allotment letter ref.no.: . date: . mr/mrs./ms . sub...

25
'. ALLOTMENT LETTER Ref. No.: . Date: . Mr/ Mrs./ Ms . Sub: Allotment of Flat No- , in "Pinnacle" Iaipur. Dear Sir/Madam, We refer to your application dated , for allotment of a residential Flat in our project "Pinnacle" situated at Khasra No. 35(Part), Village Bhojpura, Sahakar Marg Scheme, Lal Kothi, [aipur, It gives us immense pleasure to inform you that you have been allotted Flat No. ......... , having carpet area of sq. ft.: built up area of sq. ft. and super built-up area of sq. ft. type on floor in tower no . In pursuance of the terms & conditions as laid down in the Application Form the Total Price of the Flat and other charges (if any) shall be payable as per the payment plan agreed between us. The terms and conditions of the Agreement for sale, to be executed between you and the promoter, shall be final and binding between both the parties. All the taxes, dues, levies, demands or charges including but not limited to Service Tax, CST, if any, shall be borne by the purchaser/ allottee. We value our relationship and welcome you amongst our family. Thanking you and assuring you the best of services at all times. Yours faithfully, For Ratnawat Infrastructure Construction Company LLP ~ (Authorized Signatory)

Upload: others

Post on 22-Aug-2020

4 views

Category:

Documents


0 download

TRANSCRIPT

Page 1: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

'.ALLOTMENT LETTER

Ref. No.: . Date: .

Mr / Mrs. / Ms .

Sub: Allotment of Flat No- , in "Pinnacle" Iaipur.

Dear Sir/Madam,

We refer to your application dated , for allotment of a residential Flat in ourproject "Pinnacle" situated at Khasra No. 35(Part), Village Bhojpura, Sahakar MargScheme, Lal Kothi, [aipur,

It gives us immense pleasure to inform you that you have been allotted Flat No .......... , having carpet area of sq. ft.: built up area of sq. ft. and superbuilt-up area of sq. ft. type on floor in tower no .

In pursuance of the terms & conditions as laid down in the Application Form theTotal Price of the Flat and other charges (if any) shall be payable as per the paymentplan agreed between us. The terms and conditions of the Agreement for sale, to beexecuted between you and the promoter, shall be final and binding between both theparties.

All the taxes, dues, levies, demands or charges including but not limited to ServiceTax, CST, if any, shall be borne by the purchaser/ allottee.

We value our relationship and welcome you amongst our family.

Thanking you and assuring you the best of services at all times.

Yours faithfully,For Ratnawat Infrastructure Construction Company LLP

~

(Authorized Signatory)

Page 2: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

FORM·G[see rule 9]

Agreement for Sale

AffixphotographAllottee/Allottee

Colorof

Firstwiththesignature across

photograph

Affix Colorphotograph of theau thorized signatoryof Promoter withsignature across thephotograph

This Agreement for Sale, hereinafter referred to as the Agreement, is executed on this day of

............. Two thousand _ and at Jaipur.

By and Between

RATNAWAT INFRASTRUCTURE CONSTRUCTION COMPANY LLP (formerly known as Ratnawat

Infrastructure Construction Company Private Limited), a limited liability partnership

incorporated under the Limited Liability Partnership Act, 2008, having its identification no. MD-

6363 and Registered office at 48 1st Floor, Manokamna Golimar Garden, Sahakar Marg, Jaipur -

302015 (Rajasthan) and its PAN is , represented by its authorized

signatory (Aadhar No ) authorized vide

board resolution dated hereinafter referred to as the "Promoter" (which expression

shall, unless it be repugnant to the context or meaning thereof be deemed to mean and include, its

assignees, legal successor(s) in interest) of the ONE PART.

AND

Mr/Ms./Mrs son/daughter/wife of .

........................... aged about years, Rio .

........... (Aadhar No ) (PAN )

(hereinafter singly Ijointly, as the case may be, referred to as the "Allottee(s)", which expression shall,

unless repugnant to the context or meaning thereof be deemed to mean and include their legal

successor(s), administrators, executors successors & permitted assignees) of the OTHER PART.

The Promoter and the Allottee(s) shall hereinafter be collectively referred to as "Parties" andindividually as a "Party".

INTERPRETATIONS/ DEFINITIONS:

(1) In this Agreement, the following expressions unless repugnant to the context shall have themeaning assigned thereto -

(a) "Act"means the Real Estate (Regulation and Development) Act, 2016;

(b) "Built-up area" means the sum of area of the Apartment or Flat. It shall include areaencompassed within the walls of Apartment or Flat, all balconies, whether covered or un­covered, and thickness of wall. In case there be a common wall only 50% of thickness of suchwall shall be taken in consideration for calculating t.he built-up area;

(c) "Carpet area" means the net usable floor area of an apartment excluding the area covered bythe external walls, areas under services shafts, exclusive balcony or verandah area andexclusive open terrace area, but includes the area covered by the internal partition walls ofthe apartment.

1Signature of Promoter Signature of Allottee

Page 3: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share
Page 4: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share
Page 5: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

Flyash Bricks: Fly ash Bricks consist of fly ash, cement/lime, sand, water asper Indian Standard IS 12894:2002 and tested as per IS 3495(Part 1-4).

AACBlocks 1st grade Autoclaved Aerated Concrete blocks of Standard size &properties (non toxic, fire resistance, environmental friendly,lightweight, thermal insulation etc.) confirming to IS 2185 : 1979(Part 3)

O. The stage wise time-schedule of completion of the Projects Phase thereof including theprovisions of civic infrastructure like water, electricity, sanitation and all other above-mentionedinternal/external development works is as under:-

Date by which the

Stage works are proposed to Details of works tobe complete be completed

1 14-Aug-2017 Basements (Structure Work)2 07-Jan-2019 Super Structure3 12-Feb-2019 Block masonry4 26-Dec-2019 Electrical & Plumbing Work (Inc. CP and Sanitary Fitting)5 03-Jul-20 19 Internal Plaster6 31-0ct-2019 Outer Plaster7 13-Jan-2020 Flooring8 20-Nov-2019 Fixing of Door and Windows9 23-Dec-2019 Internal Paint10 I1-Jan-2020 External Paint11 15-Feb-2020 Outer Development

P. The Airport Authority of India has also granted NOC for height clearance for the Project vide itsletter bearing no. AAI/RHQ/NR/ATM/NOC/2015/333/ 3821-24 dated 01/12/2015

Q. Environmental Clearance from the department concerned Environment Impact AssessmentAuthority has been obtained for the Project vide its letter bearing no. FI(4)/SEIAA/SEAC­Raj/Bectt/Project./Cat.Btajls l (15181) /16-17 Jaipur dated 13.02.2017

R. The Fire NOC has also been issued by Chief Fire Officer Nagar Nigam, Jaipur vide its letterbearing no. ~.9(31/16-17 ).:ml{)f/'lf.iVl/17/521 dated 2l.06.2017.

S. The Promoter has opened a separate account in Branch of ICICI Bank Ltd, Sahakar Marg,Jaipur for the purpose as provided in sub-clause (D)of clause (1) of sub-section (2) of section 4of the Act.

T. Consent to Establish under section 25/26 of the Water (Prevention & Control of Pollution) Act,1974 has been obtained for the Project vide its letter bearing no. F(MUID)/JAIPUR(Sanganer)/125(1)/2017~2018/2396-2398 dated 22.06.2017.

