BECIL/RFP/SERVICES/ANTENNA/RFCABLE/CABLE TRAY/FMPHASE-III(BATCH-

1)/AGARTALA&GORAKHPUR/2016-17, DT: 20 FEB 2017

TENDER

FOR

DISMANTLING, ERECTION AND INSTALLATION OF

ANTENNA SYSTEM/RF CABLE/CABLE TRAY etc

AT

CTI AGARTALA, GORAKHPUR

FOR

PRIVATE FM BROADCASTERS

BROADCAST ENGINEERING CONSULTANTS INDIALIMITED

56/A17, Block-C, Sector-62, NOIDA 201301

CONTENTS

S.No TITLE

1. : TENDER SCHEDULE AND CRITICAL DATES

2. : PREFACE AND SCOPE OF WORK

3. : GENERAL CONDITIONS O F CONTRACT

4. : CLAUSES OF CONTRACT SPECIFICATION

5. : SUMMARY

6. : BILL OF QUANTITIES

TENDER SCHEDULE AND CRITICAL DATES

Sealed quotations are invited by BECIL, 56/A17, Block-C, Sector-62, NOIDA 201301 for Dismantling, Erection and Installation of Antenna system/RF Cable /cable tray etc at CTI Agartala, Gorakhpur for Private FM broadcasters

Work EMD (In Rs.)

Time of completion

Date of issuing

of tender

Last Date of receipt of

Tender

Time and date

of opening of Tender

Dismantling, Erection and

Installation of Antenna

system/ RF Cable/Cable

tray at CTI Agartala,

Gorakhpur for Private

FM broadcasters

Rs 14000 For

Agartala site,

Rs 6000 for

Gorakhpur

3 weeks after start of

work for Agartala site

and

2 Weeks after start of

work for Gorakhpur

20-02-2017

27-02-2017

At 15:00 Hrs

27-02-2017

at 15:30 Hrs

Quotations should be submitted in tender box at :-

Broadcast Engineering Consultants India Limited (BECIL),

56/A-17, Block-C, Sector-62,

Noida 201301-U.P

The Envelope should be superscripted as “Dismantling, Erection and Installation of Antenna system/RF

Cable/Cable Tray etc at CTI Agartala and Gorakhpur sites for Private FM broadcasters”.

The Tenderer may contact on mail or Phone/Fax for any clarification regarding the nature & scope

of work involved to the below officer:

Shri Rupesh Kumar

Asst. Manager

E-mail: rupesh@becil.com

M:8130190453

Phone: 0120-4177850 Fax : 0120-4177879

TENDER DOCUMENT

PREFACE AND SCOPE OF WORK

PREFACE:

1. BROADCAST E N G I N E E R I N G C O N S U L T A N T S I N D I A LIMITED invites tender for “Dismantling, Erection, Installation of Antenna system/RF Cable/cable tray at CTI Agartala and Gorakhpur sites for Private FM broadcasters”.

2. Type of work: a) Dismantling of existing installed antenna and Installation of New Antenna (wherever

required as per BOQ)

b) Dismantling of existing installed RF Feeder Cable and Installation of New RF feeder

Cable

c) Dismantling of existing installed Cable Tray and Installation of New Cable Tray

3. The joint measurements of work shall be done by the Contractor or their authorized representative a n d BECIL Personnel or his authorized a g e n t

4. The Contractor at his owns cost shall provide electricity, water, pumps/ generator& store for cement and tools and plants (T&P).

GENERAL CONDITIONS OF CONTRACT

1. The contractor's rates must include the cost of transportation of labour, T & P to the site etc.

2. The concrete/ mortar mix shall be determined based on standard weights.

3. For interpreting the specification, the following order of decreasing importance shall be

followed:

a) Drawings

b) Instructions from the BECIL Personnel in writing

c) Conditions of Contract

4. Any defect developed within Defect Liability Period of one year from the date of virtual completion will have to be rectified by the Contractor at his own cost.

5. The contractor shall ensure that during execution of work, no damage is caused to any of the

new equipment/material and other existing installation, structures at site. Any Loss/Damage, if reported by Prasar Bharti/BECIL, shall have to be rectified/compensated/paid by the contractor.The contractor will indemnify BECIL against all such risks and their consequences. Personal working shall be properly insured by the contractor against any injuries and death as the installation work involves working at height. BECIL shall not responsible for any claim

arising out of accidents 6. The Contractor shall not be entitled to any compensation for any loss suffered by him on

account of any delay in commencing or executing the work, whatsoever is the cause for such delays.

