rfq application for architectural … application for architectural services. project name project...
TRANSCRIPT
RFQ APPLICATION FOR ARCHITECTURAL SERVICES
Project Name
Project Scope
Campus
Project Number
For application and selection process information, refer to RFQ 12/13-09 Architectural Design Services
APPLICANT FIRM Contact Information
RFQ 12/13-09 Architectural Design Services
Name of Firm
Address(Zip)(State)(City)(Street)
(Email)(Fax)(Telephone)
Contact Person(Name) (Title)
(Email)(Fax)(Telephone)
1 PROJECT COMPATIBILITY(5 Points)
In the space below, please provide a brief letter of introduction and justification describing why your firm may be most ideally suited for services to be provided on this Request (Project Compatibility).
RFQ 12/13-09 Architectural Design Services
2 APPLICANT - BUSINESS STRUCTURE(0 Points)
Former Name(s) of FirmCurrent Name of Firm
(Years w/Firm)(Years Experience)(License #)(Name)Licensed Project QualifierOwnership Type
Total StaffNumber of OfficesOperating in Florida SinceYear Established
(Zip)(State)(City)(Street)Office Locations (Home)
Project Office Location(Zip)(State)(City)(Street)
Other(Zip)(State)(City)(Street)
(Zip)(State)(City)(Street)Other
(5 Points)3 DISTANCE
Project Office to LW Campus (Miles)
4 SUPPLIER DIVERSITY(10 Points)
Firm Minority Certification(Black, Hispanic, Asian, Women, Small Disadvantaged)
Non-minority Firm Profile% Black % Hispanic % Asian % Women % Other
Refer to General Information Supplement for additional instructions.
RFQ 12/13-09 Architectural Design Services
5 APPLICANT - ASSIGNED PROJECT STAFF(30 Points)
(Corporate Licenses #)
Applicant Firm
(Years w/Firm)(% to Project)(License #)(Name)Principal-in-Charge
(Years w/Firm)(% to Project)(License #)(Name)Project Manager
(Years w/Firm)(% to Project)(License #)(Name)Architectural Designer
(Years w/Firm)(% to Project)(License #)(Name)LEED Coordinator
(Years w/Firm)(% to Project)(License #)(Name)Support Architect
(Years w/Firm)(% to Project)(License #)(Name)Construction Administrator
(Years w/Firm)(% to Project)(License #)(Name)Other
(Years w/Firm)(% to Project)(License #)(Name)
(Years w/Firm)(% to Project)(License #)(Name)
(Years w/Firm)(% to Project)(License #)(Name)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
(Years Experience)
RFQ 12/13-09 Architectural Design Services
5.1 APPLICANT FIRM STAFFING ORGANIZATIONAL CHART(0 Points) Optional
RFQ 12/13-09 Architectural Design Services
Name of Project
6 RELATED PROJECT EXPERIENCE
The following section (up to 10 projects-pages) may be used to describe your related experience in the design and construction of projects of similar size and scope. It is strongly recommended to provide color photographs of each project to supplement your written descriptions.
(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.1
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.2
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.3
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.4
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.5
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.6
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.7
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.8
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.9
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Name of Project
6 RELATED PROJECT EXPERIENCE(40 Points)
RFQ 12/13-09 Architectural Design Services
Location - City, State, Country
Function/Project Use
Completion/Anticipated Date Size (GSF)
6.10
Cost (Construction)
Nature of Firm's Responsibility
Project Owner's Representative, Address & Telephone Number
Project User's Representative, Address & Telephone Number
Project Type (New/Rem/Ren)
Firm's Staff Responsibilities
Present Project Status
Firm's Project Architect and Key Professionals Involved
Occupancy Type
Photographs
Although the Architect's continuing contract will unlikely utilize LEED Projects, the college supports sustainability initiatives. If you have LEED experience, please provide information on your most recent 3 projects.
(0 Points)7 LEED - CERTIFIED PROJECTS
(Date)(Certification Level: Platinum, Gold, Silver, Certified) Certification/Date
(Cost/GSP)(Cost)(GSF/Stories) Size/Cost
(State)(City)(Street)(Owner) Owner/Location7.1 Project Name
(Date)(Certification Level: Platinum, Gold, Silver, Certified) Certification/Date
(Cost/GSP)(GSF/Stories) (Cost)
(State)(City)(Street)(Owner) Owner/Location7.2 Project Name
Size/Cost
(Date)(Certification Level: Platinum, Gold, Silver, Certified) Certification/Date
(Cost/GSP)(Cost)(GSF/Stories) Size/Cost
(State)(City)(Street)(Owner) Owner/Location7.3 Project Name
RFQ 12/13-09 Architectural Design Services
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
2013
(5 Points)8 CONTRACT WORK WITH THE COLLEGE
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
(Project) (Total Construction Cost)(Final Completion Date)
2011(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
2012
(Sum Total Construction Cost)(Total Number of Projects Completed)
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
2010
RFQ 12/13-09 Architectural Design Services
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
(Total Construction Cost)(Final Completion Date)(Project)
2009
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
9 DISPUTES, LITIGATION, DEFAULTS
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Applicant should disclose the results and amounts of settlement of the most recent ten (10) design or construction contract litigation, arbitration, mediation or other claims involving the Applicant or its principals or any proposed consultants for a period of five years prior to the submission of this proposal. These cases should prioritized as follows: (1) Disputes with Owners, (2) Disputes in the State of Florida, (3) other.
(5 Points)
RFQ 12/13-09 Architectural Design Services
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
Current StatusType of complaintYear FiledPlaintiff/DefendantName of case
9 DISPUTES, LITIGATION, DEFAULTS
RFQ 12/13-09 Architectural Design Services