U. Approval letter for Sewerage connection has been obtained for the project vide its letter bearingno. ~-29( )/\fI1{ fu~l \iJT;1/2017/191 dated 12.06.2017.

V. The Allottee(s), being aware of the Project and details given in the advertisements about theProject made by the Promoter and/or on visiting the model of the Apartment/ Building, hasapplied for allotment and to purchase Apartment /Building (hereinafter referred to as the 'Unit')in the Project vide his/her/their/its application dated The allottee(s) has alsodeposited a sum of Rs l- (Rupees ......................... Only) as an advance payment/ booking amount including application fee (notbeing more than 10% of the cost of the apartment as provided in sub-section (1) of section 13)and agrees to make timely and complete payments of the remaining sale price as well as otherdues under this Agreement as per terms and conditions of this Agreement.

W. The Allottee has applied for an apartment/flat in the Project vide application no dated................... and has been allotted apartment/Flat no having carpet area of............... square feet, type: on floor in tower no. . .("Building") along with garage/covered parking no admeasuring square feet

4Signature of Promoter

Page 6: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

in the , as permissible under the applicable law and of pro rata share inthe common areas as defied under clause (n) of section 2 of the Act (hereinafter referred to asthe "Apartment" more particularly described in Schedule-4 and the floor plan of the apartmentis annexed hereto and marked as Schedule-3.

Note: Garage includes covered car parking/basement car parking/stilt car parking.

X. The Parties have gone through all the terms & conditions set out in this Agreement andunderstood the mutual rights and obligations detailed herein. The Parties hereby confirm thatthey are signing this Agreement with full knowledge of the all laws, rules, regulations,notifications etc. applicable to the Project.

Y. The Parties, relying on the confirmations, representations and assurances of each other tofaithfully abide by all the terms, conditions and stipulations contained in this Agreement and allapplicable laws, are now willing to enter into this Agreement on the terms and conditionsappearing hereinafter;

z. In accordance with the terms and conditions set out in this Agreement and as mutually agreedupon by and between the Parties, the Promoter hereby agrees to sell and the Allottee herebyagrees to purchase the [Apartment] and the garage/covered parking as specified in para V.

AA. The details of common area are as under:-

A. The entire land except exclusions mentioned elsewhere in the agreement.B. The stair cases, lifts, staircase and lift lobbies, fire escapes, and common entrances and

exits of buildings;C. The common basements, parks, play areas, open parking areas;D. Installations of central services such as electricity, gas, water and sanitation, air­

conditioning, system for water conservation and renewable energy;E. The water tanks, sumps, motors, fans, compressors, ducts and all apparatus connected with

installations for common use;F. All other portion of the project necessary or convenient for its maintenance, safety, etc., and

in common use;

BB.The details of limited common areas and facilities are as under:-

Storage spaces having an aggregate area of 282.04 sq. mts. (Approximately) and services havingan aggregate area of 911.16 sq. mts. (Approximately).

NOW THIS AGREEMENT WITNESSETH AND THE PARTIES HERETO MUTUALLY AGREE ONFOLLOWING TERMS AND CONDITIONS, NAMELY:-

1. TERMS:

1.1 Subject to the terms & conditions as detailed in this Agreement, the Promoter herebyagrees to sell to the Allottee(s) and the Allottee(s) hereby agrees to purchase and receivethe Apartment as specified in para 'W'

1.2 The Total Price for the Apartment based on the carpet area is Rs l-(Rupees only) ("Total Price")The applicable taxes viz VAT,Work Contract Taxes, GST etc. as the case may be shallbe paid by the allottee separately as per prevailing rates.

r---------.-- ....- .-... --..--------.- --------_-

te of Apartment Rate of Apartmentper square feet per square feet(built-up area) (super built-up area)

_.

---_---

Rate of Apartment Raper square feet(carpet area)

Block Building Towerno .

Apartment no ....

---_ ...._-------------_-----_-- ..-

f----------.---- .-.---------+otal Price (in Rupees)

(Exclusive of applicabletaxes viz VAT,WorkContract Taxes, GS1._~~<::

5Signature of Promoter Signature of Allottee

Page 7: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

And (if/as applicable) subject to the provisions of building by-laws

f------------------------ --arage/ covered parking-2

Price for 1 (in Rs.)---- ----,---,_

Price for 2(in Rs.)

otal price (in Rupees)L- _

Explanation:

(i) The Total Price above includes the booking amounts ofRs .•.........................••...... l-(Rupee ............•••.•........•••......•...••.....................•••...........••••••......•••... Only) paidby the allottee to the Promoter towards the Apartment as mentioned in Para 'W'

(ii) The Total Price above includes Taxes (consisting of tax paid or payable by thePromoter by way of GST, Value Added Tax, Service Tax and Cess or any othersimilar taxes which may be levied, in connection with the construction of the Projectpayable by the Promoter, by whatever name called) upto the date of the handingover the possession of the Apartment to the allottee and the Project to theMaintenance Society or the competent authority, as the case may be, after obtainingthe completion certificate:

Provided that in case there is any change/ modification in the taxes, the subsequentamount payable by the Allottee(s) to the Promoter shall be increased/ reduced basedon such changed modification:

Provided further that if there is any increase in the taxes/ government levy/dutiesand lease money after the expiry of the schedule date of completion of the Project asper registration with the Authority, which shall include the extension of registration,if any, granted to the said Project by the Authority, as per the Act, the same shallnot be charged from the Allottee;

(iii) The Promoter shall periodically intimate to the Allottee.(s), the amount payable asstated in (i) above and the Allottee(s) shall make payment demanded by thePromoter within the time and in the manner specified therein. In addition, thePromoter shall provide to the Allottee(s) the details of the taxes paid or demandedalong with the Acts/rules/notifications together with dates from which suchtaxes/levies etc. have been imposed or become effective;

(iv) The Total Price' of Apartment/ includes price of land, construction of, not only theApartment but also, the common areas, internal development charges, externaldevelopment charges, taxes, cost of providing electric wiring, electrical connectivityto the Apartment, lift, water line and plumbing, finishing with paint, marbles, tiles,doors, windows, fire detection and firefighting equipment in the common areas, etc.and includes cost for providing all other facilities, amenities and specification to beprovided within the Apartment and the Project.

(v) It shall be the duty of the buyer to deduct and deposit TDS as per the applicablerates on the sale consideration paid either in installments or in full whatever thecase may be and shall produce a receipt of such deduction to the promoter.

1.3 The Total Price is escalation free, save and except increases which the Allottee(s) herebyagrees to pay, due to increase on account of development charges payable to thecompetent authority, increase in lease money charges and/or' any other increase incharges which may be levied or imposed by the competent authority, from time to time.The Promoter undertakes and agrees that while raising a demand on the Allottee(s) forincrease in development charges, cost/charges imposed by the competent authorities,the Promoter shall enclose the said notification/ order / rules/ regulations to that effectalong with the demand letter being issued to the Allottee(s), which shall only beapplicable on subsequent payments:

6Signature of AllotteeSignature of Promoter

Page 8: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

1.4 As mentioned in para 'V' above, the Promoter has already received an advance/ bookingamount from the Allottee(s) a sum of Rs /- (Rupees ................................................. Only) (not being more than 10% of the total cost ofthe Unit as provided in sub-section (1) of section 13) out of the total price ofRs and the Allottees(s) agrees and undertakes to pay the balance amount ofRs of the total price strictly in accordance with the payment plan givenbelow:-

---------------_.-Stage of Percentage of Installment Period within

development the Total Price Amount in which theworks & as calculated Rs. installrnen t

completion of under Term & amount is tothe Unit (with Condition No. be paid by the

details of l.2 Allotteeworks)

---_ ..- ---r--

- -----------------

r----------- --~-.'------------

------

Note: Payment plan will be as per the mutual discussion between the parties.

l.5 The Promoter may allow, in its sole discretion, a rebate for early payments ofinstallments payable by the Allottee(s) by discounting such early payments @ _ % perannum for the period by which the respective installment has been preponed. Theprovision for allowing rebate and such rate of rebate shall not be subject to anyrevision/withdrawal, once granted to an Allottee(s) by the Promoter.

