mumbai zonal office · zonal manager, punjab & sind bank, mumbai zonal office, 27/29, ambalal...
TRANSCRIPT
PUNJAB & SIND BANK MUMBAI ZONAL OFFICE
PROPOSED RENOVATION OF OFFICER QUARTERS (Vasant Parijat, Vasant Kadamba, Vasant Chinar, Vasant Ashoka, Vasant Mandar, Vasant
Gulmohor, Vasant Kusumba- Thane)
(Civil, Painting, Electric)
(Technical Bid)
(Volume-1)
TENDER DOCUMENTS
NAME OF THE CONTRACTOR :
ADDRESS :
DATE OF SUBMISSION : On or Before July 20, 2019 upto 1.00 p.m.
PUNJAB & SIND BANK MUMBAI ZONAL OFFICE
27/29, Ambalal Doshi Marg, Fort, Mumbai- 400001
E-mail: [email protected]
Ref . No. Date:
To,
Dear Sir,
TENDER NOTICE
Sub.:- Proposed RENOVATION OF OFFICER QUARTERS AT VASANT PARIJAT, VASANT KADAMBA, VASANT
CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT GULMOHOR, VASANT KUSUMBA- THANE
We hereby invite you to submit your quotation for above- mentioned work. The specifications, special conditions of contract
and schedule of work to be carried out is enclosed herewith. You are requested to inspect the site and the nature of work prior
to submitting the tenders. You are requested to submit your most competitive offer complete in all respect to reach THE
ZONAL MANAGER, PUNJAB & SIND BANK, MUMBAI ZONAL OFFICE, 27/29, Ambalal Doshi Marg, Fort, Mumbai-
400001 by 1.00 p.m. on July 20, 2019 in a sealed cover with the name & address of your firm on the left hand bottom corner.
1. The Tender documents can be obtained from Mumbai Zonal Office or can be downloaded from Bank’s website on payment of Rs. 1,000/- (Rupees One Thousand Only) in cash/DD/Pay Order/Cheque in favor of Punjab & Sind Bank
towards cost of tender. Please note that the cost of the tender is non-refundable.
2. Estimate of the work is Rs. 62,09,630.00 without GST.
3. Bank’s Empanelled Contractor of Class “A” Category can also quote for the tender.
4. Sealed tenders on item rate basis are invited in two bid system from eligible reputed and quality conscious contractors as
per eligibility criteria for the “RENOVATION OF OFFICER QUARTERS AT VASANT PARIJAT, VASANT
KADAMBA, VASANT CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT GULMOHOR, VASANT
KUSUMBA- THANE”
5. The following are the eligibility criteria for the contractors to participate in the tender process:
a) The applicant should have undertaken works in Government Departments / Public Sector Undertakings / Central
Autonomous Bodies/State Autonomous Bodies / Financial Institutions and other reputed Private Firms during last
5years.
1. One work/project costing 80%of the value of estimated work OR
2. Two works/projects costing 50%ofthe value of estimated work OR
3. Three works/projectscosting40% of the value of estimated work
b) The applicant should have Income Tax registration number. The applicant should have registered with statutory
authorities for GST, Work Contract Tax etc, as applicable to them in terms of extant laws. Applicant should submit
copy of the income tax PAN, GST certificate with valid registration number.
c) The applicant shall have the average annual financial turnover of at least 30% the value of the value of estimated
work in the respective category during last 3 years prior to 31-03-2019.
d) Contractors for all classes should have well-established office in Mumbai, Thane, Navi Mumbai with adequate
engineering staff and the applicant / firm / company shall be registered with ESI, EPF etc, as per extant labour laws.
e) Similar work means renovation of Quarters/ Office/ Branch Premises of Nationalized Bank in Mumbai including
Furniture, Civil, Painting, Electric.
f) The contractor\firms should submit completion certificate from the employer clearly indicating the nature, magnitude, date of starting and date of completion, indicating whether the works are completed within the stipulated
time in respect of qualifying works.
6. The tender document is in two volumes as detailed below:
VOLUME-1 Technical Bid Containing
1. Tender Notice
2. Introduction.
3
3. Special Instructions & conditions.
4. Letter of Offer.
5. Articles of agreement
VOLUME-2 Price Bid containing 1. Preamble to B.O.Q.
2. List of Approved Manufacturers for materials.
3. Bill of quantities.
6. The technical bid-volume 1 duly filled in, signed in all the pages and stamped by the tenderer to be submitted giving the details of company profile, audited Balance Sheet for last 3 years, Proof of submission of Income Tax returns, PAN No.,
GST No., Work experience of similar works during the last 5 years may be submitted in a separate sealed cover-1 with
the EMD DD super scribing as “Technical Bid & Name of the work”. The Volume-2 –Price bid duly filled and signed
to be placed in a separate sealed cover-2 super scribing as “Price Bid & Name of the work”. Both the technical and
Price bid to be enclosed within another cover and the same may be superscribed as “Tender for the RENOVATION OF
OFFICER QUARTERS AT VASANT PARIJAT, VASANT KADAMBA, VASANT CHINAR, VASANT
ASHOKA, VASANT MANDAR, VASANT GULMOHOR, VASANT KUSUMBA- THANE” and shall be submitted
to THE ZONAL MANAGER, PUNJAB & SIND BANK, MUMBAI ZONAL OFFICE, 27/29, Ambalal Doshi Marg,
Fort, Mumbai- 400001 on or before July 20, 2019 upto 1.00 p.m..
7. The Sealed Envelopes shall be opened on July 20, 2019 at 2.00 P.M. Or Day & Time Convenient to Bank in the presence
of the tenderers or authorized representatives if they desire to attend.
8. The Price bid of tenderers who satisfies the eligibility criteria prescribed only will be opened. The date of opening of
Price bid of qualified contractors will be decided after scrutiny of technical bid/or as may be decided by the competent
authority. The date and time of opening of Price bid will be intimated to the qualified bidders
9. Non-compliance of the above instructions is liable to render the Tender non-bonafide.
10. Details of similar projects and particulars of the Contractor to be submitted in prescribed format enclosed under Appendix B.
11. The envelope should be accompanied by an Earnest money Deposit of Rs. 62,000/- (Rupees Sixty Two Thousand Only),
by Crossed Order A/C. Payee Demand Draft, in favor of PUNJAB & SIND BANK. A tender not accompanied by such
Demand Draft as Earnest Money Deposit will not be considered. The Earnest Money Deposit of the unsuccessful tenderer
will be returned without any interest within fifteen days from the date when the decision for award of work is taken by
Bank.
12. This Earnest Money Deposit shall not bear any interest and shall be forfeited in the event of evasion, refusal or delay on
the part of the tenderer to sign & execute the contract on acceptance of his tender. The EMD without any interest have be
returned to the tenderer if his tender is not accepted.
13. The rates quoted will include and cover all cost, expenses, liabilities of very description and all risk of every kind to be
taken in execution and handing over the work to the Bank. All Taxes taxes applicable and prevailing from time to time on
such item for which the same are leviable and the rates quoted by contractor are inclusive of the same. Each page of the
tender shall bear the signature of the bidder over his name stamp.
14. Bank reserves the right to accept or reject lowest or any other bid in full or in part and/ or accept any bid other than the
lowest in full or in part without assigning any reason, whatsoever. No correspondence will be accepted / entered in this
connection and Bank’s decision shall be final, conclusive and binding on all.
15. All rules & regulations of the Society to be followed while working. Timing of work will be 10am to 6pm with no work between 2pm to 4pm.
16. This tender notice shall form part of the contract and non- submission of tender in the above manner will render your
offer liable for rejection.
Thanking you,
Yours faithfully,
Zonal Manager
4
I N T R O D U C T I O N
1. NAME OF THE CLIENT PUNJAB & SIND BANK
OFFERING CONTRACT
2. SITE ADDRESS OFFICER QUARTERS
Vasant Parijat, Vasant Kadamba, Vasant Chinar, Vasant Ashoka,
Vasant Mandar, Vasant Gulmohor, Vasant Kusumba- Thane
3. SCOPE OF WORK Civil, Painting, Electric Work
4. A. ISSUE OF TENDERS TO BE DOWNLOADED FROM BANK’S WEBSITE
WWW.PSBINDIA.COM
B. SUBMISSION OF TENDERS ON OR BEFORE JULY 20, 2019 UP TO 1.00 P.M.
AT PUNJAB & SIND BANK’S ZONAL OFFICE
27/29, AMBALAL DOSHI MARG, FORT, MUMBAI - 01
5. C. DATE OF OPENING OF TENDERS ON JULY 20, 2019 AT 2.00 P.M. OR DAY & TIME CONVINEINT TO BANK
6. TIME LIMIT FOR EXECUTION Renovation / Repair work of each flat is to be completed in all respect
within 21 days from the start of work and total work of all flats is to be
completed within 6 Months from the date of work order.
7. EARNEST MONEY DEPOSIT Rs. 62,000/-
8. INITIAL SECURITY DEPOSIT 2% OF ACCEPTED VALUE OF TENDER LESS EMD.
9. RETENTION MONEY 8% OF EACH INTERIM BILL VALUE.
10. TOTAL S.D. INCLUDING I.S.D 10% OF COST OF WORK
AND RETENTION MONEY
11. DEFECT LIABILITY PERIOD 12 MONTHS FROM DATE OF COMPLETION OF WORK
12. INSURANCE 100% OF CONTRACT VALUE
13. PENALTY OF DELAY 1% OF THE CONTRACT SUM PER WEEK MAXIMUM
AMOUNT OF LIQUIDATED DAMAGE WILL BE 10% OF COST
OF WORK.
14. PAYMENT OF R.A. BILLS After Completion of minimum group of Four flats.
5
DETAILS OF THE FIRM
A. GENERAL INFORMATION:
Name and address of the Firm
Status of the Firm (Enclose Copy) Company
Partnership
Proprietor Firm
Individual
Name of Proprietor/ Directors/ Partners? i)
ii)
iii)
Registration Details
Companies/ Firm Registration No. & Date
PAN No.
GST No.
Name and address of Bankers
(a) Telephone
(b) Mobile
(c) Fax
(d) E-mail
Place of incorporation/registration
Year of Incorporation/registration
Main Lines of business
If you are registered in panel of other
Organization / Statutory bodies such
CPWD, PWD, MES, Banks, etc, furnish their name, Category and date of
registration.( furnish proof)
Details of three responsible clients/persons
to whom the major works carried out by
the applicant with address and telephone
number who will be in a position to certify
about the quality as well as past
performance of your organization
1.
2.
3.
Details of EMD DD No.
Date:
Issuing Bank/Branch
6
B. FINANCIAL STATEMENT:
ANNUAL TURN OVER (CIVIL ENGINEERING PROJECTS) DATA FOR LAST THREE YEARS
YEAR TURNOVER IN RS. LAKHS.
2016 – 2017
2017 – 2018
2018 – 2019
AVERAGE ANNUAL TURNOVER
Note:
1. All individual firms must complete the information in this form. The information supplied should be the annual turnover in terms of the amount billed to clients for each year in progress or completed during the last three years.
2. Attested Copy of the audited balance sheets and profit & loss account for the last 3 years shall be enclosed.
C. CERTIFICATES
CERTIFICATES YES NO
Income Tax returns filed Certificate
GST registration Certificate
Provident Fund registration Certificate
Work completion certificates
PAN Card
Note: Attach attested copies of Items Answered Yes above
D. KEY PERSONNEL OF THE ORGANISATION
Sl.
No.
Name Designation Qualification Professional
experience
No. of years working
with the organization
E. PLANT & EQUIPMENT OWNED BY THE ORGANISATION AND AVAILABLE FOR THIS WORK
Sl.
No.
Equipment Year of
Manufacture
Capacity Number/ Quantity
Note:
1. Give details of all the key equipments for construction, such as concrete mixers, weigh batchers, vibrators, Trucks,
Tippers, Hoists, Rammers, Steel shuttering plates, Steel Scaffolding materials, polishing machines, that the firm
proposes to use for the proposed works at the site.
2. The applicant should clearly demonstrate that he has access to all key equipment which will be required for the
successful completion of the works.
F. EXPERIENCE RECORD.
1. DETAILS OF “RENOVATION WORKS” COMPLETED DURING LAST FIVE YEARS, COSTING
MORE THAN RS. 17 LAKHS EACH.
7
Sl.
No.
Name of work
and name &
address of the
Owner
Total cost
(Rs. Lakhs)
Date of
commencement
Date of
completion
Carpet Area special features if
any
In the above table, list only those works, which have similar nature & complexity. Provide copies of Work Orders and Completion Certificates for each project. Work orders and Completion
Certificates will be verified if required.
2. DETAILS OF WORKS IN HAND COSTING MORE THAN RS. 25 LAKHS EACH.
Name
of
work
Name &
Address
of client
Value of
Firm's
Portion
of total
Contract
Date of
award
Original
Stipulated
Date of
Completion
Value of
Outstanding
Work (Rs.
