requisite skills necessary for the kind of

projects executed.

The contractor had adequate technical skills and experience on

similar type of projects.

The contractor used latest construction methods in the current project.

The community did not raise any social, political or cultural issues

against construction of the current project.

The project execution was adversely affected by the surrounding

weather and climatic conditions.

Macro- economic conditions (such as interest rates, inflation) did not

significantly affect the execution of this project.

The project was affected by the Governance policy of the relevant

government agencies which has a bearing on the project performance.

The consultant was highly committed to ensuring construction work

according to design specifications.

There were adequate designs, specifications and documentations for

the use of contractor.

The client emphasized on completing the current project very fast

without any reference to quality.

The client tended to purchase construction materials at cheaper rate

which led to the dilution of other project objectives.

No variations in original design took place in the current project

during construction phase.

The level of technological sophistication considered in the project

was satisfactory.

There were no incidences of disagreements resulting from industrial

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

196

relations prevailing at the time of project implementation.

The physical and ecological conditions surrounding the project were

favourable to project execution.

There were very few internal procurement challenges

The client’s decisions were timely and objective.

Right equipments were available in the construction site of this

project.

The project faced stringent insurance and warranty contractual

requirements.

Working capital was adequate.

54321

54321

54321

54321

54321

54321

197

Appendix A2: Questionnaire for Confirmatory Study (Phase II)

Section A: Project and Respondent information

1. Contract at: .......................................Constituency......................................................

2. Type of project: Educational Health Care

Industrial estate Agricultural Market

3. Your position on the project: Client Consultant Contractor

4. Please indicate how long you have been involved in the construction of CDF

projects?

Below 3 years 3 – 6 years over 6 years

5. Which of these indicate the average quantity of building construction projects you

handle/year in the constituency

Up to 3 projects 4–6 projects 7 – 9 projects 10 project and above

6. Please indicate the overall value of CDF construction projects that you have

worked on in the last 3 years? Over Ksh. 15 Millions (£175,000) Ksh. 10

Million to Ksh.15 Millions (£115,000-£175,000) Up to Ksh. 10 Million s

(£115,000)

7. Please indicate the procurement approach employed for this project (please tick)

Design/Bid/Build Design/Build Competitive bid Negotiated general

contract Build–Own–Operate–Transfer Turnkey contract.

8. Project dates and cost estimate.

Contract start on site: Original contract sum

Original completion date: Approved variations:

Actual completion date: Final project cost

5

1

6 4

32

1 2

3 4

1 2 3

321

431

32

1

2

198

Section B Performance measurement variables amongst CDF Construction

Projects

Based on your experience associated with the current as well as other construction

projects undertaken in the past, you are kindly requested to indicate your level of

agreement with each of the following performance measurement variables on 1 to 5

point Likert scale (1=strongly disagree, 2=Disagree, 3=Indifferent, 4=Agree and

5=strongly Agree).

PERFORMANCE VARIABLES (PV) LEVEL OF AGREEMENT

Time Performance Factor (7)

TPV1: Timely delivery of resources

TPV2: Harmonious relationship on site.

TPV3: A clear plan was formulated.

TPV4: No delays in securing funds.

TPV5: No effect of weather and climatic conditions.

TPV6: No design changes.

TPV7: At handover there were no apparent defects

Cost Performance Factor (6)

CPV1: Equipments at pre budgeted rates.

CPV2: Stable labour costs

CPV3: No increase materials cost

CPV4: Minimum variations cost were incurred

CPV5: Adverse effect on quality of groundwater level.

CPV6: No financial claims at completion.

Site Dispute Performance Factor (4)

DPV1: No serious dispute due to specifications.

DPV2: Disputes due to the frequent changes

DPV3: No incidences of trade union agitation

DPV4: Dispute resolution meetings

Environmental Impact Performance Factor(4)

EPV1: Project has led to air pollution.

EPV2: Increased solid waste.

EPV3: Utilised environmentally friendly technology.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

199

EPV4: Project has led to depletion natural resources.

Quality Performance Factor (3)

QPV1: Right material was used for the construction work.

QPV2: A sound QMS adhered to.

QPV3: Workers were trained on positive attitudes

Safety Performance Factor (3)

SPV1: Accidents were reported.

SPV2: Fatalities did occur.

SPV3: Near misses occurred.

SECTION C. FACTORS AFFECTING SUCCESS OF CDF FUNDED

CONSTRUCTION PROJECTS.

This section seeks to determine the factors that influence the success of CDF

construction projects. These factors have been categorised under six heads; Project

related, client related, consultant related, contractor related, supply chain related and

External environment related factors. On basis of the project you were involved in,

you are kindly requested to indicate your level of agreement with each of the following

project success variables on 1 to 5 point Likert scale (1=strongly disagree, 2=Disagree,

3=Indifferent, 4=Agree and 5=strongly Agree).

PROJECT SUCCESS VARIABLES (SV) LEVEL OF AGREEMENT

Project Related Factor (7)

PSV1: Influence of Design Complexity.

PSV2: Adhered to the requisite Quality standards.

PSV3: Continuous monitoring of actual expenditures.

PSV4: Formal dispute resolution structures.

PSV5: Effect of location and Site conditions.

PSV6: Adequate Information sharing and collaboration.

PSV7: Adequate Project planning and, Scheduling.

Client related factor(5)

CSV1: Adequate experience on similar projects.

CSV2: Cheap materials were used.

CSV3: Project funds secured on time.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

200

CSV4: Client’s emphasis on time rather than quality.

CSV5: Design documents approved on time.

External environment related factor (6)

ESV1: Community had no issues against the project.

ESV2: Adversely affected by the surrounding weather.

ESV3: Effect of the Governance policy.

ESV4: Favourable physical and ecological conditions.

ESV5: Effect of Macro- economic conditions.

ESV6: No incidences industrial unrests.

Supply chain related factor (3)

LSV1:Few internal procurement challenges

LSV2: Right equipments were available.

LSV3: Effect of stringent insurance/warranty rules.

Consultant related factor (3)

SSV1: No variations were incorporated.

SSV2: Adequate designs/specifications/documentations.

SSV3: Adequate consultant committed to project.

Contractor related factor (3)

RSV1: Site Managers possessed requisite skills.

RSV2: Contractor had adequate technical skills.

RSV3: Contractor used latest construction methods.

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321

54321