7. After acceptance of the tender, the tenderer shall submit the order of acceptance within 3

days of the information of acceptance. In any case of delay, the Earnest Money may be forfeited and the order may be get cancelled.

8. No extension of time will be allowed to the contractor due to weather conditions prevalent in the area. The contractor is expected to take all the precautions at his own cost so that the workmanship and the materials are not affected in the inclement weather.

9. EMD: An earnest money deposit (EMD) of as mentioned above will be submitted by

the Tenderer in a separate envelope along with the tender proposal in the form of DD in favor of Broadcast Engineering Consultants India Limited payable at New Delhi. The EMD of the successful tenderer shall be returned after submission of PBG, whereas the EMD of the unsuccessful tenderer shall be returned within 15 days of the finalization of the contractor. The EMD shall not carry any interest.

10. BECIL reserve the right to decide & Place work order on L1 basis on site offered by bidders.

BECIL decision will be final and will be binding on all bidders. In case, L1 does not accept the order work will go to L2.

11. Negotiation may be done by private broadcasters with L1 bidder.

12. The Competent Authority does not bind himself to accept the lowest or any other

tender and reserves to himself the authority to reject any or all of the tenders received without the assignment of any reason .All Tenders in which any of the prescribed conditions are not fulfilled or are incomplete in any respect are liable to be rejected.

PRO VISIONS FOR LABOURS

1 Labour – Payments to labour shall be as per law & shall be paid to the satisfaction of BECIL personnel. Photostat copy of receipt of payment made is to be supplied to the BECIL personnel by the contractor if desired by him.

2 Medical facilities (as per law) for workers will be provided by the Contractors including their insurance during the complete work at each site.

3 As the work involve high risk therefore it is compulsory that all the labours shall be

got insured according to the work compensation policy or equivalent . Without this the labour or any other person are not allow to enter in the premises of AIR HPT

sites.

SECURITY OF MATERIALS

Safe custody of Materials supplied by the BECIL is the responsibility of the Contractor,

including its watch and ward.

N.B. It may be noted that the installation work is to be carried out at the working

station of HPT sites. As such the Contractor shall have to adhere to all security

norms / procedure & instructions of the station-in-charge during complete period /while carrying out the work at site.

CLAUSES OF CONTRACT

1. DEFINITIONS M/S Broadcast Engineering Consultants India Ltd. (BECIL) - The Principal.

THE CONTRACTOR (To whom work is awarded)

a) Any of those mentioned above as such in the agreement shall include their

Legal representatives, assignees or successors and are treated through out the contract

document as if each were of singular number and masculine gender.

b) “The Site” shall mean the site of the contract work including any building, tower

and i n s t a l l a t i o n thereon and any other land allotted by the Principal for contractor’s

use.

c) The term “Sub-contractor “ , as employed herein, includes those having a direct

contract with the Contractor and it includes one who furnishes material worked to a

special design according to the plans or specification of the work but does not include

one who merely furnished material & not so worked. Anyone doing work on a piece

rate basis shall be deemed a sub-contractor.

d) Written notice shall be deemed to have been duly served if delivered in person to the

individual or to a member of the firm /Contractor or if delivered at or sent by

registered mail to the last business address know to him who gives this notice.

e) The term “work” of the Contractor or sub-contractor includes labour.

f) All time limits stated in the Contract Document are the essence of the Contract.

g) The law of the place of work shall govern the construction under this Contract.

h) The date of virtual completion of a project. or specified area of project is the

date when Installation is sufficiently completed in accordance with the contract

document as modified by any change on variation orders agreed by the parties;

so that the Principal can occupy the project for the use it was intended.

2. CONTRACT DOCUMENT

The following documents shall constitute the contract documents.

a) Preface

b) General Condition of Contract.

c) Bill of Quantities

d) Drawing issued by BECIL from time to time.

2.1 The contract o r d e r is Complementary. What is called for in any one shall be as

binding as if called for by all. The contract document shall remain in the custody of

the Principal.

2.2 After the award of the contract, the Contractor will arrange and get approved from the BECIL personnel all such further drawings and details as may be necessary along with structural drgs. from a Structural Engineer by BECIL .These drawings shall be a reasonable development of the work described in the contract document.