Lakhs)
Estimated
Completion
Date
Reasons
for
Delay, if
any
Special
Features,
if any
1. Details of all works which are at various stages of execution including works for which work orders have been received but work is yet to start, or works approaching completion but for which full completion certificates are yet
to be issued, are to be provided.
2. Details as available at the time of preparation of this document have to be provided.
/
8
To,
The Zonal Manager
Punjab & Sind Bank
Mumbai Zonal Office
27/29, Ambalal Doshi Marg, Fort, Mumbai- 400001
Dear Sir,
LETTER OF OFFER
Sub. :- Proposed RENOVATION OF OFFICER QUARTERS AT VASANT PARIJAT, VASANT KADAMBA, VASANT
CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT GULMOHOR, VASANT KUSUMBA- THANE
With reference to the tenders regarding the above work invited by you, we have to state as under.
We declare that before quoting the rates, We have visited the site and our rates are as per present site condition, Further we
herewith deposit EMD (Rs. 62,000/-) as Earnest Money for due execution of the works at my / our tendered rates as per the
Terms of Contract. In the event of this tender being accepted, I / We agree to enter into and execute the necessary contract
documents as required by you.
D.D. No. : Drawn on :
Dated : Amount :
As required by you, I / We are returning herewith the documents (in single) duly signed by us at each page in token of our
acceptance of the provisions in the documents.
We hereby after to execute and complete the whole of the works strictly in accordance with the said conditions of contract,
special conditions of contracts, specifications and drawings at the rates set out against each of the items of work in the
schedule of quantities. The total cost included in the above is Rs. (Rupees
only)
We have carefully read and clearly understood the conditions of contracts, special conditions of contract, and specifications.
We agree to complete the work at the rate \ rates quoted by me \ us in the schedule of quantities and within the specified time
from the date of work order awarding the work to us.
We understand the work is to be completed within scheduled time period.
Our rates are firm and include and cover all cost, expenses, liabilities of very description and all risk of every kind to be taken
in execution and handing over the work to the Bank. All Taxes applicable and prevailing from time to time on such item for
which the same are leviable and the rates quoted by us are inclusive of the same.
Thanking you,
Yours faithfully,
NAME : _____________________________________
ADDRESS ; _____________________________________
_____________________________________ _____________________________________
_____________________________________
TELE. NO. : _____________________________________
FAX. NO. ; _____________________________________
MOBILE NO. :_____________________________________
9
FORM OF AGREEMENT
THIS AGREEMENT made this day of , 2019 between PUNJAB & SIND BANK (hereinafter called “The
Employer”) of one part and of having registered office at
(Hereinafter called “the Contractor”) of the other part.
WHEREAS the Employer is desirous of carrying out Proposed RENOVATION OF OFFICER QUARTERS AT VASANT
PARIJAT, VASANT KADAMBA, VASANT CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT
GULMOHOR, VASANT KUSUMBA- THANE (Hereinafter called “the Work”) and has caused drawings and Bills of
Quantities showing and describing the work to be done to be prepared by or under the direction of Architect AND
WHEREAS the Contractor supplied the owner with a fully priced copy of the said Bills of Quantities (which copy
hereinafter referred to as “the Contract Bills”) AND WHEREAS the said drawings (hereinafter referred to at “the Contract Drawings”) and the Contract Bills have been signed by on or behalf of the parties hereto: AND WHEREAS the contractor
has deposited the sum of Rs. 62,000/- with the Employer for due performance of this Agreement.
NOW IT IS HEREBY AGREED AS FOLLOWS
1. For the consideration hereinafter mentioned the contractor will upon and subject to the conditions annexed carry out and
complete the work shown upon the contract Drawings and described by or referred to in the Contract Bill and in said
conditions.
2. The Bank will pay the Contractor the sum of Rupees (hereinafter referred to as “the Contract
Sum”) of such other sum as shall become payable hereunder at the times and in the manner specified in the said
conditions.
3. The term “the Architect” in the said conditions shall mean the person as the owner shall nominate for that purpose, not
being a person to whom the contractor shall object for reasons considered to be sufficient by, mentioned in the said
conditions. Provided always that no person subsequently appointed to be the Architect under this Contract shall be
entitled to disregard or overrule and certificate or opinion or decision or approval or instruction given or expressed by the
Architect for the time being.
4. Tender documents containing Notice to the Contractors, Conditions of Contract, Appendix thereto, Special Conditions of
contract, Specifications, Schedule of Quantities with the rates entered therein shall be read and studied as forming part of
this agreement, and the parties hereto shall respectively abide by and submit themselves to the conditions, stipulations
and perform the agreements on their parts respectively in such conditions contained.
5. Time shall be considered as of the essence of this Agreement and the Contractor hereby agrees to commence the work
soon after the site is handed over to him as provided for in the said conditions and to complete the entire work within 6
Months from date of work order, nevertheless to the provisions of extension of time.
6. This agreement and Contract shall be deemed to have been made in and any question or dispute arising out of or in any
way connected with this agreement and contract shall be deemed to have arisen in and only the courts in Bombay shall
have jurisdiction on to determine the same.
AS WITNESS the hands of the said parties.
Signed by the said In the presence of BANK
Witness
Name:
Address:
Signed by the said
In the presence of CONTRACTOR
Witness
Name:
Address:
10
TENDER FORM
The general Terms and Conditions that are more particularly set out herein below for the purpose of appointing contractors
for the purpose of carrying out Proposed RENOVATION OF OFFICER QUARTERS AT VASANT PARIJAT, VASANT
KADAMBA, VASANT CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT GULMOHOR, VASANT
KUSUMBA- THANE of PUNJAB & SIND BANK and other ancillary activities which is herein after referred to as “the said
work”. The definition and interpretation of the certain classes are more particularly set out hereunder.
DEFINITIONS:-
1. “THE SAID WORK” includes all items of Proposed RENOVATION OF OFFICER QUARTERS AT VASANT
PARIJAT, VASANT KADAMBA, VASANT CHINAR, VASANT ASHOKA, VASANT MANDAR, VASANT
GULMOHOR, VASANT KUSUMBA- THANE of PUNJAB & SIND BANK with bill of quantities, general terms &
conditions / special conditions / technical conditions.
2. The “BANK” shall mean the “PUNJAB & SIND BANK” having its registered address at MUMBAI ZONAL OFFICE,
27/29, Ambalal Doshi Marg, Fort, Mumbai- 400001 and authorized representative(s) of the BANK to discharge all or
any of its function.
3. The “CONTRACTOR” shall mean the individual or firm or Company, whether incorporated or not who is assigned the subject work, and shall include the personnel representative/ (s) of such individual person, firm or company of such
individuals or firm or Company, successors and permitted assigns.. The work contractor shall include “Sub-Contractor”
if expressly permitted by the Employer in writing.
4. The “ARCHITECT / CONSULTANT” means the authorized person or persons nominated by the BANK for the purpose
of the contract, who shall inspect, direct, Supervise, measure and issue certificates in respect of the said work and be
incharge of the work for the purpose of this contract. It also includes any person claiming through or under them.
5. The “CONTRACT” means instructions to Contractor, Tender, the written acceptance thereof, a form agreement between
‘EMPLOYER’ and ‘CONTRACTOR’ (where completed) to execute the works as per conditions and specifications set in
this document including Bill of Quantities.
6. The “SPECIFICATION” means specification referred to includes General, Special and Technical specifications (with
drawings if any) and any modification thereof or addition thereof as many from time be furnished or approved in writing
by the Consultant / Employer.
7. The “CONTRACT PRICE” means the sum named in the tender subject to additions or deductions there from as the case
may be.
8. The “PLANT & EQUIPMENT” of the contractor shall mean all plants, machinery, equipment, pipe work services and
all other things to be provided, erected, commissioned and maintained in accordance with Contract.
ELIGIBILITY FOR TENDERING & GENERAL CONDITIONS OF CONTRACT
1. The tender must be submitted in a sealed cover superscribed with the tender number, the name of the work as given
above and the tenderers name & address on the bottom left side of the envelope and handed over to the BANK. Tenders
will be received upto 1.00 p.m. on July 20, 2019.
2. The tenderer should visit the site and acquaint himself with the site conditions and should study all the tender documents
carefully and understand the tender contract conditions, specifications etc. before quoting. If there are any douts they
should get clarification in writing.
3. Late tenders i.e. tenders submitted / received after 1.00 p.m. on July 20, 2019 will not be considered.
4. The tender documents are non-transferable.
5. All the entries in the tender documents must be made in English and all entries must be by hand and written ink. If any
of the document is missing or unsigned, the tender may be considered invalid by the BANK in its discretion.
6. The tenderer should quote the rate and amount for the assessed quantities (area) of each item. The rates for each item
should be written both in figures as well as in words. Erasures, alteration, and overwriting must be avoided. Wrong
figures and words, if any, should be scored out and the correct figures and words neatly written authenticated by the
signature of the tenderer. No advice of any change in rates or conditions after opening the tender will be entertained.
11
7. In the event of any discrepancy in the rates quoted in words and figures, the former shall be prevail. Mathematical
computation error, if any, in the amount shall however be rectified.
8. The Employer has assumed that Contractor is fully aware of all items of work. Some items of work will be done simultaneously and some items will be done in sequence and different operations in different times.
9. The Contractor is responsible for the due and proper execution of all the works, terms and conditions stipulated under
this contract. Before offering his tender, Contractors should visit the site of works to ascertain the nature of work and to
collect all relevant information such as general, local, physical & climatic conditions of the site, availability, handling
and storage of materials, water, electricity, availability of labour, roads, the configuration of the ground. Any failure on
the part of the Contractor in this regard shall not absolve him from any responsibilities or obligations under this contract
and no claim whatsoever on account of these shall be entertained.
10. On receipt of intimation from the BANK for the acceptance of his/ their Tender, the successful Tenderer shall be bound
to implement the Contract and within ten days thereof, the successful Tenderer shall sign an agreement if called upon to
do so, but the written acceptance by BANK of a Tender will constitute a binding contract between BANK and the person so tendering, whether such formal agreement is or is not subsequently executed.
11. The tenderer should note that unless otherwise stated, the Tender is strictly on item rate basis and his attention is drawn
to the fact that rates for such a every item should be correct, workable and self–supporting. The quantities in the
Schedule of Quantities approximately indicated the total extent of work, but may vary and even be omitted thus altering
the aggregate value of the Contract. No claim for any compensation shall be entertained in this regard.
12. The tenderer must obtain all the information which may be necessary for the purpose of tendering for himself, on his
own responsibility and at his own expenses and for entering into a Contract must inspect the Site of the work and all
matters pertaining thereto, regarding supplying, fabricating and erecting at Site without any damage to the existing
property of the Client’s or their neighbors, if any.
13. PUNJAB & SIND BANK does not bind itself to accept the lowest or any tender and reserves to itself the right to accept
or reject any or all the tenders either in whole or in part, without assigning any reasons for doing so. PUNJAB & SIND
BANK also reserves the right to divide the work between two or more tenderers and the successful tenderers shall have
to carry out even part orders for various items at quoted rates. No variation in rates shall be allowed on this account
under any circumstances, whatsoever no correspondence will be accepted / entertained in this connection and Bank
decision shall be final conclusive and binding on all.
14. The rates shall be firm and shall not be subject to exchange variations, labour conditions, fluctuations in Railway
Freights or any conditions whatsoever.
15. The rates quoted by the tenderer in the schedule of quantities will be deemed to be for the finished work and shall include all charges for:
i. Design, Fabrication, supply and installation at Site, Labour, maintenance, fixing, arranging, cleaning, making good,
hauling etc.
ii. Plant, double, scaffolding, frame work, ladders, ropes, nails, spikes, tools, materials, workmen, protection from
weather, temporary support, platform, and maintenance of the Same. Insurance for labour materials and third party.
iii. All Taxes or any other levy imposed by Central Government or State Government or any Local Authorities.
iv. Packing, transportation, loading and unloading, freight charges, transit
v. Covering for the walling and other works during inclement weather or strikes or whenever Directed, as necessary.
vi. All temporary canvas, lights, tarpaulin, barricade, water shoots etc.
vii. All measures required to be taken for protection of existing works.
viii. All such temporary weather-proof sheds at such places and in a manner approved by the Architect for the storage and protection of materials against the effects of sun and rain.
ix. Testing of materials.
x. No tools and plants shall be issued by the Bank under the Contract.
16. All the payments of bills for the work shall be done only at MUMBAI ZONAL OFFICE, PUNJAB & SIND BANK.
17. For any clarification in any item of work, The contractor should get the same from the interior designer before
carrying our the work and all items of work should be carried out with the approval of the Bank.