1.6 It is agreed that the Promoter shall not make any addition and alteration in thesanctioned plans, layout plans and specifications and the nature of fixtures, fittingsand amenities described herein at Schedule-'S' and Schedule-'6' (which are inconformity with the advertisement, prospectus etc., on the basis of which sale iseffected) in respect of the Apartment without the previous written consent of theAllottee(s) as per the provisions of the Act:

Provided that the Promoter may make such minor additions or alterations as may berequired by the Allottee(s), or such minor changes or alterations as per the provisions ofthe Act.

1.7 The Promoter shall confirm to the final carpet areas that has been allotted to theAllottee after the construction of the building is completed and the occupancy certificatehas been granted by the competent authority, by furnishing details of the changes, ifany in the carpet area. The Total Price payable for the carpet area shall be recalculatedupon confirmation by the Promoter. If there is reduction in the carpet area than thePromoter shall refund the excess money paid by Allottee within 45 days with interestfrom the date when such an excess amount was paid by the Allottee. If there is anyincrease in the carpet area, which is not more than three percent of the carpet area ofthe Apartment, allotted to the Allottee, the Promoter may demand that from the Allotteeas per the next milestone of the Payment Plan as provided in this Agreement. All thesemonetary adjustments shall be made at the same rate per square feet as agreed in TermNo. 1.2 above.

.....

7Signature of Promoter Signature ofAllottee

Page 9: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

1.8 Subject to Term No. 9.3 the Promoter agreed and acknowledged, the Allottee shall havethe right to the Apartment as mentioned below:

(i) The Allottee(s) shall have exclusive ownership of the Apartment;

(ii) The Allottee(s) shall also have undivided proportionate ownership and share in thecommon areas. Since the share/ interest of Allottee(s) in the common areas isindivisible and cannot be divided or separated, the Allottee(s) shall use the commonareas, along with other occupants and maintenance staff etc., without causing anyinconvenience or hindrance to them. It is clarified that the Promoter shall handoverthe common areas to the Maintenance Society after duly obtaining the completioncertificate from the competent authority as provided in the Act;

(iii) That the computation of the price of the Apartment includes recovery of price ofland, construction of, not only the Apartment but also, the common areas, internaldevelopment charges, external development charges, taxes, cost of providing electricwiring, electrical connectivity to the Apartment, lift, water line and plumbing,finishing with paint, marbles, tiles, doors, windows, fire detection and firefightingequipment in the common areas, etc. and includes cost for providing all otherfacilities, amenities and specification to be provided within the Apartment and theProject;

(iv) The Allottee has the right to VISit the Project site to assess the extent ofdevelopment of the Project and his Apartment.

1.9 It is made clear by the Promoter and t.he Allottee agrees that the Apartment along with................. garage/covered parking shall be treated as a single indivisible unit for allpurposes. It is agreed that the Project is an independent, self-contained Project coveringthe said Land and is not a part of any other project or zone and shall not form a part ofand/or linked/ combined with any other project in its vicinity or otherwise except forthe purpose of integration of infrastructure for the benefit of the Allottee. It is clarifiedthat Project's facilities and amenities shall be available only for use and enjoyment oft.he Allottee(s) of the Project.

1.10 The Promoter agrees to pay all ou tgoings / dues before transferring the physicalpossession of the Apartment to the Allottee(s) which it has collected from the Allottee(s),for the payment of outgoings/dues (including land cost, ground rent, municipal or otherlocal taxes, charges for water or electricity, maintenance charges, including mortgageloan and interest on mortgages or other encumbrances and such other liabilitiespayable to competent authorities, banks and financial institutions, which are related tothe Project). If the Promoter fails to pay all or any of the outgoings/ dues collected by itfrom the Allottee(s) or any liability, mortgage loan and interest thereon beforetransferring the Apartment to the Allottee(s), the Promoter agrees to be liable, even afterthe transfer of the property, to pay such outgoings/ dues and penal charges, if any, tothe authority or person to whom they are payable and be liable for the cost of any legalproceedings which may be taken therefore by such authority or person.

1.11 The Allottee has paid a sum of Rs••.••••..•••••••••••••••.•••••••••••••••/- (Rupees ............................................... Only) as booking amount being part payment towardsthe Total Price of the Apartment at the time of application the receipt of which thePromoter hereby acknowledges and the Allottee hereby agrees to pay the remainingprice of the Apartment as prescribed in the payment plan at Term No. 1.4 above as maybe demanded by the Promoter within the time and manner specified therein.

Provided that if the Allottee(s) delays in payment towards any amount which is payable,he shall be liable to pay interest at the rate prescribed in the Rules. The obligations ofthe Allottee(s) to pay the amount and the liability towards interest as aforesaid may bereduced when mutually agreed to between the Promoter and the Allottee(s).

2. MODE OF PAYMENT:

Subject to the terms of the agreement and the Promoter abiding by the constructionmilestones, the Allottee shall make all payments, on written demand by the Promoter, withinthe stipulated time as mentioned in the payment plan at Term No. 1.4 above throughaccount payee cheque/ demand draft/ banker's cheque or online payment (as applicable) infavor of 'Pinnacle' payable at Jaipur.

3. COMPLIANCE OF LAWS RELATING TO REMITTANCES:

3.1

8Signature of Promoter

Page 10: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

the necessary formalities as laid down in Foreign Exchange Management Act,1999 ('FEMA'),Reserve Bank of India Act, 1934 ('RBI' Act) and the Rules and Regulation made thereunderor any statutory amendments or modifications made thereof and all others applicable lawsincluding that of remittance of payment, acquisition/ sale/ transfer of immovable propertiesin India etc. and provide the Promoter with such permission, approval which would enablethe Promoter to fulfill its obligations under this Agreement. Any refund, transfer of security,if provided in terms of the Agreement shall be made in accordance with the provisions ofFEMAor statutory enactments or amendments thereof and the Rules and Regulation of theReserve Bank of India or any other applicable law. The Allottee understands and agrees thatin the event of any failure on his/ her part to comply with the applicable guidelines issuedby the Reserve Bank of India, he/ she may be liable for any action under FEMAor other lawsas applicable, as amended from time to time.