2.3 The Contractor shall keep one copy of the specification, with descriptive schedule

or other like document referred to in this clause and one copy of the Contract

Drawings and such other drawings and supplied to him from time to time so as

to be available to the Principal or his representative at all reasonable times.

2.4 Upon final payment under the clauses of these conditions, the contractor shall, if

requested by BECIL forth with, return to BECIL all drawings, details specifications

and other document of like nature which bears his name or that of the Consultant.

3. TYPE OF CONTRACT

The Contract shall be an Item Rate Contract.

4. ERRORS

Any error in description or omission of items from the contract bills shall not

vitiate this contract but shall be corrected and deemed to be a variation

required by BECIL representative.

6. SCOPE AND INTENT

6.1 SCOPE: - The general character and scope of the work is illustrated and

defined by specification and by the signed Drawings. If the Contractor

shall find any discrepancy in or divergence between the contract drawings and

or the Contract Bill shall immediately given to the BECIL personnel a written

notice specifying the discrepancy or divergence and the BECIL personnel shall

issue instruction in regard there to.

6.2 INTENT: - The contractor shall carry out and complete the work in every

aspect in accordance with the Contract and with the direction of and to the

reasonable satisfaction of the BECIL personnel and Principal. BECIL from time to

time, may issue further drawings and which are collectively referred to as

BECIL personnel’s instruction. All such drawings and instructions shall be

consistent with the contract document, true development there of, and

reasonable inferable there from.

6.3 The Contractor shall not without the written consent of the Principal,

assign this contract or sublet any portion of the work failing which the

Principal may serve a notice in writing rescinding the contract where upon the

security deposit may be forfeited.

7.0 BECIL INSTRUCTIONS

7.1 If within seven days after receipt of written notice from the BECIL personnel

required for compliance to an instruction & the Contractor does not comply

there with, then BECIL may employ and pay other person/ firm to execute

any work what so ever at Contractor’s risk and cost.

7.2 All instructions issued by the BECIL personnel shall be in writing. Any instruction

issued orally shall be of immediate effect but shall be got confirmed in writing

by the Contractor within seven days and if not dissented by the BECIL

personnel, the Contractors confirmation shall take effect as from the expiry of

the said period of seven days.

8. FACILITIES AND CO-OPERATION

In case of the work indicated on the drawings but not included in the schedule of

work, the Contractor shall provide necessary facilities and co-operation for

execution of such work including all cutting, filling or patching of his work that

may be required or execute such work so as to receive the work of other

contractor shown upon or reasonably implied by the drawings and

specification for the completed structure and he shall make good after

them the BECIL personnel may direct. Any cost caused by the defective or

ill- timed work is to be borne by the party responsible thereof.

9. WORK SCHEDULE CHART

The Contractor shall prepare PERT chart/ Bar chart and submit the same for

approval of BECIL.

10. ACCESS TO THE WORK

BECIL personnel, the Principal and their representatives shall at all

reasonable time have access to the works and to the workshops or other

places of the contract where work is being prepared for the Contract including

workshops of sub contractors.

11. BECIL PERSONNEL STATUS AND DECISIONS

11.1 The term BECIL personnel means the Engineer/Site Incharge appointed or nominated by BECIL who shall supervise and be in charge of the work at site. Such work shall be subject to be guidance of the BECIL officials and under control and direction of the Principal.

11.2 BECIL personnel shall be the Principal’s representative during the construction period.

He shall periodically visit the site, familiarize himself generally with the progress

and the quality of the work to determine in general if the work is

proceeding in accordance with contract document.

11.3 BECIL personnel or its representative shall have power to give notice to the

Contractor or to his representative for non approval of any work or

material and such work shall be suspended or the decision of the principal be

obtained. The work will, from time to time, be examined b y the BECIL personnel

but such examination shall not in any way exonerate the Contractor from

obligation to remedy any defects which may be found to exist at any stage of

the works or after the same is completed. Subject to the limitation of this

clause the contractor shall take instructions only from the BECIL personnel.

11.4 Decisions: BECIL personnel shall within a reasonable time give decision

on all claims of the Contractor and all other matters relating to the execution

and progress of the work. The BECIL personnel may in consultation with the

Principal so desire to find it necessary, and from time to time issue further

drawings, details and/ or written instructions, written directions and written

explanation.