EARNEST MONEY DEPOSIT/ SECURITY DEPOSIT/ MOBILIZATION ADVANCE
12
1. The tenderer is required to deposit towards Earnest money, a sum of Rs. 62,000/- in the form of a Demand Draft drawn
in favour of “PUNJAB & SIND BANK” and submit the Demand Draft along with the tender. Tenders unaccompanied
by the requisite Earnest Money Deposit will be summarily rejected.
2. EMD of the selected contractor / Tenderer will be retained as part of the Security Deposit required for due and satisfactory fulfillment of the contract in terms of the conditions of contract but shall be forfeited, if the Contractor /
tenderer fails to execute the agreement or start the work within 15 days of receipt of acceptance letter or if he withdraws
his bid within the period of validity of the bid (15 days). EMD of the unsuccessful tenderers shall be returned.
3. The Contractor shall pay Security Deposit @ 10% for the Contracted amount towards the security deposit after adjusting
the EMD shall be recovered in full from the first “on account “ bill.
4. The amount of Security Deposit may be refunded 14 (fourteen) days after the end of defects liability period provided he
has satisfactorily carried out all the works and rectified all defects in accordance with the condition of the contract,
including site clearance.
5. Defects liability period: Defects pointed out during the defects liability period of 12 (Twelve) months from the date of virtual completion of work, will be satisfactorily rectified by the contractor at no extra cost to the Employer with end
satisfaction.
6. No interest shall be payable on the EMD/SD amount.
7. No payment will be made towards mobilization Advance.
VALIDITY OF TENDER BID
1. The tender rates shall remain valid for a period of 90 days from the date for receipt of tender.
2. The tendered Rates shall remain firm during the contract period and no price escalation shall be permitted,
BANK’S RIGHT OF ACCEPTANCE OF BIDS
The BANK does not bind itself to accept the lowest or any tender and reserves to itself the right to accept or reject any or all
the tenders either in whole or in part, without assigning any reasons for doing so. BANK also reserves the right to divide the
work between two or more tenderers and the successful tenderers shall have to carry out even part orders for various items at
quoted rates. No variation in rates shall be allowed on this account under any circumstances, whatsoever no correspondence
will be accepted / entertained in this connection and BANK’s decision shall be final conclusive and binding on all.
BID, QUANTITIES / MEASUREMENTS
1. Price bid shall be quoted for all the items described in the schedule of quantities. Price quotation for part items of the
schedule shall not be accepted and such tender shall be summarily rejected.
2. No payment shall be made for the personal visit for assessing the quantities/ measurements for the preparation of the
tender bid.
3. Quantities / measurements for which the bid for various item is submitted shall be given precisely in the schedule of
Quantities, These quantities and measurements shall be based on the basic of personal assessment and physical
verification at site.
4. The Contractor shall calculate realistic quantities after receipt of drawings and after submitting first interim bill but
before submitting the second interim bill to Bank.
5. Any work done at factory will not be counted in the running accounts bill until the material is brought on site.
6. Excess quantity shall not be executed without written permission from Bank. In case of upward or downward revision in
quantities of items, the rate quoted by the Contractor shall remain firm at all the times.
7. The contractor shall take joint measurements with the Architect/Bank representative before covering up or
otherwise placing beyond the reach of measurement any item of work should the contractor neglect to do so,
the same shall be uncovered at contractor’s expense or in default thereof, no payment or allowance shall be
made for such work or the materials with which the same, was executed.
13
8. In case of any class of work over which there is no specification mentioned, the same shall be carried out in
accordance with the latest Indian Standard Specifications subject to the approval of the Architect / Bank.
DIMENSIONS: 1. Figured dimension are to be followed in all cases, Large scale details take precedence over small scale drawings, In
general the drawings shall indicate the dimensions positions and type of construction, the specification shall indicate the
qualities and methods, and the bill of quantities shall indicate the quantum and rate for each item of work.
2. Any work indicated in the drawings and not mentioned in the specifications or vice-versa shall be furnished as though
fully set forth in both. Any ambiguity, conflict of interpretation, errors or inconsistencies discovered in the drawings /
documents shall be promptly brought to the provisions giving more rigorous interpretation shall prevail but in
the event of disagreement between the contractors and the supervisors, decision of interior Designer shall be
final Incase of any discrepancy, the contractor is to ask for an explanation before proceeding with the work.
However specifications will prevail over the drawings.
OBSERVANCE / COMPLIANCE OF LABOR LAWS AND OTHER STATUTORY PROVISIONS FOR THE
CONTRACT
1. The contractor shall, in the execution of the contract, be responsible to comply with all the labor laws & statutory
provision governing the work, such as, but not limited to, the following Laws or any other act or enactment relating
thereto and rules as amended up to date.
a. Contract labor (Regulation & Abolition) Act. 1970. The Contractor shall submit a copy of the license obtained under
this act along with the bid.
b. Employees State Insurance Act for Security and Insurance of staff/ workers.
c. Payment of Wages Act.
d. Minimum wages Act, 1948.
e. Workmen’s Compensation Act.
f. Industrial Disputes Act. g. Bank’s Liability Act
The Contractor shall abide by and adhere to all labour laws, PF, ESIC, etc. The Contractor shall work only on and during
hours of working day unless he obtains prior approval of the Architect / Bank. The Contractor will observe and abide by the
rules and regulations of the public Authorities regarding overtime, night working and any particular rule regarding nuisance
to the residence that may result there from.
2. The works to be carried out under the contract shall, except as otherwise provided in theses conditions, include all labor,
supervision, materials, tools, tackles, plants, equipment, transport, lead/ lift of materials etc. as may be required for
execution and completion of the works.
3. The materials used for the work shall be of prescribed quality / standard and the work executed according to the prescribed specification. Materials and mix not being of the specified standard / specification shall be rejected at the cost
of the contractor.
4. After completion of work all accumulate debris, dirt etc shall be removed and disposed away from the BANK premises
by the contractor at his expense and no payment shall be done / made for that.
5. Doors, Windows, Staircases and passages shall be cleaned / washed by the contractor as part of the contract work
without any additional payment.
6. The debris shall be removed from the site every three days.
7. The contractor shall clean the site everyday before the closure of work.
8. No additional work is to be carried out by the contractor unless instructed by the BANK through Architect. The
contractor will have to carry out the item of work with prior permission from BANK and as per instruction from
Architect which may not have been specified in tender but necessary for completion of job.
9. Any extra item of work carried out other than specified in tender will be paid by the BANK as per the actual expenses
and 15% for overheads and profit certified by Architect.
INCOME TAX
14
1. The bidder shall indicate his Income Tax PAN/GIR Number.
2. Income Tax at applicable rates of the amount of each payment shall be deducted and deposited with the Government as
per Current Statutory provision if applicable. On completion of the work, a certificate for the Income Tax deducted at
source given to the contractor.
DOCUMENTS TO BE COMPLEMENTARY All sections of contract document and working drawings shall be complementary to each other. In case of ambiguities,
discrepancies or contradictions between any two sections. Bank / Architect’s decision shall be final and binding on the
contractor for interpretation of same.
COMPLETION PERIOD
Time is the essence of the contract and the contractor is required to complete the entire work to the satisfaction of the Bank in
6 Months from the date of work order.
PROGRAM WORK AND PROGRESS REPORTS The successful contractor will have to submit a detailed bar-Chart indicating the schedule of various activities from the date
of commencement till completion and get the same approved by Architect. Contractor shall strictly adhere to the same. This
program shall form part of contract and shall be binding on the contractor. However, the BANK reserves the right to alter the
Program, if necessary, from time to time, No claim whatsoever of any nature by the Contractor on this account shall be
entertained by BANK. They shall also have to write their requirements about co-ordination from other agencies working at
site.
WATER & ELECTRICITY REQUIREMENT
1. The Contractor will be permitted to draw and use water from BANK’s U/W Tank and O/W Tank. He will not claim any
compensation for late, intermittent and no supply of water. At the time of shortfall, the Contractor will arrange water
without any extra cost. The Contractor has to arrange ‘Sintex’ tanks of adequate capacity to store water and pumps and pipes for distribution of water from tanks to work place free of charge. The site for storage and distribution of water will
be decided by the owner / Bank.
2. The Contractor will be provided Electricity at one point by the BANK free of cost, only most convenient to the Bank. He
will also ensure that all safety measures are adhered to at his costs. The Contractor will not make any wastage of this
facility nor will claim any compensation for late or intermittent supply for electricity. Cost of power shall be born by the
BANK. Any accidents, mishaps, etc. due to fault and negligence of Contractor’s workmen, the Contractor will be
responsible and indemnifies and keep indemnified the members of the managing and repair committee and the BANK.
DELAY IN COMPLETION OF WORK
1. Liquidated damages per week will be 1% of the contract value inclusive of non-completion of work in time including
Sundays and holidays per week, subject to maximum of 10% of contract value. The Bank may without prejudice to any other mode of recovery deduct the amount of such damages from any moneys in his hands due or which may become
due to the Contractor. The payment or deduction of such damages shall not relieve the Contractor of his obligations and
liabilities of this contract.
2. If in the opinion of the Bank / Architect, the works gets delayed due to causes which the Bank may consider being
beyond the control of the contractor, the Bank at the completion of the time allowed for the contract shall make fair and
reasonable extension of time for completion in respect there of. For extension of time for completion, the contractor has
to apply in writing with detail reasons.
PAYMENT SCHEDULE
1. Total value of work is Rs. including transportation, loading, unloading, Octoi charges etc. and nothing extra will be paid on any account. In the event of variation in the Quantity / Area, the payment shall be made on the basis
of the actual Quantity / Area at the quoted Rate.
2. Bill in Triplicate duly Certified by Architect shall be submitted to Bank after satisfactory completion of the work.
Payments to the contractor shall be made within 15 days of submission of each “on account” bill. Bill submitted by the
contractor must contain item wise quantity of work done in a manner that verification of work done can be done. The
quantities for which the bills are submitted shall be subject to physical verification before payment.
3. In the event of variation in the Quantity / Area, the payment shall be made on the basis of the actual Quantity / Area at
the quoted Rate.
15
4. No interest will be given for late payments.
5. All payments to the Contractor shall be made subject to deduction of taxes at source at the rate applicable.
6. Final payment, except Security Deposit (which is to be released only after the defect liability period including observing
the performance of water proofing during the rainy season) shall be made within 30 days from the submission of the final
bill after verification of the completion of the work. No further claim except the security Deposit after the submission of
the FINAL BILL shall be accepted.
7. For final payment, the Contractor will submit details of all items, payments received for works and materials, any claim
and net balance due which Architect/ Bank will check, make any adjustments if any, will receive ‘No Claim’ from the
Contractor and pay and settle the same if any.
8. The Contractor will submit original certificate for payment of Works Contract Tax in respect of the Owner / Bank or else
the same will be deducted from his bills.
9. The decision of the Architect and repair committee for payment or for any extra work to be made or any deduction to be
made from the whole cost of the work or any other matter whatsoever relating to the contract shall be final and binding
to all parties.
10. The Contractor shall be liable to pay Rs. 500/- per day as penalty in the event of default for any reason whatsoever in the
removal of debris and / or materials and / or tools and / or plants and / or equipment within 7 days from the written
instructions given to contractor to do so till such removal takes place. The penalty imposed by the Society will be in
addition to the penalty mentioned above. The Bank may without prejudice to any other mode of recovery deduct the
amount of such damages from any moneys in his hands due or which may become due to the Contractor. The payment or
deduction of such damages shall not relieve the Contractor of his obligations and liabilities of this contract.
SUBLETTING
The selected contractor shall not sub-contract the work to any other individual, Agency or firm.
DEFECTS IN WORK
1. Any defects / deficiency pointed out by the BANK’s authorized person(s) shall be removed / rectified to his / their
satisfaction, otherwise payment for such items(s) shall not be passed till the defect/ discrepancy is removed / rectified by
the contractor.
2. The Architect shall have the power to withhold any certificate of work and/ or part thereof not being carried out to his
satisfaction and he can make the necessary corrections in previous certificate in any subsequent certificates.
3. In case the Contractors are disobeying Architect/ Bank, they may get bad work replaced in the manner the Architect think fit at the cost and consequences of the Contractor.
4. The Architect/ Bank shall have the right to alter, omit and abandon any part of work without invalidating the contract. If
any work is over and above that included into the Contract and is required to be executed at site, the Architect/ Bank has
power either to delegate this work to Contractor as an extra item or to any outside Contractor, as the case may be.
SECURITY OF WORKS / MATERIALS / STORES ETC OF THE CONTRACTOR AND BANK’S PROPERTY
1. The Contractor shall be responsible to make safety arrangements at his own cost for his materials / stores, storages, etc.
All such stores shall be cleared away and the ground left in good and proper order on completion of this contract unless
otherwise expressly mentioned therein.
2. All stores and materials brought to the site shall become and remain the property of the Bank and shall not remove from
the site without prior written approval of the Bank. When the work is finally completed or the contract is determined for
reason other than default of the Contractor, he shall forthwith remove the same from site.