3.2 The Promoter accepts no responsibility in regard to matters specified in Term 3.1 above. TheAllottee shall keep the Promoter fully indemnified and harmless in this regards. Wheneverthere is any change in the residential status of the Allottee subsequent to the signing of thisAgreement, it shall be the sole responsibility of the Allottee to intimate the same in writing tothe Promoters immediately and comply with necessary formalities if any, under theapplicable laws. The Promoter shall not be responsible towards any third party makingpayment/remittances on behalf of Allottee and such third party shall not have any right inthe application/allotment of the said Apartment applied herein in any way and the Promotershall be issuing the payment receipts in favor of the Allottee only. However allottee shall beentitled to get the name of his/her/their/its assignee(s) substituted in his/her/their/itsplace with the prior approval of the Promoter.

4. ADJUSTEMENT/ APPROPRIATION OF PAYMENTS:

The Allottee authorized the Promoter to adjust/ appropriate all payments made by him/ herunder any head of dues against lawful outstanding of the Allottee against the Apartment, ifany, in his/ her name and the Allottee undertakes not to object/ demand/ direct thePromoter to adjust his payments in any manner.

5. TIME IS ESSENCE:

The Promoter shall abide by the time schedule for completing the Project as disclosed at thetime of registration of the Project with the Authority and towards handing over theApartment to the Allottee and the common areas to the Maintenance Society or thecompetent authority, as the case may be.

The Allottee has seen the proposed layout plan, specifications, amenities and facilities of theApartment and accepted the floor plan, payment plan and the specification, amenities andfacilities annexed along with this Agreement which has been approved by the competentauthority, as represented by the Promoter. The Promoter shall develop the Project inaccordance with the said layout plans, floor plans and specifications, amenities andfacilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abideby such plans approved by the competent authorities and shall also strictly abide by thebye-laws, FAR, and density norms and provisions prescribed by the relevant building bye­laws and shall not have an option to make any variation/ alteration/ modification in suchplans, other than in the manner provided under the Act, and breach of this term by thePromoter shall constitute a material breach of this Agreement.

6. CONSTRUCTION OF THE PROJECT:

7. POSSESSION OF THE APARTMENT:

7.1 Schedule for possession of the said Apartment - The Promoter agrees and understandsthat timely delivery of possession of the Apartment to the Allottee and the common areas tothe Maintenance Society or the competent authority, as the case may be, is the essence ofthe Agreement. The Promoter assures to handover possession of the Apartment along withready and complete common areas with all specifications, amenities and facilities of theProject in place on , unless there is delay or failure due to war, flood,drought, fire, cyclone earthquake or any other calamity caused by nature effecting theregular development of the real estate project ("Force Majeure"]. If however, the completion ofProject is delayed due to the Force Majeure conditions then the Allottee agrees that thePromoter shall be entitled to the extension of time for delivery of possession of theApartment, provided that such Force Majeure conditions are not of a nature which make itimpossible for the contract to be implemented. The Allottee(s) agrees and confirms that, inthe event it becomes impossible for the Promoter to implement the project due to ForceMajeure conditions, then this allotment shall stand terminated and the Promoter shallrefund to the Allottee(s) the entire amount received by the Promoter from the Allottee with

-9

Signature of Promoter Signature of Allottee

Page 11: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

interest within forty-five days from that date. The Promoter shall intimate the Allottee aboutsuch termination at least thirty days prior to such termination. After refund of the moneypaid by the Allottee, the Allottee agreed that he/ she shall not have any rights, claims etc.against the Promoter and t.he Promoter shall be released and discharged from all itsobligations and liabilities under this Agreement.

7.2 Procedure for taking possession- The Promoter, upon obtaining the occupancy certificatefrom the competent authority shall offer in writing the possession of the Apartment, to theAllottee(s) in terms of this Agreement to be taken within 2 (two) months from the date of issueof occupancy certificate. Provided that, in the absence of local law, the conveyance deed infavor of the Allottee shall be carried out by the Promoter within three months from the date ofissue of occupancy certificate. The Promoter agrees and undertakes to indemnify theAllottee(s) in case of failure of fulfillment of any of t.he provisions, formalities, documentationon part of the Promoter. The Allottee(s), after taking possession, agree(s) to pay themaintenance charges as determined by the Promoter/ Maintenance/Society/RWA, as the casemay be, after the issuance of completion certificate for the Project. The Promoter shallhandover the occupancy certificate of the Apartment, as the case may be, to the Allottee at thetime of conveyance of the same.

7.3 Failure of Allottee to take possession of Apartment-Upon receiving a written intimationfrom the Promoter as per Term No. 7.2 above, the Allottee(s) shall take possession of theApartment from the Promoter by executing necessary indemnities, undertakings and suchother documentation as prescribed in this Agreement and the Promoter shall give possessionof the Apartment to the Allottee(s). In case the Allottee(s) fails to take possession within thetime provided as per Term No. 7.2 above, such Allottee shall continue to be liable to paymaintenance charges as specified under Term No. 7.2 above.

7.4 Possession of the Allottee- After obtaining the occupancy certificate and handing overphysical possession of the Apartment to the Allottee, it shall be the responsibility of thePromoter to handover the necessary documents and plan, including common areas to theMaintenance Society or the competent authority, as the case may be, as per the local laws:

Provided that, in the absence of any local law, the Promoter shall handover the necessarydocuments and plans, including common areas, to the Maintenance Society or the competentauthority, as the case may be, within thirty days aft.er obtaining the completion certificate.

7.5 Cancellation by Allottee- The Allottee(s) shall have the right to cancel/withdraw hisallotment in the Project as provided in the Act:

Provided that where the Allottee(s) proposes to cancel/withdraw from the Project without anyfault of the Promoter, the Promoter herein is entitled to forfeit the booking amount paid for theallotment. The balance amount of money paid by the Allottee(s) shall be returned by thePromoter to the Allottee(s) within forty-five days of such cancellation.

7.6 Compensation-The Promoter shall compensate the Allottee in case of any loss, caused to himdue to defective title of the land, on which the Project is being developed or has beendeveloped, in the manner as provided under the Act and the claim for the interest andcompensation under this provision shall not be barred by limitation provided under any lawfor the time being in force.

Except for occurrence of a Force Majeure event, if the Promoter fails to complete or is unableto give possession of the said Apartment (i) in accordance with the terms of this Agreement,duly completed by the day specified in Term No. 7.1 above; or (ii) due to discontinuance of hisbusiness as a developer on account of suspension or revocation or expiry of the registrationunder the provisions of the Act; or for any other reason; the Promoter shall be liable, ondemand to the Allottee, in case the Allottee wishes to withdraw from the Project, withoutprejudice to any other remedy available, to return the total amount received by him in respectof the Apartment, with interest including compensation in the manner as provided under theAct within forty-five days of it becoming due:

Provided that where if the Allottee does not intent to withdraw from the Project the Promotershall pay the Allottee interest for every month of delay, till the handing over of the possessionof the Apartment which shall be paid by the Promoter to the Allott.ee within forty-five days of itbecoming due.

8. REPRESENTATIONS AND WARRANTIES OF THE PROMOTER:

The Promoter hereby represents and warrants to the Allottee(s) as follows:

(i)

Signature of Promoter Signature of Allottee

Page 12: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

requisite rights to carry out development upon the said Land and absolute, actual, physicaland legal possession of the said Land for the Project;

(ii) The Promoter has lawful rights and requisite approvals from the competent authorities tocarry out development of the Project;

(iii) That there is an encumbrance of Rs, 25,00,00,000/- (Rupees Twenty Five Crores Only) fromAu Financers (India) Limited having its registered office at 19-A Dhuleshwar Garden, .Jaipur-302001 against equitable mortgage on the property of the LLP situated at Khasra No. 35(Part), Village Bhojpura, Sahakar Marg Scheme, Lal Kothi, Jaipur, Rajasthan.