11.5 Dismissal: The Contractor shall on the written request of BECIL

personnel / Principal immediately dismiss from the work any person employed

thereon by him who may be in the opinion of the BECIL personnel and/ or

the Principal be incompetent . The same Person may not be employed on the

work without the permission of the Jr. Manager or the Principal as the case may

be.

12.0 CONTRACTORS FIELD ORGANISATION AND EQUIPMENT

12.1 Equipment: The contractor shall provide and install all necessary hoists,

ladders, Scaffolding, tools, plants, motors, pumps, all transport for labour and plant

necessary for the proper carrying out execution and completion of the work to

the satisfaction of the BECIL personnel /Principal.

13.0 MEASUREMENT OF WORK DONE /CERTIFICATES AND PAYMENTS

13.1 The BECIL personnel shall except as otherwise provided, ascertain and

determine by measurement the value in accordance with the contract of the

work done. All measurement of all items having financial value shall be entered in

Measurement book and /or level field book so that a compete record is obtained

of all work performed under the Contract.

13.2 At the period of interim certificate named in the appendix to these

conditions, the BECIL personnel shall issue a certificate stating the amount due to

the Contractor from the Principal and the contractor will be entitled to

payment thereof within the period for honoring certificate. Interim valuations

shall be made whenever the BECIL personnel considers it to be necessary.

The certificate shall be issued when the Contractor executes the net work of

25% of the contracted amount.

13.3 The amount stated as due in an interim certificate shall be total value of

the work properly executed and of the materials and goods delivered to or

adjacent to the work for use thereon up to and including a date not less

than seven days before the said certificate, less any amount which may be

retained by the Principal and less any installment previously paid under this

condition.

13.4 The Principal shall retain 10% of the total value of the work done as security

deposit subject to the conditions agreed upon in respect thereof in the contract

documents.

13.5. The Contractor shall be entitled to the payment of the final balance in

accordance with the final certificate Issued in writing by the BECIL personnel

at the expiry of the period referred to as the Defects Liability Period of

twelve months from the date of virtual completion or as soon as after the

expiry and all defects made good according to the true intent and meaning

here of which ever shall last happen provided always that the issue by the

BECIL personnel of any certificate during the progress of the work or after

completion shall not relieve the contractor from his liability . In case of

dishonesty or fraud or fraudulent concealment relating to the works or

material or of any matter dealt with in the certificate and in case of all defects

and insufficiency in the work or materials which on reasonable examination

would have disclosed .The rates of extra items though approved during the

currency of work are subject to changes in the final bill which can be finally

approved by the Principal or Consultant of the Principal, if Principal so desires.

13.6 The measurement and valuation of the work shall be completed with in the

period of final Valuation and measurement stated in the appendix to these

conditions. The Contractor shall be supplied with the copy of the priced bill of

valuation not later than the end of the said period and before the issue of final

certificate.

14. CLAIMS FOR EXTRAS

When any instruction or decision given involves an extra amount or whereby the

Contractor may plan to claim an extra amount it shall be the responsibility of the

Contractor to inform the Principal of the extra amount and get written authorization

from the Principal before proceeding with the work involved.

15. DEDUCTION FOR UNCORRECTED WORK

If the BECIL personnel deems it inexpedient to correct work damage or not

done in accordance with the Contract, an equitable deduction from the

contract price shall be made by the Principal there of on the basis which is

applicable for extra work/items.

16. FLUCTUATIONS

The Contractor shall not claim any extra for fluctuation of prices and the contract

price shall not be subject to any rise for prices except as provided for especially

in any clause in the Contract Document.

17. WORKMANSHIP

All workmen shall be of best trade practices and the Contractor shall

immediately remove from the works workman which in the opinion of the

Principal or their representative are defective or unsuitable and shall substitute

proper workman at his own cost.

18. INSPECTION:

The contractor shall furnish promptly without additional charges all reasonable

facilities and labour necessary for the safe and convenient inspection and

test that may be required by the BECIL personnel or Principal.

19. INSPECTION OF WORK

As and when required by the Principal or the BECIL personnel, Contractor

shall organize inspection of works at his cost to prove their soundness and

efficiency. If after tests any work or portions of work are considered defective or

unsound by the Principal or the BECIL personnel, the Contractor shall remove the

defective work from the site, or pull down and re- execute the works at his own

cost to the satisfaction of BECIL personnel and the Principal.