3. All tools, plant and equipment brought to site by the Contractor shall not be removed from the site without prior written approval of the Bank. When the work is finally completed or the Contract is determined for reason other than default of
the Contractor, the Contractor with prior written permission of the Bank shall forthwith remove the same from site all
tools, plant and equipment.
16
4. For any damage / injury to the BANK’s property or to any member of the BANK or to the members property on account
of any unsafe practices adopted or by any un-prudential action by the Contractor or by his men, the contractor shall be
responsible. BANK reserves the right for recovering proper remedy / compensation for the same from the contractor.
5. Contractor should indemnify and keep indemnified the Bank against any legalities arising out of labour rules, local
authorities rules etc. during the execution of work and any losses and claims for injuries or damage to any person or any
property and should take third party insurance in the joint name of Bank and contractor.
6. The Contractor shall ensure protection to the owners, flat owners, occupiers of the Bank, other properties near site and to
the public in general. The approach is kept free at any time.
7. The contractor must take all measures and precautions to prevent death / injury to his own labors or any other person and
shall take THIRD PARTY (Public Liability) Insurance Policy in the joint name of BANK and contractor at his own
expenses. This will be comprehensive and all risks covered to safeguard all men, materials and property during and on
account of the execution of work under this contract and will submit certified copy to employee.
a. All Risk Policy with accidental cover to neighboring property due to work of contractor’s workmen.
b. Workmen’s Compensation Policy.
c. Automobile Third Party Insurance with unskilled third party liability of his vehicles or his suppliers or debris
removal vehicles, etc. damaging any cars, etc. while bringing, removing materials, etc.
8. The contractor shall, if required by Architect / bank, arrange to test materials and / or portion of the work at his own cost
in order to prove their soundness and efficiency. If after any such test, the material or portion of work is found, in the
opinion of the Architect and Bank to be defective or is found, in the opinion of the Architect and Bank to be defective or
unsound, the contractor shall pull down and re-erect the same at his own cost. Samples of materials and workmanship shall be submitted by the contractor for the approval of the Architect / bank before procurement and execution.
9. Contractor shall submit written performance guarantee from the manufactures of all bought out items.
10. The Contractor shall submit original copies of invoices, order forms for any materials purchased for project work, to the
Bank / Architect if called for.
CONTRACTOR’S SUPERVISION
1. The Contractor shall give and provide all necessary superintendence during the execution of work and as long after as
Architect / Bank may consider necessary for proper fulfilling of Contractor’s obligations under the contract. The
Contractor shall himself supervise the execution of contract and shall appoint a full time competent agent (site engineer /
supervisor) approved by the Architect / Bank to act on his behalf and to be present all throughout at site. The Contractor
shall further employ engineers and assistants to the above to supervise the work in sufficient numbers to the satisfaction
of Architect / Bank. These engineers must be completely authorized by the Contractor to represent him and to receive
and execute order and instructions by the Architect / Bank as if Contractor himself is present. The Contractor shall visit the site daily and shall have minimum once a week, or more as the case many be, joint meeting with the Architect &
Bank on a day fixed jointly by the Architect and the Bank.
2. The Contractor shall provide and employ on site in connection with the execution and maintenance of the works: a) Only such assistance’s as are skilled and experienced in their respective fields and qualified and such agents,
foreman and leading hands as are competent to give proper supervision to the work.
b) Such skilled, semi-skilled and unskilled labour as is necessary for the proper and timely execution and maintenance
of the work.
c) The contractor shall employ a whole time qualified and competent supervisor for the work, whose name shall be
notified and who shall interface with the BANK’s representative(s) for the ongoing contract work.
3. The Architect / Bank shall be at liberty to object any Contractor man / men, employed by him, for misconduct or is
incompetent or negligent in the proper performance of his duties or whose employment is otherwise considered by the
Architect / Bank to be undesirable to work within the premises of BANK. Any person so removed from the works shall
be replaced immediately by a competent substitute.
INSURANCE The contractor shall obtain adequate insurance cover at his own cost for work against any loss or damages as well as
workman compensation and third party risk, until the date of virtual completion of the work, The insurance cover shall be in
joint names of the owner and the contractor, is to be deposited with the owner within 7 (twenty one) days from the date of
issue of work order.
OCCUPATION OF PARTIALLY COMPLETED PORTION BY THE BANK
17
The Bank shall be entitled to and will be at liberty to occupy even the partially completed portion of the work by themselves
or through their agents and servants if they so desire. Necessary extension of time for completing the work shall have no
claim for any compensation whatsoever due to the delay, if any involved in completing the work on account of partial
occupation.
MOCK UP The Contractor shall prepare a mock-up of items, if required, strictly in accordance with the specification, free of cost, for
approval of Architect and Bank. The work on these items shall proceed further only after the approval of the mock-up.
UNSCHEDULED ITEMS OF WORK
1. Work should be carried out strictly as per the standard specifications given in Tender document and the directions of the
Engineer Workmanship / Work of substandard nature will not be accepted and paid for.
2. Any work carried out as per specifications and found defective in opinion of architect / consulting engineer shall be
demolished are replaced by new work by contractor to the satisfaction of architect / consulting engineer.
3. If change in any item or additional work is to be carried out while executing the job by the contractor will be executed with prior consent from the Bank and as per instruction from Architect which may not have been specified in tender but
necessary for completion of job.
4. In case of any dispute the decision of Bank will be final and binding on the contractor.
5. The Contractor shall comply with all acts and regulations for the successful completion of the contract works and shall
give due notice and pay all fees / taxes etc. as per statutory requirements.
6. No additional work is to be carried out by the contractor unless instructed by the Bank through Architect.
7. All materials to be delivered at site. If the material used for the work is not in conformity with the specifications, the same shall be replaced at your cost. All the material required for the above work shall be arranged by the contractor at
his own cost.
8. Selection of material to be done in consultation with the Bank’s representative / Engineer. The Contractor shall, if
required by Architect/Bank, arrange to test materials and / or portion of the work at his own cost in order to prove their
soundness and efficiency. If after any such test, the material or portion of work found, in the opinion of the Architect and
Bank to be defective or is found, in the opinion of the Architect and Bank to be defective or is found, in the opinion of the
Architect and Bank to be defective or unsound, the Contractor shall pull down and re-erect the same at his own cost.
Samples of materials and workmanship shall be submitted by the contractor for the Approval of the Architect / Bank
before procurement and execution.
9. Rules for varied/deviated or extra items to be worked out on the rates quoted in the Tender for the similar items. Wherever it is not possible to base the rates for varied/ deviated or extra items on Tender quoted rates then the rate
analysis is to be submitted by the contractor will include the actual cost of material, Taxes, Transportation if any,
Miscellaneous expenses, Labour, Wastage of materials, 15% towards contractors overheads and profit.
10. Bank will provide free Electricity and Water for the execution of work. However the Contractor shall make his own
arrangement to draw the power and water from source as decided by Bank.
11. While executing the work the contractors have to ensure that no inconvenience whatsoever is caused to the offices /
people staying/ residing/ functioning in the premises.
12. On completion of the work the contractor shall clear away and remove from the site all constructional plant, surplus materials, rubbish and temporary works of every kind and leave whole of the site and the works clean and in a workman
like condition to the satisfaction of client. No extra payment will be made for this purpose. After completion of work all
accumulated debris, dirt etc shall be removed and disposed away from the Bank premises by the contractor at his
expense. The Contractor shall take due care while disposing of such waste materials and ensure that any rules /
regulations laid down by Municipal Corporation or any other statutory body are not violated. The Contractor shall be
responsible and answerable to any complaint arising out of improper disposal of waste material.
13. Doors, Windows, Staircases and passages shall be cleaned / washed by the contractor as part of the contract work without
any additional payment. The contractor shall clean the site everyday before the closure of work.
18
14. Adequate number of fire extinguishers, first aid boxes, must be provided on the site by the contractor.
15. Any item work which is not specified in the schedule and which is not capable of assessment by sight (visual) inspection
and which becomes known only after the contract work has commenced, such as broken/ leaky pipes, cracks in walls,
seepage. Percolating through the walls, beams / pillars etc shall be, on joint inspection, by the BANK and Contractor, assessed for quantum and the rate decided on mutual consultation.
VARIATIONS
1. The Architect/ Bank shall make any variations of the form, quality or quantity of the works or of any part thereof that
may in their opinion be necessary and for that purpose or for any other reason it be necessary, the Contractor shall do any
of the following :
a] Increase / decrease/ omit any work
b] Change, character, quality, level, lines, position, dimensions etc.
c] Execute additional work of any kind as may be necessary for completion of the work.
2. And no such variation shall in any way vitiate or invalidate the contract but the extension of proportionate time limit, if
any, for all such variations shall be taken in to account.
3. The Contractor shall make no such variations without an order in writing by Architect / Bank.
CANCELLATION OF THE CONTRACT OR PART OR FULL ON CONTRACTOR’S DEFAULT:
If the Contractor shall at any time:
a) Become bankrupt or insolvent.
b) Make an arrangement without assignment in favour of his creditors or agree to carry out the contract under the
committee of Inspection of his creditors.
c) Being an individual / partner / company or corporation go in to liquidation.
d) Have action levied on his goods or property on the works.
e) Assign the contract or any part thereof otherwise than as provided in the general condition of the Contract.
f) Abandon the Contract.
g) Persistently disagree the instructions of the Architect / Bank and or contravene any provisions of the contract including general accepted principles of working.
h) Stopping the work under flimsy excuse with threatening attitude or showing discourtesy to members so the majority
members wish this.
In that case, the Bank may determine and terminate the contract after giving due notice and time to the Contractor. The Bank
shall be entitled after giving due notice in writing for removal of the Contractor from whole or any portion of work, without
avoiding the Contract or releasing the Contractor from any of his obligation or liabilities under the Contract and adopt any or
several of the following measures:
I. Rescind the Contract, in which case the security deposit of the Contractor shall stand forfeited to the Bank without
prejudice to Bank’s right to recover any amount from Contractor,
II. Carry out the work or any part thereof by employing other agency and required labour and materials and debiting on
Contractor’s account.
III. Measure up the work executed by the Contractor and to get the remaining work completed by another contractor at the risks and expenses of the Contractor. In the event of any several of the courses referred above being adopted.
IV. Upon non-completion of the work, upon use of sub standard quality, upon non co-operation, upon a deadlock on a
particular issue between the Owner/ Bank and the Contractor / Architect.
a. The contractor shall have no claim for compensation for any loss sustained by him by any reason for material
purchased by him, tools, machinery, labor to retain the same in further execution of the work for wear, tear and
destruction caused by his negligence.
b. The Bank shall be entitled to take possession of any materials, tools, machinery, equipment which was on site, as if
those are the property of Bank to carry out the balance work, In this case Contractor is not entitled for any
compensation for use and employment of the same.
ARBITRATION CLAUSE All disputes or differences of any kind whatsoever which shall at any time arise between the parties hereto touching of
concerning the work or the execution or maintenance thereof of this contract or the right touching of concerning the works or
the execution or maintenance thereof of this contract or the construction, remaining operation or effect thereof or to the rights
or liabilities of the parties or arising out of or in relation thereto whether during or after determination, foreclosure or Branch
of the Contract (other than those in respect of which the decision of any person is by the contract expressed to be final and
binding) shall after written notice by either party to the contract to the other of them and to the Appointing Authority who
shall be appointed for this purpose by the Bank, be referred for adjudication to a sole arbitrator to be appointed as hereinafter
provided.
19
For the purpose of appointing the sole Arbitrator referred to above, the Appointing Authority will send within thirty days of
receipt by him of the written notice aforesaid to the Contractor, a panel of three names of persons who shall be presently
unconnected with the organization for which the work is executed.
The contractor shall on receipt by him of the names as aforesaid, select any of the persons named to be appointed as a sole Arbitrator and communicate his name to the Appointing Authority within thirty days of receipt by him of the names. The
Appointing Authority shall thereupon without any delay appoint the said person as a sole Arbitrator, if the contractor fails to
communicate such selection as provided above within the period specified, the Appointing Authority shall make the selection
and appoint the selected person as the sole Arbitrator.
If the Appointing Authority fails to send to the Contractor the panel of three names as aforesaid within the period specified,
the Contractor shall send to the Appointing Authority a panel of three names of persons who shall all be unconnected with
either party. The Appointing Authority shall on receipt by him of the names as aforesaid selected any one of the persons
named and appoint him as the sole Arbitrator. If the appointing authority fails to select the person and appoint him as the sole
Arbitrator within thirty days of receipt by him of the panel and inform the contractor accordingly, the contractor shall be
entitled to appoint one of the persons from the panel as the sole Arbitrator and communicate his name to the Appointing
Authority.
If the Arbitrator so appointed is unable or unwilling to act or resigns his appointment or vacates his office due any reason
whatsoever another sole Arbitrator shall be appointed as aforesaid.