(iv) As per the best of the knowledge of the Promoter there are no litigations pending before anyCourt of law or Authority with respect to the said Land, Project or the Unit;

(v) All approvals, licenses and permits issued by the competent authorities with respect to theProject, said Land and Unit are valid and subsisting and have been obtained by followingdue process of law. Further, the Promoter has been and shall, at all times, remain to be incompliance with all applicable laws in relation to the Project, Unit and common areas;

(vi) The Promoter has the right to enter into this Agreement and has not committed or omitted toperform any act or thing, whereby the right, title and interest of the Allottee(s) createdherein, may prejudicially be affected;

(vii) The Promoter has not entered into any agreement for sale and/ or development agreement orany other agreement / arrangement with any person or party with respect to the said Land,including the Project and the said Unit which will, in any manner, affect the rights ofAllottee(s) under this Agreement;

(viii) The Promoter confirms that the Promoter is not restricted in any manner whatsoever fromselling the said Unit to the Allottee(s) in the manner contemplated in this Agreement;

(ix) At the time of execution of the conveyance deed the Promoter shall handover lawful, vacant,peaceful, physical possession of the Unit to the Allottee(s) and the common areas to theMaintenance Society;

(x) The Schedule Property is not the subject matters of any HUF and that no part thereof isowned by any minor and lor no minor has any right, title and claim over the ScheduleProperty;

(xi) The Promoter has duly paid and shall continue to pay and discharge all governmental dues,rates, charges and taxes and other monies, levies, impositions, premiums, damages and/orpenalties and other outgoings, whatsoever, payable with respect to the said Project to thecompetent authorities till the completion certificate has been issued and possession of theApartment along with common areas (equipped with all the specifications, amenities andfacilities) has been handed over to the Allottee and the Maintenance Society or thecompetent authority, as the case may be;

(xii) No notice from the Government or any other local body or authority or any legislativeenactment, government order, notification (including any notice for acquisition or requisitionof the said property) has been received by or served upon the Promoter in respect of the saidLand and/ or the Project.

9. EVENTSOFDEFAULTSANDCONSEQUENCES:

9.1 Subject to the ForceMajeure clause, the Promoter shall be considered under a condition ofdefault, in the following events, namely:-

(i) The Promoter fails to provide ready to move in possession of the Apartment/Flat to theAllottee(s) within the time period specified in Term No. 7.1 above in this Agreement orfails to complete the Project within the stipulated time disclosed at the time ofregistration of the Project with the Authority. For the purpose of this clause, 'ready tomove in possession' shall mean that the Apartment or Flat shall be in a habitablecondition which is complete in all respects including the provision of all specifications,amenities and facilities, as agreed to between the parties, and for which occupationcertificate and completion certificate, as the case may be, has been issued by thecompetent authority;

(ii) Discontinuance of the Promoter's business as a developer on account of suspension orrevocation or expiry of his registration under the provisions of the Act or the rules orregulations made thereunder.

11Signature of Promoter Signature of Allottee

Page 13: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

9.2 In case of default by the Promoter under the conditions listed above, Allottee(s) is entitledto the following:-

(i) Stop making further payments to the Promoter as demanded by the Promoter. If theAllottee(s) stops making payments, the Promoter shall correct the situation bycompleting the construction/ development milestones and only thereafter theAllottee(s) be required to make the next payment without any interest; or

(ii) The Allottee(s) shall have the option of terminating the Agreement in which case thePromoter shall be liable to refund the entire money paid by the Allottee(s) under anyhead whatsoever towards the purchase of the Apartment, along with interest withinforty-five days of receiving the termination notice:

Provided that where an Allottee(s) does not intend to withdraw from the Project orterminate the Agreement, he shall be paid, by the Promot.er, interest for the period ofdelay till the handing over of the possession of the Apartment, which shall be paid bythe Promoter to the Allottee within forty-five days of it becoming due.

9.3 The Allottee(s) shall be considered under a condition of default, on the occurrence of thefollowing events:

(i) In case the Allottee(s) fails to make payments for one consecutive demand made by thePromoter as per the payment plan stated above, despite having been issued notice inthat regard, the Allottee(s) shall be liable to pay interest to the Promoter on the unpaidamount.

(ii) In case of default by Allottee under the conditions listed above continues for a periodbeyond one consecutive month after notice from the Promoter in this regard, thePromoter may cancel the allotment of the Apartment in favour of the Allottee(s) andrefund the money paid to him by the Allottee(s) by deducting the booking amount andthe interest liabilities and this Agreement. shall t.hereupon stand terminated:

Provided that the Promoter shall intimate the Allottee about such termination at leastthirty days prior to such termination.

(iii) The Allottee(s) may obtain finance from any financial institution bank or any othersource but the Allottee(s) obligation to purchase the said apartment/Unit and makingof all payments pursuant to this Agreement shall not be contingent onhis/her/their/its ability or competency to obtain such financing, and the Allottee(s)will remain bound under this Agreement whether or not the Allottee(s) has/have beenable to obtain financing for the purchase of the said apartment/Unit.

(iv) Failure, pursuant to a request by the Promoter, to become a member of the associationof Allottee(s) or to pay subscription charges etc. as may be required by the Promoter orAssociation of Allottee(s), as the case may be.

(v) Assignment of this Agreement or any interest of the Allottee(s) in this Agreementwithout prior written consent of the Promoter or not executing documents as may berequired under the law for such transfer

(vi) Dishonor/stoppage of payment by any cheque(s) including postdated cheques given byAllottee(s) for any reason whatsoever

(vii) Sale/transfer/disposal of/dealing with, in any manner, the reserved car parking spaceindependent of the Unit or selling of the additional allotted parking space to any thirdparty other than occupant of the Building and / or of the project.

10. CONVEYANCE OF THE SAID APARTMENT:

The Promoter, on receipt of Total Price of the Apartment as per Term No. 1.2 under theAgreement from the Allottee shall execute a conveyance deed and convey the title of theApartment together with proportionate indivisible share in common areas within three monthsfrom the date of issuance of the occupancy certificate and the completion certificate, as the casemay be, to the Allottee:

Provided that in absence of local law, the conveyance deed in favour of the Allottee shall becarried out by the Promoter within three months from the date of issue of occupancy certificate.

12Signature of Promoter Signature of Allottee

Page 14: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

Provided further that, in case the A.llottee(s)fails to deposit the stamp duty, registration chargeswithin the period mentioned in the demand notice, letter, the Allottee(s) authorizes the Promoterto withhold registration of the conveyance deed in his/her favour till payment of stamp duty andregistration charges to the Promoter is made by the Allotteets).

11. ASSOCIATION OF OWNERSBUILDING/ APARTMENT /PROJECT:

AND MAINTENANCE OF THE SAID

11.1 The Promoter shall be responsible for providing and maintaining the essential services inthe Project, till the formation of I~WAand taking over of the maintenance of the Project bythe Resident Welfare Association (RWA)/Maintenance Society. The cost of suchmaintenance has been excluded in the Total Price of the Apartment.