20.0 POSSESSION, COMPLETION AND POSTPONMENT

20.1 On the date of commencement stated in the appendix to these conditions,

possession of the site shall be given to the Contractor who shall there upon

begin the work regularly and diligently proceed with the same and he shall

complete the same on or before the date for or in accordance with

provisions of extension of time contained in these conditions.

20.2 The BECIL personnel may issue instruction in regard to the postponement

of any work to be executed under the provisions of this Contract.

20.3 If at any time or times before virtual completion of the work the Principal

with the consent of the Contractor may take possession of any part or parts of

the same for handing over to other agency, then not withstanding anyt hing

expressed or implied elsewhere in this Contract, such a part shall not be

deemed to be virtually completed. The Contractor shall not claim that such parts

are complete and refund of payment in lieu thereof.

21. EXTENSION

Upon it becoming reasonably apparent that the progress of the work is

delayed, the Contractor shall forthwith give written notice of the cause of the

delay to the Principal that the completion of the work is likely to be or has

been delayed beyond any extended time previously fixed under the clause.

The BECIL personnel may grant extension of time for such period for which delay

occurred for reasons beyond the control of Contractor.

22. TERMINATION OF CONTRACT

If the contractor is found faulting at any instance of the period of execution of project by his misdeeds or conduct OR attitude towards work in terms of deviation from

specifications and drawings, the contract will be terminated without assigning any reason. All decisions will be taken at the discretion of BECIL and contractor will not have any legal binding on the contract.

23. ARBITRATION AND JURISIDICTION

The CMD BECIL reserves to himself the right of accepting the whole or any part of the tender and the tenderer shall be bound to perform the same at the rate quoted. In case of any dispute, the Principal shall appoint in consultation and agreement with the Contractors, an Architect of repute in Delhi (India) as Arbitrator whose decision shall be final and binding on both the parties i .e the Principal and the Contractors However , the jurisdiction of only the Delhi High Court shall be accepted incase a reference of dispute ismade to a court.

SUMMARY WORK:- DISMANTLING, ERECTION AND INSTALLATION OF ANTENNA SYSTEM, RF CABLE AND CABLE TRAY

1 Earnest Money Deposit Rs 14000 For Agartala site, Rs 6000 for Gorakhpur

2 Defect Liability Period 12 Months from the date of completion of work

3 Payment terms and condition 30% of total order value after completion of Dismantling work as per Bill of quantity.

50% of total order value after Erection and Installation as per Bill of Quantity.

10% of total order value after commissioning of complete system certified by BECIL

10% after defect liability period or after submission of PBG for 10% valid for defect liability period.

4 Period of final Measurement: 1 Week

5 Date of commencement of

work at Site Within one week after instruction from BECIL

6 Period of completion 3 weeks after start of work for Agartala site and

2 Weeks after start of work for Gorakhpur site

7 Liquidated damages Penalty @ 2% for the order value for 1-4 weeks of delay

subject to maximum of 10 % of the order value. After 4

weeks of delay, BECIL shall be free to cancel the order and

get the work done from a third party at your risk & cost.

BILL OF QUANTITY

DISMANTLING, ERECTION AND INSTALLATION

OF

ANTENNA SYSTEM/RF CABLE/CABLE TRAY

IMPORTANT NOTE:-

ALL THE APPLICABLE TAXES MUST BE DEFINED VERY CLEARLY AS PER PRICE FORMAT

THE QUANTITY OF ITEMS MENTIONED IN BOM MAY VARY ACCORDING TO THE SITE

CONDITION AND HENCE PER METER RATE MUST BE MENTIONED.

IT IS UPTO THE DISCRETION OF BECIL WHETHER THE WHOLE OR PART OF THE WORK IS IMPARTED TO ITS VENDOR. IN ORDER TO EXECUTE THE WORK ON TIME, BECIL RESERVE THE RIGHT

TO DISTRIBUTE THE SITES AMONG THE VENDORS ON L1 BASIS.

AS PER THE PROJECT REQUIREMENT, NUMBER OF SITES MAY INCREASE OR DECREASE

AS PER THE SITE REQUIREMENT, ITEMS IN THE BOM MAY BE INCREASED OR DECREASED

SITE WISE L1 WILL BE DECIDED FOR EXECUTION OF WORK

S. No.

Description Unit Total Qty.