The work under the contract shall, however, continue during the arbitration proceeding and no payment due or payable to the
contractor shall be withheld on account of such proceedings.
The Arbitrator shall be deemed to have entered on the reference on the date he issues notice to both the parties fixing the date
of the first hearing.
The Arbitrator may from time to time, with the consent of the parties, enlarge the time for making and published the award.
The Arbitrator shall give a separate award in respect of each dispute or difference referred to him. The Arbitrator shall decide
each dispute in accordance with the terms of the contract and give a reasoned award. The venue of arbitration shall be such
place as may be fixed by the arbitrator in his sole discretion.
The fees, if any, of the arbitrator shall, if required to be paid before the award is made and published, be paid half and half by
each of the parties. The cost of the reference and of the award including the Fees, if any of the Arbitrator who may direct to
and by whom and in what manner such costs or any part thereof shall be paid and may fix or settle the amount of costs to be
so paid.
The award of the Arbitrator shall be final and binding on both the parties.
Subject to aforesaid, the Provisions of the Arbitration Act, 1996 or any statutory modification or re-enactment thereof and the
rules made there-under, and for the time being in force, shall apply to the arbitration proceeding under this clause.
I / We hereby declare that I/We have read and understood the above conditions for the guidance of Tenderers.
Seal : Signature of the Contractor
Place : Address :
20
SPECIAL CONDITIONS OF CONTRACTS
1. All materials, tools, plants and equipment to be used for construction, shall be brought and stored on BANK premises by
the Contractor in a manner directed in specifications for construction materials at his own cost and risk including his own
security arrangement without causing hindrance to occupants.
2. All due precautions shall be taken by the Contractor to prevent damage including that of window panes, as a result of
Contractor's action will have to be made good by the Contractor at his own expense.
3. a) All debris resulting from breaking work shall be carefully lowered on specially constructed platforms preferably in
specially provided chutes and suitable screens and hoppers shall be provided to ensure that as far as possible no debris
flies or rebounds from the building and / or scaffolding. Under no circumstances shall debris be thrown down on the ground or footpath.
b) The Contractor shall regularly remove all waste and debris from the site. Dumping of debris temporarily on the
premises shall be strictly in location allotted for the purpose and nowhere else. Every day after working hour’s sweepers
must clean the site.
4. The Contractor will provide at his own expense necessary sheds, passages, special covering, platforms to be constructed
in front of main entrance, BANK office, staff toilet, and also netting, kantans, etc. in area of common passage at the
work site.
5. Proper cordoning off shall be maintained at all times to ensure that no children or unauthorized persons enter the work area.
6. The Contractor shall bear in mind that he have to carry out part of work inside the premises of the occupants and he will
take extreme care not to damage inside Branch.
7. The contractor shall provide at his own cost necessary sanitary and drinking water facilities for his workers more about
in area of site only and they commit no nuisance.
8. When a contractor is selected, if Architect/ Bank find any anomaly in rates of some specific items, the Contractor shall
furnish explanation and rate analysis.
9. Rates quoted by the Contractor shall include all terminal taxes, octroi duties, central or state excise duties, import duties, sales tax and any other taxes leviable under the state or central government or public rules. No claim whatsoever shall be
entertained in respect of escalation in prices of materials, labour etc. except change in taxes announced by Municipal or
Government bodies subsequently. Rates quoted also include work Contract Tax. M.W. Tax, extra water charges, all
liaison work with Municipal Authorities for Building Department, Water Department, Pest Control etc. including
specific bills of water charges and sewage charges raised by BMC towards the repair works under taken including all out
of pocket expenses. The Contractor at his costs and expenses shall obtain all permission from BMC, etc.
10. The contract shall not be deemed to be duly completed until maintenance certificate have been issued by the Architect
recording that the works have been completed and maintained to his satisfaction and will be issued after defect liability
period is over and after ascertaining the views of the repair committee.
11. The Contractor is responsible for the execution of all works, which is more particularly set out as per terms and
conditions of the Agreement. The Contractor is well aware about the dangers and hazards for the completion of the said
work. It is the Contractor who would be responsible in the event of breakage of glass of windows, etc. of the BANK and
Contractor will take all precaution of BANK’s property so as not to damage them.
12. The Contractor shall, at his own expense supply all the stores and materials required for the contract. All the materials to
be supplied by the Contractor shall be of the best of kinds, and only of ISI standard. The Contractor shall furnish
necessary proof to the satisfaction of the Architect / Bank that the material complies with specifications as described in
the Technical specifications. The Contractor shall, at his own expense and without delay, supply samples of materials
proposed to be used in the execution of the work for the approval of the Architect / Bank, who may reject all materials
not corresponding either in quality or in character with the approved samples. The Contractor is made aware that there
will be no basic rate for all construction materials.
13. The Contractor shall not enter on or take possession of the site unless permitted to do so by the Bank. The portion of the
site to be occupied by the Contractor will be clearly defined and indicated by the Bank and the Contractor will on no
21
account be allowed to extend his operation beyond these areas. Then on completion, completely clean the areas of works
against his final completion of work done in that area.
14. The Contractor shall suspend the execution of the work of any part/s thereof, wherever called upon in writing by the
Bank / Architect to do so and shall not resume work thereon until so directed in writing by the authority. The Contractor shall also suspend the execution of work or any part thereof under notice of court, Government or Municipal Corporation
unless the Architect / Bank instructs otherwise in writing. The Contractor will be allowed an extension of time for
completion equal to period of suspension and no claim otherwise will be considered for payment. Time may also be
extended to allow for alterations of work or deviation from the contract if it is felt reasonable by Architect / Bank.
15. If Bank has permitted the contractor to house his workers on site in specified areas, during progress of work he will erect
temporary structures of the approved standards and scales for his workers and maintain at his own expenses. The
Contractor should demolish / remove temporary structures before the main work comes to an end and clear the site. This
facility is not incorporated in contract and will be exclusively at the discretion of the Bank and the Bank can stop this
facility in the middle of work and Contractor cannot claim anything whatsoever for taking away this facility any time. If
this facility is granted, he shall be responsible for giving all necessary notices of infection and contagious disease of his
workers and instantly remove such cases from site. The Contractor shall obtain all necessary permission from municipality, government, etc. at his own costs.
16. It is hereby clarified that within the guarantee period of the entire work the owner / Bank observes any hitches or lacunas
or damage caused to the flat and / or common area and / or the BANK’s property, the Architect / Contractor shall be
communicated regarding the same. The Architect / Bank would visit the premises and give their comments in respect of
the same. The rectification of the damaged area is the sole prerogative and responsibility of the Contractor who is to
rectify the said damage at his costs, etc. within the decided time frame as mutually decided between the parties. In the
event of failure of the Contractor to rectify such error the Bank / Owner shall have the full liberty to deduct the amount
of loss at cost from the balance amount due end payable to the Contractor.
17. The Contractor shall clean and level up the premises and open spaces in and around building to the satisfaction of the Bank at regular intervals and after completion of work. If he fails to their satisfaction, the same shall be carried out by
the owner at Contractor’s risk, cost and consequences and work will be treated as incomplete.
18. It is hereby clarified that the Employees / Workers who would be assigned the work and who would be temporarily
lodged in the premises of the owner shall have no access whatsoever in the building after the completion of the work for
the particular days. The workers shall not enter the building for the purpose of taking water or for any other Private jobs
that would be given by the flat owners during the subsistence of the work assigned.
22
TECHNICAL SPECIFICATIONS
CIVIL WORK
Specifications For Construction Materials
All materials consumed during course of construction shall be new, of approved quality, manufactured by renowned concern
confirming to relevant Indian Standard Specifications or equivalent, otherwise the same should be approved by Architect before using the same. The Contractor shall furnish manufacturer’s Certificate when asked for. The Contractor shall also get
tested the materials at his own cost when asked for. The Architect can reject any material either not confirming to
specifications or deterioration in the same. The contractor shall keep the register on site for receipt and consumption of
materials.
Cement
The cement shall be ordinary portland 43 grade and or 53 grade as required of approved quality i.e. L & T or other equivalent
brand approved by the BANK. It should be delivered at site in sealed bags marked with manufacturer’s name and trade
brand.
The bags shall be stored in suitable watertight shed clear of walls by 12’’ and on 6’’ raised dry floor. Each consignment shall
be stacked separately so that older stocks to use early.
Cement deteriorated in quality or otherwise shall not be used under any circumstances and shall be removed from site
forthwith. ‘Warehouse Set’ which takes place when cement is stored in high stacks should not be reason of rejection.
Clogged bags of cement when dropped on-solid floor shall reduce lumps to powder. Such hardening shall be treated as
‘Warehouse Set’ and the Architect shall decide the same.
Sand
Only river sand free from silt, dust, vegetable clay, alkali or any organic matter or other deteriorating substance and shall be
clean, sharp, hard, grainy, strong and durable. Before use of this sand for any item of construction, washing of this sand is
compulsory so that silt content is less than 4%. ( IS 383) .
Metal
Coarse aggregates shall be inert, cubical in shape, free from softness, flaky, porous particles, stone or other dust and confirm
to IS 383 and IS 515.
R.C.C. Bars
Only torque m.s. steel bars free from rust from reputed manufacturers to use.
Epoxy, Antirust, Polymer And Other Waterproofing Compounds
Manufactured by renowned manufacturers to be used as per direction of manufacturer. Admixture shall be used only after the
approval of Engineer-in-charge, who shall be furnished with all the required literature pertaining to its efficiency. The
admixture shall meet the requirement of IS 456 and IS 9103.
CARPENTARY AND FINISHING WORK
Joinery in Timber :-
All joints shall be standard mortise and tenon, dowel, dovetail and cross halved. Screws, nails etc. will be of standard iron or
wire of oxidized nettle fold, tenons should fit the mortises exactly. Where screws show on a finished surface, those will be
sunk and the hole plugged with a wood plug of the same wood and grain of the finished surfaces will be neatly punched and
hole filled with woodfiller to match the colour. The contact surface of dowel, tenons wedges etc. shall be glued with an
approved adhesive.
Timber
All woods should be properly seasoned of natural growth and free from worm holes, loose or dead knots or other defects and shall not suffer warping, splitting or other defects. The moisture contents shall not exceed 12% All wood brought to site
should be clean. All internal framework shall be treated with approved wood preservative.
Plywood
Plywood should be used after applying white anti termite liquid. Nails or screws fixed in the plywood should be equally
spaced. The plywood sides wherever they are visible should be covered withy the beading patti.
23
Too many joints in furniture pieces will not be considered. Rough finished sides while fitting the fixtures like locks, hinges
etc. will not be considered.
The contractor will have to make punctures of cutouts as required by electrical or any other contractor, for which no separate
payment will be made by the Bank or by the respective contractor. All contractors will work in team of good spirit and in good faith.
Certain details shall be modified as per the site adjustments.
Laminate
The laminate should be used to approved make and shade and of 1.5 mm thickness only. No scratches or patches on
laminates shall be considered.
Hardware and Metals
The hardware throughout shall be of approved manufacturer. The fitting generally shall be of brass or oxidised brass unless
otherwise specified. The screw should match the finish of the article to be fixed and to be round or flat headed or counter
sunk as required.
Glass
All glasses should be of approved manufacturer and free from bubbles, smoke, air-holes and other such defects. While
cutting glass, proper allowance be made for expansion. All cracked, scratched and broken pane should be replaced.
ELECTRICAL WORK
Power Panels:
The Power panels shall be fabricated from MS sheet steel 16 gauge and shall be of compartmental design. The main
supporting framework shall be of angle iron or of heavier gauge sheet metal. The panel shall be self-supporting design, dust
and vermin proof, dead front and fully inter locked with isolating switches. The panel-mounted switches shall have Interlock defeat for testing and inspection.
The panel shall be designed so as to facilitate inspection, cleaning and repairs. The clearance between phase to phase and
phase to earth or metal parts shall be as per relevant IS standards. The metering instruments like volt meter, ammeter etc.
shall be flush mounted and shall be of 1.0 class accuracy and of standard design size shall be 96 mm x 96. All indication
lamps shall be of neon type.
The panel shall have separate cable ally and a bus bar chamber. The bus bars shall be rigid hard drawn tinned electrolytic
copper & sleeved with heat shrinkable sleeves. The current density shall not exceed 1.25 amp per sq. mm. and the neutral bus
shall be rated for capacity of phase bus unless otherwise stated in schedule of quantities/drawings. However, the minimum
size of bars shall be 25mm x 3mm.
The panel shall be powder coated comprising of degreasing and de-scaling in sulphuric acid etc. with synthetic enamel paint
for smooth finish. The color of paint shall be battle-ship Grey or as directed. The Panel shall be tested at site before
commissioning. The Panel drawings shall be got first approved from Consultants before taking up for fabrication. All wiring inside the panel shall be done with switchboard copper conductors/cables soild copper links. The insulators for
supporting the Bus-Bars shall be epoxy based cast resin. All hinged doors shall be earthed with flexible braided copper earth.