11.2 That within a period of 3 months after the agreement to sale has been executed formajority of apartments or booking has been made for such number of apartments then thepromoter shall form a society (either under societies registration act, or cooperative societyact) or any association of the residents or any other body corporate for the responsibilitiesof maintenance of common amenities and common services described in and/or with suchother object or purpose or in such manner and to such extent as the promoter or theirnominees may decide from time to time. The allottee agrees and undertakes that in theevent of decision of the promoter to form any such society or association or body corporate,he shall be bound to join, subscribe and become a member of the society or association orbody corporate and to abide by and comply with the bye-laws and rules and regulations ofsuch society or association or body corporate. The allottee has undertaken that he/sheshall at all times sign and execute the application for registration and all other documentsnecessary for the formation and registration of the society or association or body corporateincluding its bye-laws and shall duly fill in, sign and return to the promoter within 10 (Ten)days of the same being forwarded by the promoter to the Allottee. The Allottee shall notraise any objection, if any changes or modifications are made in the draft bye - laws asmay be required by the registrar of societies or other competent authority as the occasionmay demand. After the allottee hands over the management / maintenance of the commonamenities and common services to the society or association or body corporate, it shall bethe sole responsibility of the society or association or the body corporate, as the case maybe, to run and maintain the common amenities and all common services and to determinefrom time to time the rate and amount of combined expenses and outgoings for thecommon amenities and common services along with the sinking fund charges recoverableproportionately from the allottee and from all other parties and the allottee agrees that heshall be liable to pay the said combined expenses and outgoing for common amenities andservices and other dues to the society or association or the body corporate as the case maybe from time to time & regularly. In the event of the society or the body corporate beingformed and registered, the society or association or body corporate so formed shall besolely responsible for the administration of the affairs in relation to theapartments Zmultistoried residential scheme and the property appertaining thereto and forthe management of common areas & facilities. The society may look after the said affairs ofresidential scheme on its own or appoint a professional agency for the said purpose.

11.3 The "Allottee r s" hereby agrees to pay to the promoter/society/body corporate as the casemay be, a non-refundable interest free sum of Rs. / - (Rupees_______________ .... Only) as payment towards 'MaintenanceCorpus' of the Society or the body corporate as the case may be [hereinafter known as"Said Corpus"] at the time of offer of possession. Upon formation of the Society, thepromoter shall be bound to deposit this sum in a separate bank account of the Society. Allprinciple and interest monies in the said account shall exclusively be used formaintenance, upkeep and repairs of the said building. The said maintenance corpus shallnot be utilized for any purpose other than specifically approved by the Society under itsbye laws. It is agreed that the monies to the credit of said corpus fund may be invested infixed deposits/Government Securities and / or debt mutual funds or in any other manneras may be approved by the promoter/Society/body corporate.

11.4 The "Allotteer s" hereby agrees that in case shortfall occurs in maintenance funds beingavailable from interest earned out of corpus funds then, in addition to the money paidtowards the Said Corpus referred to above, he shall pay such proportionate maintenancecost on a monthly basis as determined by the Society and / or the "Promoter". Suchpayment shall be made latest by the 10th of every month in advance. In case of default ofpayment of the aforesaid charges the promoter or its nominee shall be entitled todiscontinue / disconnect the service of water and electricity etc. to the said flat as alsoshall have right to remove common benefits, amenities, facilities and services etc. apartfrom the right to recover the charges with minimum interest (il! 12 % p.a. from the allotteeand/or from the occupier of the said nat.

Signature of Promoter Signature of Allottee

Page 15: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

11.5 Till the society is formed and the maintenance is handed over to it as stated above, theentire maintenance upkeep and preservation of the said building, operation of the commonservices and management of common areas therein shall be done by the promoter. Thepromoter shall maintained the building/project from the maintenance corpus and itsearnings, but if any shortfall occurs in maintenance funds being available from interestearned out of corpus funds then, the flat owner/occupier shall pay such proportionatemaintenance cost on a monthly basis as determined by the "Promoter" on the terms andconditions mentioned herein unless agreed to separately. The Buyer agrees to payproportionate share of all expenses incurred by the Promoter for maintenance of saidbuilding "PINNACLE" as and when demanded by the promoter.

12. DEFECT LIABILITY:

It is agreed that in case any structural defect or any other defect in workmanship, quality orprovision of services or any other obligations of the Promoter as per this Agreement relating tosuch development is brought to the notice of the Promoter within a period of five years by theallottee from the date of handing over possession, it shall be the duty of the Promoter to rectifysuch defects without further charge, within thirty days, and in the event of Promoter's failure torectify such defects within such time, the aggrieved Allottee(s) shall be entitled to receiveappropriate compensation in the manner as provided under the Act.

13. RIGHT TO ENTER THE APARTMENT FOR REPAIRS:

The Promoter/Maintenance Society shall have rights of unrestricted access of all common areas,garages/covered parking and parking spaces for providing necessary maintenance services andthe Allottee(s) agrees to permit the Promoter/Maintenance Society to enter into the Apartmentor any part thereof, after due notice and during the normal working hours, unless thecircumstances warrant otherwise, with a view to set right any defect.

14. USAGE:

14.1 Use of Basement(s) and Service Areas:- The basement and service areas, if any, as locatedwithin the Project, shall be earmarked for purposes such as parking spaces and servicesincluding but not limited to electric sub-station, transformer, DG set rooms, undergroundwater tanks, pump rooms, maintenance and service rooms, fire fighting pumps andequipment's etc. and other permitted uses as per sanctioned plans. The Allottee(s) shall not bepermitted to use the services areas and the basements in any manner whatsoever, other thanthose earmarked as parking spaces, and the same shall be reserved for used by theMaintenance Society for rendering maintenance services.

14.2 Use ofParking:-

(a) The Allottee(s) will not be allowed to cover the parking area in any manner or raise any wallor any type of barrier / rope / fastening around the said car parking area

(b) The Allottee(s) agrees and confirms that the reserved car parking allotted tohim/her/them/it shall automatically be cancelled in the event of cancellation, termination,surrender, relinquishment, resumption etc. of the said Unit under any of the provisions ofthis Agreement or otherwise

(c) The Allottee(s) undertakes to park his/her/their/its vehicle in the allotted car parking spaceand nowhere else in the Building.

15. GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT

15.1 Subject to Term 12 above, the Allottee(s) shall, after taking possession, be solely responsible tomaintain the said Apartment at his/her own cost, in good repair and condition and shall notdo or suffer to be done anything in or to the said building Apartment, or the staircases, lifts,common passages, corridors, circulation areas, atrium or compound which may be inviolation of any laws or rules of any authority or change or alter or make additions to the saidApartment, and keep the said Apartment, its walls and partitions, sewers, drains, pipes andappurtenances thereto or belonging thereto in good and tenantable repair and maintain thesame in a fit and proper condition and ensure that the support, shelter etc. of the building isnot in any way damaged or jeopardized.

15.2

14Signature of Promoter

Page 16: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

windows or carry out any change in the exterior elevation or design. Further the Allottee shallstore any hazardous or combustible goods in the Apartment or place any heavy material in thecommon passages or staircase of the building. The Allottee shall also not remove any wall,including the outer and load wall of the Apartment.

15.3 The Allottee shall plan and distribute its electric load in conformity with the electric systemsinstalled by the Promoter and thereafter the Maintenance Society and/or maintenance agencyappointed by the Maintenance Society. The Allottee shall be responsive for any loss ordamages arising out of breach of any of the aforesaid conditions.