Unit Price

Total Price

Name of Site: Agartala

1 Dismantling of FM Antenna

Removing the existing 1 bay X4 sides antenna along with other hardware fitting / fixtures etc. and packing (Removing the existing 16 panel antenna along with other hardware fitting / fixtures etc. and packing (including supply of packaging) of the complete antenna system as required.

JOB 1

2 Dismantling of existing RF feeder cable

Removing the existing RF cable along with its mounting fixtures and accessories and packing the RF cable on *cable drum and accessories in boxes so as the same can be dispatched and used at new location.

Meter 1X130

3

Erection of 4 bay X1 side FM Antenna on the existing tower in the FM aperture after unpacking, physical checking/ necessary care for the safety of the antenna system like cleaning, ingress of moisture, pressurization etc. at site before Erection in accordance with the Erection manual of the manufacturer along with hauling of the complete panel antenna system.

JOB 1

4 Erection, of new RF Co-axial cables on the existing tower/Cable Tray. Meter 1X130

5 Horizontal RF Cable Tray: Erection/hoisting, fixing of new horizontal RF cable tray for RF coaxial cables along with vertical support, complete as required at site.

Mtr 93

6 Installation of RF Coaxial Cable including making various RF co-axial line input/output connections for feeding to the FM antenna complete from Antenna Patch Panel/Rigid Line as required.

JOB 1

7 Any other job offered for the completeness of the system JOB 1

8 EARTHING

a

Preparation and commissioning of earth pits duly linked by 25mm X3 mm copper strip having each with 600 x 600 x 3.15 mm thick copper electrode with watering arrangement of chamber funnel, charcoal salt etc. The electrode shall be connected with 25mmx3mm thick copper strip and terminated into the chamber with brazing arrangement. The earth resistance shall not exceed 1.0 ohms. The rate shall include testing the same & documentation. (IS 3043 : 1987).

Nos. 2

b Supply of 25mm x3mm Copper strip from earth pit to respective location below the ground upto 6” and along with the cable tray as per site requirement.

Per Meter

1

9 Optional Item Rate, if required at site

a Dismantling of Existing Horizontal cable tray, along with support and clamps etc

Per Mtr Rate*

1

b Dismantling of Existing Vertical cable tray, along with support and clamps etc

Per Mtr Rate*

1

c Vertical RF Cable Tray: Erection/hoisting, fixing of new vertical RF cable tray for RF co-axial cables on the existing tower complete as required at site.

Per Mtr Rate*

1

* Cable drum of new RF cable and boxes of accessories of new RF cable shall be utilized for packing at site

S. No.

Description Unit Total Qty. Unit Price

(in INR)

Total Price

(in INR)

Name of Site: Gorakhpur

1 Dismantling of existing RF feeder cable

a Removing the existing RF cable along with its mounting fixtures and accessories

1 job 1X115 mtr

2 Erection of RF Co-axial cables on the Tower/Cable Tray. 1 job 1X115 mtr

3

Horizontal RF Cable Tray: Erection/hoisting, fixing of new horizontal RF cable tray for RF coaxial cables along with MS canopy, vertical support, complete as required at site.

Mtr 60

4

Installation of RF Coaxial Cable including making various RF co-axial line input/output connections for feeding to the FM antenna complete from Antenna Patch Panel/Rigid Line as required.

JOB 1

5 EARTHING

a

Preparation and commissioning of earth pits duly linked by 25mm X3 mm copper strip having each with 600 x 600 x 3.15 mm thick copper electrode with watering arrangement of chamber funnel, charcoal salt etc. The electrode shall be connected with 25mmx3mm thick copper strip and terminated into the chamber with brazing arrangement. The earth resistance shall not exceed 1.0 ohms. The rate shall include testing the same & documentation. (IS 3043 : 1987).

Nos. 2

b Supply of 25mm x3mm Copper strip from earth pit to respective location below the ground upto 6” and along with the cable tray as per site requirement.

Per Meter 1

6 Any other job offered for the completeness of the system JOB 1

7 Optional Item Rate, if required at site

a Dismantling of Existing Horizontal cable tray, along with support and clamps etc

Per Mtr Rate*

1

b Dismantling of Existing Vertical cable tray, along with support and clamps etc

Per Mtr Rate*

1

c Vertical RF Cable Tray: Erection/hoisting, fixing of new vertical RF cable tray for RF co-axial cables on the existing tower complete as required at site.

Per Mtr Rate*

1