An earth bus of copper shall be fixed along the length of the panel at the lower section. Adequate ventilation for the panel
shall be provided. Logic diagram of operation of switches shall be painted on the panel. The name plates for each feeders
shall be of engraved design and pasted to the respective switch gear. The letters shall not be less than 10mm size for
individual feeders and not less than 18mm for the main feeders. All switchgear to be mounted in the panel shall be as per
schedule of quantities.
Switch Fuse Units :
Switch Fuse Units shall be of sheet metal or iron clad with HRC fuses as described in schedule of quantities. The unit shall be
of robust construction of standard specified make. design to withstand adverse working conditions. It shall have quick break
type mechanism with ON and OFF position indicators of the operating handle. The switch shall be interlocked so that the unit cannot be opened in ON condition. The interior shall be so arranged that clearance from live parts are adequate and shrouded.
Manufacture’s instructions shall be followed for installation of switch fuse units. The switch shall be solidly earthed. The
switch shall be mounted on walls on angle iron support grouted to wall. The supports shall be treated for rust treatment &
painted with 2 coats of synthetic enamel paint. The height of the switch board shall be such that it is accessible for operation
& maintenance.
Cables :
Cables shall confirm to IS 1554-1976. Cable shall be heavy duty, armoured, PVC insulated & PVC sheathed 1.1 MV grade
aluminum or copper. Cable shall be fixed with G.I. spacers & saddles at an interval of 45 cms and on every side of bends.
The bending radii of cables shall be as per manufacturers instructions and in no case it shall be less than 12 times the overall
diameter of the cable. Cable shall be so installed that they are not subject to mechanical damage. If there is a bend in the
24
cable enclosed in a conduit, care has to be taken to prevent undue compression of insulation. This applies also to the top of
vertical runs of longer than 5 meters where there could be compression caused by the weight of unsupported vertical cables.
Cables may rest without fixing in horizontal runs or ducts or trunkings. The cables run in cable trays shall be permitted unless
the cables exceed the standard drum length. Joints if so necessary shall be located in accessible position. Termination of the
cables shall be done with heavy duty copper/Aluminum lugs and brass cable glands. Cables laid under ground shall be to a minimum depth of 750 mm. It shall be ensured that cables laid underground are free of
water lines, sewage lines etc. The trenches shall be at least 30 cm wide & filled with 10 cms thick of layer of dry sand on
which the cable shall be laid. Further, 10 cms thick sand layershall be put on the cable over which a brick layer shall be kept.
The trench shall than be back filled with soft earth, rammed and consolidated to original level. Cable route indicators shall be
laid at intervals of 20 metres and at all change in directions. For cables laid on walls aluminum tags shall be fixed showing
the size of the cable and the feeder number of the cable. These tags shall be at each ends and at least one or two places at
intermediate positions. The mode of measurement of the cables shall be as follows :
i. For top entry of the cable, the measurement shall be taken up to the bottom of the switch-gear.
ii. For bottom entry of the cable, the measurement shall be taken up to the top of that switch board. No wastage shall be
allowed for measurements.
Distribution Boards :
1. These shall be of sheet metal and of standard design with copper bus bars. The board shall be fixed at accessible heights. The boards shall be solidly fixed to walls/partitions, concealed of open as directed. All connections inside the
distribution board shall be neatly arranged and tied with PVC strings. The MCB’s shall be of 9 KA for fault level. The
distribution board shall be suitably earthed. Legend shall be written on D.B. & Circuits.
2. The Distribution Board circuitry shall be as per the schematic/given in Drawing.
3. The Sheet steel used for fabrication shall be of CRCA of 14/16 SWG. The Board shall be suitable for wall mounting. It
shall be totally enclosed, Dust Proof & vermin proof. The fabrication shall be as per relevant is Specifications for degree
of protection by enclosure for low voltage switch-gear IP 52. The Equipment such as MCB, ELCB, Insulators, Bus-Bars
shall be as per relevant is specification with latest amendments.
4. The Sheet steel shall be smoothly finished, leveled and free from flaws. All doors, removable covers shall be Gasketed
all round the perimeter.
5. The Service Voltage is 440 volts & Busbar will be Electrolytic copper. The copper busbar shall be tinned through out the length.
6. The door interlock shall be provided so that it shall not be possible to open the door with breaker in close position.
7. Enough space shall be provided for termination. The minimum two earth terminals shall be provided for each D. B. The
Board shall be factory wired with proper ferruling.
8. Adequate shrouds shall be provided for avoiding accidental contact with Live Terminals, Busbar etc.
9. The Conduit knockout shall be provided for Conduit Entry.
10. The guaranteed technical particulars shall be provided for the MCB & ELCB etc.
11. The engraved black anodised labels shall be provided on all feeders.
12. All Steel works shall undergo a process of degreasing, pickling in acid bath, phosphating.
13. This shall be followed by two coats of primer and two coats of final finish paint, both applied with spray. The colour
shall be light battleship gray.
14. The distribution board shall have hinged door. 15. The busbar supports shall be non hygroscopic, anti tracking material.
Point Wiring
(a) Metal Conduits:
1. All conduit pipes shall confirm to IS 9537 PART-II 1981. Metal conduits shall be ERW black enameled 20mm/25mm as
the case may be depending upon the number of wires permitted. The conduits shall be fixed to walls/ceiling with M.S.
saddles and spacers at an interval of 1 meter and on either side of bends.
2. All conduit accessories shall be 15 gauge & bends shall be of inspection type. All bends, couplers, threaded portions etc.
shall be painted with anti-corrosive paint. Bends in the pipes shall be done with bending hickeys.
3. All pipes shall be cleaned for sharp burrs. Switch boxes shall be of G.I. 16 G/14G. The switch boxes shall be concealed
as per site requirement & as per Architect’s/Consultant’s Instructions. Point shall be controlled with 5A switch or directly from DB as specified in schedule of quantities. Where plate type switches are not specified the switch-board
shall have 3mm thick hylum sheet on which switches shall be mounted.
4. While laying the conduits in the slab before casting the slab, all drops shall be laid accurately to fall in position of the
switchboard. Junction boxes shall be sand filled. All joints shall be airtight. Conduits shall be fastened to the re-
enforcement properly so that the conduits do not get dislocated while casting the slab. All conduits shall have 18 swg
fish wire.
5. The conduit shall be of 16 guage unto 32mm dia and 14 guage above 32mm dia. reputed and approved make conforming
is specification.Conduit shall be Heavy guage rigid PVC with All accessories/fittings including ordinary & inspection
tees; bushings, reducers, junction boxes, terminal boxes, saddles and steel supporting materials shall be of the same as of
the conduit. The contractor shall have dies for threading of conduit.
25
6. The conduit shall run along walls, ceiling, flooring in accordance with layout drawings.
7. The conduit shall be field bend as far as possible with reasonable long radius. The conduit bends shall be free from
cracks, other damage to the pipe or its coating and shall not have pipe section unduly flatten..
8. The conduit joint shall provide the structural rigidity and low electrical resistance.
9. All open conduit ends shall have bushings and all threads shall be cleaned and well painted with coating or red lead & oil. All burrs shall be smoothened and cleaned.
10. The conduit shall be supported with saddles at regular interval of 1000mm. The saddles shall be fixed with Rawal plugs
and M. S. screws of 3mm size.
11. The No. of wires through a given diameter of conduit shall be as per is specification.
12. When two length of conduit are joined together through a coupling, running threads equal to the full length of the
coupling shall be provided on any one length. Conduit length exceeding 8 meter length shall be provided with junction
boxes.
13. Conduit & accessories shall be securely fixed before any operation like concrete pouring plastering etc. The conduit shall
be fixed by clips which shall not cause deformation of conduits. The conduit fixing shall be at regular intervals not
exceeding 1.5 meter. At the bends the fixing shall be secured by fixing clips at 150mm. All the supporting holes are to be
drilled by electric drill machine.
(b) Pvc Conduits:
The PVC Conduits shall confirm to latest IS standards and shall be of medium gauge. The conduits shall be joined with PVC
adhesive at joints. The Conduits shall be fixed to walls/ceilings with GI, Spaces and Saddles at an interval of 60 cms & on
either side of bends. The number of wires drawn in the conduits shall be as per table 1. The point wiring shall be controlled as
in (a) above. The wiring shall be done with 2nos. of 1.5 sq.mm (Phase & Neutral). & 2.5 sq. mm. (earth) PVC insulated,
copper conductors, multi stranded and color coded with green as earth and black neutral. The circuit wiring shall be with 3
nos. of 2.5 sq. mm. PVC insulated, copper conductors, multi stranded from distribution board to switch board and the rate
shall be included in the point wiring unless otherwise stated in schedule of quantities. All other details shall be as for metal
conduits.
(c) Casing Capping/Trunk And Trunkling : PVC casing shall be fixed, wooden partitions by means of screws spaced not more than 60 cms apart. Holes for fixing the
PVC capping shall be done by drilling machine only and these holes shall be plugged with PVC plugs or grips to which the
screws shall be fastened. No less than I inch PVC casing shall be used. All bends, tees, joints etc. shall be done in workman
like manner with standard accessories. The number of wires in PVC casing capping shall be limited to a fill factor of not
more than 60%. The point shall be controlled by 5 amp switch. The switch boards shall either be flush mounted with
partitions or surface mounted or concealed mounted as per site requirements and as directed. The wiring shall be carried out
as described in (a) and (b) above.
This wiring shall not be done for concealed wiring & wiring over the false ceiling work.
Circuit Wiring
1. The Circuit wiring shall comprise of laying PVC conduit from lighting distribution board to the first switch board & pulling of wires within the conduits with 2.5 Sq.mm copper wire, PVC insulated, 100v grade wire.
2. The scope includes all materials & labour with Installation. It also includes making proper connection in the Distribution
board & switch board.
3. In case of group control directly from Distribution Board, the primary point shall be from D.B. to the first point and
secondary point and from first point to the next point looped. The point shall terminate into the 3 plate-ceiling rose.
Switch Board
The lighting switch board boxes shall be MS/ zinc passivated with 16 guage made suitably for controlling group of
light/fixture or light control as indicated in the drawing. The switch board boxes shall be suitably in the office area as
concealed type. All the switch boxes shall be provide with removable cover with proper provision of Plate/Piano type
switches.
Wiring Methods
1. The wire pulling in conduits shall be in accordance with standard practices. All the wires in a particular section by
conduit shall be bunched together and pulled at a time.
2. The wires used shall be colour coded with Red wires for R phase, Yellow wire for Y phase, Blue wire for B phase Black
wire for neutral and Green wire for each continuity conductor.
3. All the wires shall be purchased directly form the manufacturers and approved by the consultant.
4. All the wire shall be insulated with adequate thickness of extruded PVC.
5. All wires shall be of 1100v grade conforming to is 694 with latest amendment.
6. All the wire ends shall be ferruled with colour codes & numbers.
26
7. All the circuits shall be identified at both ends of the circuit.
8. A maximum of 3 lights to be switched on one switch of 5A.
9. The wiring shall be carried out with multi stranded PVC insulated copper wires of 1.5 sq. mm. 2Nos (Phase & Neutral)
& 2.5 sq.mm. (Earth). In all cases the earth shall be of green color and neutral shall be black color. All wires used shall
be of 660 V grade. The point wiring shall be inclusive of circuit wiring from Distribution Board to the switch-board unless otherwise stated in schedule of quantities. The circuit wiring shall be with 3 nos. of 2.5 sq.mm PVC insulated
multi stranded copper conductors color coded as detailed above. The rate shall also be inclusive of any chasing as
directed by the Architects/Consultant/Client’s Engineer to conceal the drops and finishing the same.
5a/15 Amps. Switch Socket Outlet Wiring
1. The Point wiring for 15 A Switch socket outlet includes running of 3 x 4.0 sq.mm PVC insulated stranded copper wire
through conduit from the distribution panel board to the individual S/S/O
2. Two nos of 15 A S/S/O are to be looped in and controlled by MCB of 20 Amps in the distribution board at each floor.
The circuit length shall not exceed a length of 70 meters.
3. All the wires for the S/S/O shall be pulled through separate conduit system (not to be mixed with light 5 Amps S/S/O
etc.)
5 Amps Switch Socket Outlet
1. The point wiring for 5 Amps switch socket outlet includes running of 3 x 2.5 sq.mm copper conductor, PVC insulated,
1100v grade wires in PVC conduit from the light distribution board to the Individual socket.
2. A maximum of 6/8 Nos. socket are to be looped in & controlled by MCB in the lighting distribution board. The circuit
length shall not exceed 75 meters.
15/5 A Switch Socket Outlet
1. It shall be of approved make conforming to latest is standards. The three-pin socket shall be provided with safety shutter
to prevent accidental contact with live parts.