15.4 The Allottee(s) shall not use the said apartment for any purpose other than residential.

15.5 The Allottee(s) shall not do any act or thing which may render void or voidable any insuranceof the said property and the building in which the said apartment is situated or any partthereof or whereby any increase in premium shall become payable in respect of the saidbuilding and/or the said apartment.

15.6 Air Conditioning for the apartment shall be done through the VRV ("Variable RefrigerantVolume") system only for the better elevation of the building. The VRV system shall beinstalled by the buyer at their own cost, but the copper fitting for the same shall be providedby the builder at the fixed points as decided in the architectural designs. The VRVunit shallbe installed at a designated place provided in each flat. The buyer agrees to abide by the saidcondition and shall be restrained from installing the VRV unit at any other place in future.This condition must be strictly followed in order to preserve the elevation of the building.

15.7 The Allottee(s) shall not demolish any structure of the Unit or any portion of the same orcause to make any new construction in the Unit without the prior approval and consent of thePromoter and/ or the local authority, if required. The Allottee(s) however undertakes that itshall not divide/sub-divide the Unit in any manner. The Allottee(s) shall not change the colorand structure of the external facade of the Unit.

16. COMPLIANCE OF LAWS, NOTIFICATIONS ETC. BY PARTIES:

The Parties are entering into this Agreement for the allotment of an Apartment with the fullknowledge of all laws, rules, regulations, notifications applicable to the Project.

17. ADDITIONAL CONSTRUCTIONS:

The Promoter undertakes that it has no right to make additions or to put up additional structureanywhere in the Project after the building plan, layout plans sanction plan and specifications,amenities and facilities has been approved by the competent authorities and disclosed, exceptfor as provided in the Act.

18. PROMOTER SHALL NOT MORTGAGE OR CREATE A CHARGE:

After the Promoter executes this Agreement he shall not mortgage or create a charge on the saidApartment and if any such mortgage or charge is made or created then notwithstandinganything contained in any other law for the time being in force, such mortgage for charge shallnot affect the right and interest of the Allottee(s) who has taken or agreed to take suchApartment.

19. BINDING EFFECT:

Forwarding this Agreement to the Allottee(s) by the Promoter does not create a binding obligationon the part of the Promoter or the Allottee(s) until, firstly, the Allottee(s) signs and delivers thisAgreement with all the Schedules along with the payments due as stipulated in this Agreementwithin thirty days from the date of receipt by the Allottee(s) and secondly, appears forregistration of the same before the concerned Sub-Registrar (address ofSub-Registrar) as and when intimated by the Promoter. If the Allottee(s) fails to execute anddeliver to the Promoter this Agreement within 30 (thirty) days from the date of its receipt by theAllottee(s) and/or appear before the Sub-Registrar for its registration as and when intimated bythe Promoter, then the Promoter shall serve a notice to the Allottee(s) for rectifying the default,which if not rectified within 30 (thirty) days from the date of its receipt by the Allottee(s),application of the Allottee shall be treated as cancelled and all sums deposited by the Allottee(s)in connection therewith including the booking amount shall be returned to the Allottee(s)without any interest or compensation whatsoever.

20. ENTIRE AGREEMENT:

This Agreement, along with its schedules, constitutes the entire Agreement between the Partieswith respect to the subject matter hereof and supersedes any and all understandings, any other

15Signature of Promoter Signature of Allottee

Page 17: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

agreements, allotment letter, correspondences, arrangements whether written or oral, if any,between the Parties in regard to the said Apartment/ Building, as the case may be.

21. RIGHT TO AMEND:

This Agreement may only be amended through written consent of the Parties.

22. PROVISIONS OF THIS AGREEMENT APPLICABLE ALLOTTEE/ SUBSEQUENT ALLOTTEES:

It is clearly understood and so agreed by and between the Parties hereto that all the provisionscontained herein and the obligations arising hereunder in respect of the said Apartment and theProject shall equally be applicable to and enforceable against and by any subsequent Allottee ofthe Apartment, in case of a transfer, as the said obligations go along with the Apartment for allintents and purposes.

23. WAIVER NOT A LIMITATION TO ENFORCE:

23.1 The Promoter may, at its sole option and discretion, without prejudice to its rights as saidout in this Agreement waive the breach by the Allottee in not making payments as per thepayment plan mentioned this Agreement including waving the payment of interest fordelayed payment. It is made clear and so agreed by the Allottee that exercise of discretion bythe Promoter in the case of one allottee shall not be construed to be a precedent and lorbinding on the Promoter to exercise such discretion in the case of other allottees.

23.2 Failure on part of the Parties to enforce at any time or for any period of time the provisionshereof shall not be construed to be a waiver of any provisions or of the right thereafter toenforce each and every provision.

23.3 No waiver shall be effective unless made in writing and signed by an authorizedrepresentative of the waiving Party.

24. SEVERABILITY:

If any provision of this Agreement shall be determined to be void or unenforceable under the Actor the Rules and Regulations made thereunder or under other applicable laws, such provisionsof the Agreement shall be deemed amended or deleted in so far as reasonably inconsistent withthe purpose of this Agreement and to the extent necessary to the conform to the Act or the Rulesand Regulations made thereunder or the applicable law, as the case may be, and remainingprovisions of this Agreement shall remain valid and enforceable as applicable at the time ofexecution of this Agreement.

25. METHOD OF CALCULATION OF PROPORTIONATE SHARE WHEREVER REFERRED TO INTHE AGREEMENT:

Wherever in this Agreement it is stipulated that the Allottee(s) has to make any payment, incommon with other allottees in the Project, the same shall be the proportion which the carpetarea of the Apartment bears to the total carpet area of all the Apartments in the Project.

26. FURTHER ASSURANCES:

Both Parties agree that they shall execute, acknowledge and deliver to the other suchinstruments and take such other actions, in additions to the instruments and actionsspecifically provided for herein, as may be reasonably required in order to effectuate theprovisions of this Agreement or of any transaction contemplated herein or to confirm or perfectany right to be created or transferred hereunder or pursuant to any such transaction.

27. PLACE OF EXECUTION:

The execution of this Agreement shall be completed only upon its execution by the Promoterthrough its authorized signatory at the Promoter's Office, in after the Agreement isduly executed by the Allottee and the Promoter or simultaneously with the execution the saidAgreement shall be registered at the office of the Sub-Registrar at Hence thisAgreement shall be deemed to have been executed at _

28. BROKERAGE

16Signature of Promoter

Page 18: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

amount of sale price agreed to be payable to the Intending Promoter for the said Premises.Further the Intending Allottee undertakes to indemnify and hold the Intending Promoter free andharmless from and against any or all liabilities and expenses in this connection.

29. COUNTERPARTS

Two copies of this Agreement shall be executed in two originals and the Promoter shall retain thefirst and send the second executed copy to the Allottee(s) for his/ her reference and record.

30. INTERPRETATION

a) Headings are inserted for convenience only and do not affect the interpretation of thisAgreement.

b) References including defined terms to the singular include the plural and vice versa and to aperson includes body corporate and vice versa.

31. NOTICES:

All the notices to be served on the Allottee and the Promoter as contemplated by this Agreementshall be deemed to have been duly served if sent to the Allottee or the Promoter by registeredpost at their respective addresses specified below:-

._-- --------------------

RATNAWATINFRASTRUCTURECONSTRUCTIONCOMPANYLLP

Allottee Name .