2. The box for socket outlet shall be suitable for concealed/surface mounting and should be supplied by the Manufacturer
with the switch & socket unit.
20 Amps Point Wiring
1. The 20 A SP MCB with Reyrolle socket is to be provided including running of 3 x 4.0 sq.mm PVC insulated stranded
copper wire through PVC conduit from distribution board to the individual switch.
2. One switch is to be provided in one circuit and controlled by one MCB of 20 Amp in the distribution board at each floor.
3. All the wires for the switches shall be pulled through separate conduit system ( not to be mixed light, 5 A S/S/O etc.)
Telephone Points
1. Telephone Points shall include supply & installation of 25mm diameter PVC conduit & Accessories along with 2 pair/4
Core wire from Tag Block to Individual Point along with the Conduit. The Telephone wire shall be of oelton make or of
approved sample.
2. The Conduit shall be laid concealed in slab/wall/beam column etc., from the Telephone Box to the Individual Telephone socket outlet Point as market in the Drawing.
3. In case of provision for further point for Telephone G.I. Pull wires shall be laid inside the entire length of conduit.
4. The Telephone Tag Block of M.S. shall also be provided by the Contractor including latest Type of Terminal strip cover
extra as per MTNL approved list.
Earh Pits / Station
The earthing station shall be done as per IS 3043 (1981) and as per drawing no. E1. The earth pit shall be atleast 2.5 mtrs
deep with GI plate electrode shall be hot dipped of 600mm x 600mm x 6mm thick. The size for copper electrode shall be
600 x 600 x 3mm thk. An alternate layer of salt and charcoal shall be filled up to 200 mm above the top of the
electrode.The electrode shall be connected with 25mm x 6 mm thick GI Flat which shall be terminated with nuts and bolts
into brick masonry chamber on top. The brick masonry chamber shall be of size 300mm x 300mm x 300mm deep which will carrythe finneling arrangement for watering. A GI Flat of 25mm x 3 mm from brick masonry chamber to the
switch gear inside the switch room shall be laid under ground and / or fixed to walls and the rate for this shall be paid as a
separate item.
Installation Of Electric Fittings
All electrical fittings shall be fixed with down rods or on round blocks as stated in schedule of quantities. The down rods
shall be 20 mm dia and 1.6 mm wall thickness of ERW black enameled MS. The down rods shall be fixed with ball and
socket joints check nuts etc. Special fixtures like spot lights etc. shall be fixed to the false ceilings as per manufacturer’s
recommendations. The fittings shall be connected with 3 core 0.5 sq. mm. flexible copper cord / cable from ceiling rose and
suitable earthed.
27
Testing Of Electrical Insulation
The following tests shall be carried out after completion of the electrical insulation work.
1) Insulation Resistance Test.
2) Polarity Test of Switches. 3) Earth Continuity Test.
1) Insulation Resistance Test : The insulation resistance shall be measured by applying between earth and whole system of
conductors or any section thereof with all fuses in place and all switches closed (except in earthed concentric wiring) all
lamps in position and both poles electrically connected together., or direct current pressure of not less than twice the
working pressure, provided that it need not exceed 500 volts for medium voltage circuits, be applied. Where the supply is
derived from 3 wire DC or Poly phase A.C. System, the neutral pole of which is connected to the earth either direct or
through added resistance, the working pressure shall be deemed to be that which is maintained between the phase
conductor and the neutral. The insulation resistance measured in mega ohms between all conductors connected to one pole of
phase conductor of the supply and all the other conductor and switches in off position it’s value shall be not less than as
specified below:
The insulation resistance measured in mega ohms shall not be less than 50 mega ohms divided by the number of outlets or
when PVC insulated cables are used for wiring , 12.5 mega ohms divided by the outlet subject to a minimum value of 1
mega ohm.
A preliminary and similar test may be made before lamps etc. are installed and in this event the insulation resistance to earth
shall not be less than 100 mega ohms divided by the number of outlets or when PVC insulated cables are used 25 mega ohms
divided by the number of outlets subject to a minimum of 1 mega ohm.
2) Polarity Test of Switches : In a 2 wire system a test shall be made to verify that all switches in every circuit are fitted
in the same conductor through out and such conductors shall be labelled or marked for connection to the phase conductor
or to the non earthed conductor of supply.
In a 3 wire or 4 wire insulation a test shall be made to verify that every non linked single pole switch is fitted in a conductor
which is labelled or marked to one of the phase conductor of supply.
3) Earth Continuity Test : The Earth Continuity Conductor including metal conduits and metallic envelopes of cables
in all cases shall be tested for electric continuity and electrical resistance of the same along with the earthing lead but
excluding any added resistance or earth leakage circuit breaker measured from connection with earth electrode to any
point in the earth continuity conductor in the completed insulated shall not exceed 1 ohm.
28
PUNJAB & SIND BANK MUMBAI ZONAL OFFICE
PROPOSED RENOVATION OF OFFICER QUARTERS (Vasant Parijat, Vasant Kadamba, Vasant Chinar, Vasant Ashoka, Vasant Mandar, Vasant
Gulmohor, Vasant Kusumba- Thane)
(Civil, Painting, Electric)
(Price Bid) (Volume-2)
TENDER DOCUMENTS
NAME OF THE CONTRACTOR :
ADDRESS :
DATE OF SUBMISSION : On or Before July 20, 2019 upto 1.00 p.m.
LIST OF APPROVED MANUFACTURES / SUPPLIERS OF MATERIALS MATERIALS APPROVED MANUFACTURERS / SUPPLIERS 1. Plywood - Marine : Century, Green, Anchor
- Commercial : Century, Green, Anchor
2. Soft & Accoustic Boards : Jolly Boards (Insulex), Sitapur Boards (Sitatex) Phenol
3. Veneer (Natural) 4mm Thk. : Anchor, Kitply, India Plywood Mfg. Co.
4. Hard Board : Jolly Boards (Insulex), Sitapur Boards(Sitatex), Anchor
5. Door Closer : Everite, Tahilsons
6. P.V.C. Tiles : Karara 7. Synthetic Enamel Paint : ICI, Asian
8. Plastic Emulsion Paint : ICI, Asian
9. Dry Distemper & Oil Bound Distemper Paint : British Paints, Goodless Nerolac, Garware
10. Red Oxide Primer Paint : Asian, Bombay Paint, Mercury Paints Goodless Nerolac
11. Wood Preservatives : British Paits, Goodless Nerolac
12. Flush Doors : Sitaboards, Anchor
13. Metal Sliding Channel : El-Binari
14. Drawer & Cabinet Lock : Godrej
15. Laminate : Formica, Greenlam, Decolam, Merino
16. Screws : G.K.W., Nettle Fold.
17. Hardware : Shalimar, Cief, Vision.
18. Adhesive : Fevicol-Sh, Mafatlal’s Movicol-Hv Ciba-Geigy’s Araldite 19. Water Proofing Compound : Roffe / Impermo / Accoproof/ Algiproof / Sunanda
20. Glazing : Triveni/Modifloat
21. Polyurathene Foam : U-Foam
22. Rubber Foam : Mm Rubber Foam
23. Pest Control : Pest Control & Anti-Termite Treatment For Interior Work
To Be Done By Local Renowned Contractor.
24. Venetian Blinds : Vista, Mac, Luxaflux & Arolux
25. Aluminium Sections : Jindal, Indal
26. Structural Steels : Tata Steel
27. Cement : Ordinary Portland Cement Of Larsen & Turbo, Ambuja, A.C.C.
Century Cement 28. Reinforcement/ Structural Steel : Sail / Tisco / Torsteel
29. White Cement : J. K. Cement Or Birla White
30. Sand Fine Aggregates Coarse Aggregates,
31. Bricks, Stone Slab And Murrum Filling, Lime : Locally Available Material Duly Tested.
32. Tiles : Kajaria, Johnson, Bell, Nitco
33. Hardeners : Ironite / Ferok / Hardonate
34. Redoxide : Shalimar / Eomite / Blundel / Asian / Jenson & Nicholson
35. Cement Paint : Snowcem / Colourcem / Sandex
36. Cast Iron Fittings : Nicco
37. GI Pipies : Gujrat, Ambika, Zenith
38. P.V.C. Pipes : Prince
39. SFU/ Isolator switch : EE/L&T/Siemens 40. L.T. Panels : EE/L&T/ Siemens / As approved
41. Meters : AE/MECO/ Rishab/ Silkon/ UE
42. DB (HRC Fuse ) : EE/Standard/ CPL/ Havel
43. DB (MCB) : EE/MDS/ Siemens
44. Wires : Finolex / Polycab
45. Conduits (MS/GI) : Superme BEC/ Precision / Circle Ark
46. Switches /Sockets : Anchor/ Preeision/ CPL/ MK/Northwest/ Avanti/ LK pace
47. Lugs : Dowell/Jainson
48. Telephone cables : Finloex/ Delton/ MTNL approved
49. Decorative lights (spot lights/ picture lights) : Phillip / Wipro
50. Fire detectors : Appolo Honry well 51. Security system : Shellain / Radioncis sentrol
52. ELCB/RCCB : EE/MDS/ Datar
53. Telephone Tag-block : Krone
54. NCCBS : L&T/EE/Crompton
55. Air Circuit Breaker : L&T Siemens /EE
56. Changeover Switches : Siemens / Blcon/ Kayee
57. Contractors : Siemens /L&T
30
58. Muisc speakers : Phillips/ Ahuja
59. Amplifers : Phillips /Ahuja
60. Elec. Fittings & fixtures : Phillips /Crompton/ Wipro
61. PL/ Spot Lights fittings : Phillips /K-lite/ Wipro
62. Copper Cable (Conductor) : Polycab / CCI ISI Mark 63. Flourscent Lights, PL Lights and Lamps etc. : Phillips/Crompton/ Bajaj
64. MCB/ ELCB : MDS/ DATAR
65. Main switcher (sheet metal boxing) : L&T
66. Ceiling Fan : Crompton/ Usha, Bajaj, Orient
67. Wall fan : Usha /Almonard
68. Exhaust fan : Unique
69. Gland Flange Type : BRACO
70. Casing Caping Patti : PRESTO PLAST
All materials to be delivered at site. If the material used for the work is not in conformity with the specifications, the
same shall be replaced by contractor. All the material required for the above work shall be arranged by the contractor at
his own cost. Selection of material to be done in consultation with the BANK representative / Engineer.
All materials shall be of the first quality.
Wherever Contractor proposes to use ‘equivalent’ makes (i.e. other than specified) the same shall be done only after
prior approval from BANK. BANK may consult Architect before giving approval. Any additional expenditure, time due
to this will be on Contractor’s account and no claims will be entertained.
Read “or equivalent approved” at the end of the list of approved manufacture / sub-contractor / brand for every
materials.
31
PREAMBLE TO BOQ Abbreviations:
R.M.T. : Running Meter Sq. MT. : Square Meter
Sq. Ft. : Square Foot
Cu. Mt. : Cubic Meter
T.W. : Teak Wood
Q.R.O : Quote Rate Only
C / C : Centre to Centre
M.T. : Metric Ton
C.P. : Chrome Plated
NO. : Numbers.
MM. : Millimeter
1. All dimensions are in M.K.S. unless otherwise stated. 2. The quoted rate shall be all inclusive and cover the cost of material including wastage, Freight, all types of taxes,
duties, royalties, erection, construction, testing of materials, if required samples brought for approval, tools and
tackles, plant and equipment’s, supervision, overheads, profit and any other expenditure incurred for completion
of work as per drawings, specifications and to the full satisfaction of BANK / Architect.
3. The rates quoted shall be valid for working at all heights, depths, and on all floor levels, No extra payment shall be
made for scaffolding, staging, ladders etc. for transportation of men and materials at higher or lower levels.
4. The item rate specifications are indicative. The Contractor will have to carry out the work in accordance with the
drawings, technical specifications and / or other conditions laid down in tender document and to the full satisfaction of
BANK / Architect.
5. Quantities mentioned against respective items are approximate and can vary to any extent. Payment shall be made on
actually executed quantities.
6. No claims shall be entertained in case of increase or decrease in quantities, BANK / Architect reserve the right to increase / decrease quantities of any item and also to add / Delete any item in totality. BANK / Architect reserve right of
operating any item for any work.
7. Rates of all items shall remain constant irrespective of floor level and no extra shall be Paid for handling and
stacking of materials, removing debris etc. from the site.
8. Unless otherwise noted, the method of measurement will be as per I.S. 1200.
9. Wherever contractor proposes to use ‘equivalent’ makes (i.e. other than specified) he shall obtain BANK’s prior
approval. BANK may ask Architect before giving approval to the same. Any additional cost and time lost due to this
will be on Contractor’s account and no claims will be entertained.
10. The rate for partition, paneling shall include necessary additional framework supports that may be required to suit site
conditions or stability of the item. Decision of Architect in regards to the need for such additional supports shall be final.