48, 1st Floor, Manokamna Golirnar Garden,Sahakar Marg, Jaipur - 302015.

Allottee Address .

It shall be the duty of the Parties to inform each other of any changes subsequent to theexecution of this Agreement in the above address by registered post failing which allcommunications and letters posted at the above address shall be deemed to have been receivedby the Promoter or the Allotteets), as the case may be.

32. JOINT ALLOTTEE:

That in case there are Joint Allottees all communications shall be sent by the Promoter to theAllottee whose name appears first and at the address given by him/her which shall for allintents and purposes to consider as properly served on all the Allotteets).

33. SAVINGS:

Any' application, letter, allotment letter or any other document signed by the allottee, in respectof the apartment, or building, as the case may be, prior to the execution and registration of theagreement for sale for such apartment, or building, as the case may be, shall not be construed tolimit the rights and interests of the allottee or the promoter under the agreement for sale, underthe Act, the rules or the regulations made thereunder.

34. GOVERNINGLAW:

That the rights and obligations of the parties under or arising out of this Agreement shall beconstrued and enforced in accordance with the Act, rules and regulations made thereunderincluding other applicable laws of India for the time being in force.

35. DISPUTERESOLUTION:

All or any dispute arising out of or touching upon or in relation to the terms and conditions ofthis Agreement including the interpretation and validity thereof and the respective rights andobligations of the Parties, shall be settled amicably by mutual discussions, between the Partiesfailing which the dispute shall be settled in the manner as provided under the Act.

INWITNESS WHERE OF parties herein above named have set their respective hands and signedthis Agreement for sale at in the presence of attesting witness, signing assuch on the day first above written.

-17

Signature of Promoter Signature of Allottee

Page 19: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAF1'

Signed and delivered by the within named Allottee(s) in the presence of witnesses on __day of __ , 2017.

+.---------------.----~--.

Passport size photographwith Passport size photograph with Passport size photographwithsignature across the photograph Signature across the photograph Signature across the photograph(First- Allottee) (Second- Allottee) (Third- Allottee)

SignatureSignature Signature

(Name): (Name) (Name)

(First-Allottee) (Second -Allottee] (Third- Allottee)

Signed and delivered by the within named Promoter in the presence of witnesses at•.............•...•.•...•...on __ day of ,2017

PROMOTERFor and on behalf of RATNAWATINFRASTRUCTURECONSTRUCTIONCOMPANYLLP

-Name: Shri .................................

-Signature

Designation: Designated Partner

WITNESSES

Signature

Name

AddressISignature

Name

Address

__.-, I

18Signature of Promoter Signature of Allottee

Page 20: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

SCHEDULE-l(Details of land holdings of the Promoter and location of the Project)

Name of Scheme/Colony and City Plot No_ Area (in meters)--------------f------------- -,-__ :__ ~ __ __1

Village Bhojpura, Sahakar Marg Khasra No. 35 (Part) 4492.60 sq. metersScheme, Lal Kothi, 1.1l_iE_u.!:___

------ ------------~----------------

1. The piece and parcel of the plot of land in site is bounded on the :-

In North: Scheme No.5

In South: Parivahan Bhawan

In East: Nallah

In West: Sahakar Marg 30 M. wide road

And measuring

North to South 204'-6" (east side) and 239'-8" (west side)

East to West 288'-0" (north side) and 179'-0" (south side)

2. Latitude/ Longitude of the end points of the Project

265353.4 N - 75 47 36.9 E,265351.1 N -75 4737.0 E,265350.3 N - 75 4739.0 E,265351.2 N - 754740.0 E.

3. Other details of the location of the Project: Opposite Hotel Las Vegas, Near 22 Godam circle,Jaipur

4. Location Map

Raj \'_'~l"'i)1;:':tltL~'• :,p r\'t~)ru

O:.i)!);:,;' ..i',c V;~i- .

PINNACLE SM) St,I<\CIVnl•'::r;jO,

19Signature ofAllotteeSignature of Promoter

----------- - -

Page 21: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

SCHEDULE-2(Building Approval Plan of the Project)

DRAFT

.1'

!.;:.#91

20Signature of Promoter Signature of Allottee

Approved Plan of the Project

Page 22: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

SCHEDULE-3

(Floor Plan of the Apartment and Block/ Tower in the Project)

21Signature of Promoter Signature of Allottee

Page 23: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

SCHEDULE-4

[Description of the Apartment and Garage/Covered Parking (if applicable)along with boundaries in all four directions]

Description of Apartment:

In North .

In South .

In East .

In West .

22Signature of Promoter Signature of Allottee

Page 24: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

SCHEDULE-5(Specifications which are part of the Apartment] which are in conformity with theAdvertisements, Prospectus etc. circulated by the Promoter at time of booking of Units in theProject]

Drawing/Dining;.. Large size tile flooring;;.. Thick Designer door shutter with door frame at main entrance or equivalent;;.. Euro profile aluminium windows with two track system;;.. Acrylic emulsion pain t on all internal wall & ceiling;;.. High-end electrical switches.

Bedrooms;..;..;..;..;..

Large size tile flooring;Veneered / laminated flush door with door frameEuro profile aluminium windows with two track system;Acrylic emulsion paint on all internal wall & ceiling;High-end electrical switches.

Wash room;.. Anti - skid tiles for flooring;;.. Veneered / laminated flush door with door frame or equivalent;;.. Counter basin with granite top;;.. Separate wet area with glass partition;;.. Provision for geyser, exhaust fan;;.. C.P. fittings of international brand;;.. Sanitary ware of international brand;;.. Grid false ceiling.

Kitchen~ Modular kitchen;~ Anti - skid tiles for flooring;~ Acrylic emulsion paint in left over areas;~ Euro profile aluminium windows with two track system;;.. Granite counter top;~ Premium modular switches;;.. Gas pipe line and gas detector;;.. Provision for geyser, exhaust fan & R.O. Unit;;.. Washing machine point in utility area.

Balcony & terraces;.. Anti - skid tiles for flooring;~ Glass railing with S.S. Handrail.

Home automation;.. All major functional control in living area;;.. Video door phone;;.. Panic button in the kitchen / master bedroom;;.. Lighting automation in living & master bedroom area.

23Signature of Promoter Signature of Allottee

Page 25: ALLOTMENT LETTER Ref.No.: . Date: . Mr/Mrs./Ms . Sub ...rera.rajasthan.gov.in/Content/uploads/b81dbec6... · DRAFT inthe ,as permissible under the applicable lawand ofpro rata share

DRAFT

SCHEDULE-6(Specifications, facilities, amenities, internal/ external development works etc. which are partof the Project) which are in conformity with the Advertisements, Prospectus etc. circulated bythe Promoter at time of booking of Units in the Project)

1. Rain Water Harvesting System & 11. Cafe Lounge;Recharging Of Tube Well Water; 12. Indoor Games Room;

2. Sewage Treatment Plant; 13. Home Theatre;3. Power Backup; 14. Tuition Room;4. Badminton & Squash Court; 15. Library;5. Ball Room; 16. Out Door Games Area;6. Music & Dance Room; 17. Landscaped courtyard;7. Library; 18. Children's play area;8. Spa; 19. Visitors Parking;9. Swimming Pool; 20. Club House.10. Well Equipped Gymnasium;

(The Schedules to this Agreement for Sale shall be as agreed tobetween the Parties) ~

24Signature of Promoter Signature of Allottee