11. All wooden frame work / member size mentioned as out of, shall be full size with maximum planing tolerance of 3 mm both ways.
12. Rates for doors include all brass oxidized heavy duty hardware, locks, floor springs, door Springs, door closer, special
door handles etc. as specified in relative items.
13. Size and type of door closer / floor spring shall be suitable for type of door. The Contractor shall give guarantee for
performance of door closer / floor spring from manufacturer.
14. Rates for partitions, paneling shall include making of necessary cut outs, chasing to be Made for conduits, switch boards
etc.
15. Rates for painting and polishing shall include cleaning glass panels, fans, floor etc.
16. After completion of work the site shall be handed over absolutely clean, after ensuring that all laminates, floors, walls,
etc. are spotless clean.
17. Contractor shall clean the site and mark the lining out on the floor with adhesive tape for approval. The same shall not
be paid separately. 18. In case of loose furniture, the specification for side unit or rear side credenza unit in any Item shall be same as the
specification of the table in that item.
19. All key holes should be fixed with metallic key hole ring.
20. Key for all locks should be different and no key should match with two different locks.
PROPOSED REPAIRS AT OFFICERS QUARTERS AT
Vasant Parijat, Vasant Kadamba, Vasant Chinar, Vasant Ashoka, Vasant Mandar, Vasant Gulmohor,
Vasant Kusumba- Thane FOR PUNJAB & SIND BANK
No. Description Quantity Rate Amount
CIVIL WORK INTERNAL PLASTER
1 Providing Cement plaster 20 mm thick (1 of cement and 3 of fine sand) in 2 coats to concrete or brick surface including breaking the existing internal plaster at hollow /cracked locations or as directed by Engineer at all heights on beams, columns, pardies, RC walls, brick walls, ceiling etc. cleaning all the surface of spoils, raking brick joints. Disposal of debris out of site. A groove to be cut at beam & wall, column & wall junction before applying first coat, Groove coated with polyalk WP for bonding and waterproof purpose without neeru finish in all positions including scaffolding, Mixing Mortar, Pattas, Drip moulds, Corners, Grooves, curing, removing existing plaster with neeru of any thickness without causing dust nuisance etc. complete as specified.
1580 Sq.ft.
POLYMER MODIFIED CEMENT MORTAR
2 Removing carefully existing damaged, loose & disintegrated concrete of RCC columns, beams, slabs, parapets, chajja soffits etc. at all heights, levels & surface of any thickness/depth. Remove loose rust from reinforcement bars by mechanical means like wire brushing, chipping, hammering etc. provide & apply two coats of anticorrosive coating of perma (Zinc base) to the rusted exposed steel reinforcement bars on all sides. If the reinforcement steel is found to have corroded more than 20% of the actual size additional reinforcement along the old one to be attached by welding/tying with 18 gauge binding wire as per direction.(Cost of steel reinforcement to be paid under separate item) After 24 hours of applying anticorrosive coat, apply two rust passivating coat mixing the same with cement in the ratio of 1:1(by weight) to the derusted as well as new steel surface by brush at an interval of six hours. Moisten the surface and apply bonding coat in the ratio of 1:1 by weight to the entire broken concrete surfaces.
200 Sq.ft
Providing & hand pack polymer modified mortar within 10 to 15 minutes of applying bonding coat . i.e. (wet on wet) as per following specifications using: 1 part by weight of Polymer. 5 parts by weight of cement. 15 parts by weight of well graded quartz sand. At the time apply layer not more than 20 mm thick. The mortar should be prepared using mechanical mixers/stirrers should be well compacted & finished using appropriate methods. The rate quoted should be for avg. Thickness of 40 mm polymer modified mortar to be applied for necessary curing, compaction with mechanical plate vibrator & as per technical specification no: iii etc. complete.
VITRIFIED TILE FLOORING
3 Providing and fixing VITRIFIED tile 24”X24” of approved make and shade for flooring laid on bed of 1:4 cement mortar in proper level including neat cement float (but filling joints with neat white cement slurry), removing carefully existing flooring, Thick neat cement slurry / paste shall be applied to the back of tiles before laying, The bedding material shall be spread fully and evenly to avoid air pockets and carting away debris, curing, cleaning etc. complete
9095 Sq.ft.
VITRIFIED TILE SKIRTING
4 Providing & fixing VITRIFIED tiles to Skirting 4" high including bedding mortar in C.M. 1:3 with joints grouted and pointed with white and colored cement including curing and cleaning, removing carefully existing skirting, bedding and stacking the tiles carefully as directed and carting away debris etc. complete.
2395 R.ft.
POLISHING TO FLOORING
5 Polishing to existing any type of flooring including cleaning etc. complete. 395 Sq.ft.
33
WATERPROOFING OF TOILET
6 Removing the existing water proofing layer in w.c/bath toilet area up to existing slab level including carting away of debris, grouting and then applying two coats of cement slurry with polymer based compound in the proportion (1:1) is to be applied with one coat horizontal & other coat vertical at the junction adjoining to wall 1 feet, with care that all crevices, cracks and unevenness is properly treated, curing for 24 hours should be carried out. Prior laying of cement sand mortar, cement slurry shall be applied at top surface. Brickbats shall be laid in cement mortar (1:4) in all positions with an average thickness of 100 mm ( 2.5 layers only for w.c) is to be provided. Brickbats should immediately be hand set in to fresh mortar, leaving a gap of half to one inch between each piece, taking care to provide the necessary slope. This brickbat layer should be cured for at 4 days. The joints in between the brickbats shall be first filled with cement slurry and immediately covered with a layer of cement mortar (1:3) so as to fill up gaps between the brickbats
790 Sq.ft.
and also from a 25 mm thick layer over the brickbat surface with I.P.S Rough Finished including 'P' trap/'S' trap etc. complete to the entire satisfaction.
CERAMIC TILE FLOORING
7 Providing and fixing 12”X12” ceramic tile of approved make and shade for flooring laid on bed of 1:4 cement mortar in proper level including neat cement float (but filling joints with neat white cement slurry), removing carefully existing flooring, Thick neat cement slurry / paste shall be applied to the back of tiles before laying, The bedding material shall be spread fully and evenly to avoid air pockets. and carting away debris, curing, cleaning etc. complete. (Basic Rate Rs. 50/- per Sq.ft.)
790 Sq.ft.
CERAMIC TILE DADO
8 Providing and fixing ceramic tile 12"X8" for dado of approved make and shade for wall on 1:4 cement mortar in proper level including single coat base coat plaster, neat cement float (but filling joints with neat white cement slurry), removing carefully existing dado/plaster and carting away debris, curing, cleaning etc. complete. (Basic Rate Rs. 50/- per Sq.ft.)
8195 Sq.ft.
MARBLE PATTA
9 Providing and fixing Marble cill to door/window with cement mortar including cement float, cement pointing in mortar 1:3 including curing filling the joints with Polymer Putty and cleaning etc. complete. (Basic Rate Rs. 70/- per Sq.ft.)
a. 3" wide 660 R.ft.
b. 6" wide 660 R.ft.
c. 12" wide 365 R.ft.
ALUMINIUM WINDOW
10 Providing and fixing powder coated Aluminium sliding window \ louvered windows between kaddappah sill, lining and soffit with standard sections of 16 gauge and 18 mm series with outer frame and shutter, frames fixed with holdfast or fixing with wooden plug or with fixing clips etc. complete as directed by Architect and as per the Architectural drawing including 6 mm thick clear glass of Modiguard / FGIL. Aluminium sections shall be smooth, rust free, straight, mitred and jointed mechanically wherever required etc. complete including removing existing wooden window and stacking as directed.
a. Sliding window 223 Sq.ft.
b. Louvered window 220 Sq.ft.
KITCHEN PLATFORM
11 Providing & making 2'3" wide and 2'8" high Kitchen Platform including S. S. Sink with kadappah slabs for verticals, top, shelves, S. S. sink etc. finished with Black Granite on top and facia including moulding, polishing etc. complete.
69 R.ft.
34
M.S. GRILLS
12 Providing, fabricating and fixing M.S. Grills of required pattern with M.S. flats, square or round bars with round headed bolts and nuts or by screws including painting of approved shade, to all steel members including fixing etc. complete. (Weight of grill 15 kg per sqm.)
600 Sq.ft.
JET SPRAY
13 Providing and fixing in position C.P. brass hand jet spray along with C.P. brass angle stop cock, necessary length of flexible pipe, C.P. wall bracket for hanging the spray etc. complete.
24 Nos.
WASH BASIN
14 Providing and fixing white vitreous china wash basin with C.I. brackets painted white, 15 mm C.P. brass pillar taps C.P. Brass china with rubber plug 32 mm C.P. brass waste of standard pattern, C.P. bottle trap of required size with waste pipe including connecting C.I. pipes of required diameter & approved make with ISI mark to external plumbing with necessary fitting such as nhani trap, bends, tees, etc. including jointing with cement mortar 1:1, making holes in wall, filling the same from both sides, testing and removing existing pipes of any material and any diameters, taking out the existing fittings from walls & floor, dismantling joints, stacking & sorting the pipes, scaffoldings etc. complete. Size 580 x 430 mm.
41 Nos.
TOWEL RING
15 Providing and fixing in position Towel ring with C.P. brackets fixed to wall on wooden plugs with C.P. brass screws etc complete
41 Nos.
TOWEL RAIL
16 Providing and fixing C.P. brass towel rail 740mm length, 20mm dia with c.p brackets, fixed to wooden cleats with c.p. brass screws including cost of materials, labor complete as per specifications.
24 Nos.
MIRROR
17 Supply & installation of 6mm thk. Clear glass Mirror of approved make on toilet wall including 12mm thk. Plywood backing with necessary framework and moulding. The exposed framework to be polished etc. complete
41 Nos.
SOAP DISH
18 Supplying and fixing Recessed Type White soap dish of approved shape and size fixed into wall with CM 1:3 etc complete.Hindustan - CAT NO 40052 or equivalent approved make
41 Nos.
EUROPEAN TYPE W. C.
19 Providing and fixing wall hanging white vitreous European type water closet with seat cover of approved make including connecting C.I. pipes of required diameter & approved make with ISI mark to external plumbing with necessary fitting such as traps, bends, tees, etc. including jointing with cement mortar 1:1, making holes in wall, filling the same from both sides, testing and removing existing pipes of any material and any diameters, taking out the existing fittings from walls & floor, dismantling joints, stacking & sorting the pipes, scaffoldings etc. complete
24 Nos.
REMOVING & REFIXING EUROPEAN TYPE W. C.
20 Removing & refixing European Type W. C. including bracket etc. complete. 2 Nos.
FLUSHING CISTERN
21 Providing and fixing flushing cistern of approved make including connecting pipes of required diameter & approved make with with necessary fitting such as bends, etc. including jointing, making holes in wall, filling the same from both sides, testing and removing existing pipes of any material and any diameters, taking out the existing fittings from walls & floor, dismantling joints, stacking & sorting the pipes, scaffoldings etc. complete.
24 Nos.
35
G. I. WATERSUPPLY LINE
22 Providing and laying in position water-supply line arrangement in toilet, W.C., Kitchen, servents room as per drawing with 15 mm dia C class Galvanized Iron OR CPVC pipes of necessary diameter, of approved make, of ISI mark for toilets, water purifier, water cooler & loft tank with C.P. brass bib cock, C.P. stop cock, C. P. brass angle cock, brass full way valve, non return valve, screw socket, joints and necessary galvanized iron/ CPVC fittings such as sockets, back nuts, elbows, bends, tees, reducers, enlargers, plugs, nipple, union, bushing, cuppling etc. including rapping with gunning cloth with bitumen or in PVC pipes etc. and applying two coats of oil paint / black Japan, pressure testing, necessary excavation and back filling in trenches or including necessary zari, drilling holes in wall / slabs etc. and remaking good the demolished position to restore the same in original condition neatly including necessary scaffolding and removing existing pipes and conveying and stacking the same on site or as directed.
1105 R.ft.
RECTIFICATION OF NAHANI
23 Rectification of nahani by removing the flooring of any kind, nahani trap and fixing nahani trap with cement concrete M-15 and laying flooring of any kind and making the nahani portion water tight finished the junction of walls and flooring in cement vata by using waterproofing compound of approved quality including connecting C.I. pipes of required diameter & approved make with ISI mark to external plumbing with necessary fitting such as bends, tees, etc. including jointing with cement mortar 1:1, making holes in wall, filling the same from both sides, testing and removing existing pipes of any material and any diameters etc. complete as directed.
17 Nos.
PLUMBING WORK
24 Providing and making plumbing arrangement as per drawing with C.I./ PVC pipes, necessary traps of required diameter & approved make with ISI mark for toilet, W.C., Kitchen, servents room with necessary fitting such as nhani trap, bends, tees, single junction, double slotted vent offsets, etc. including clamping, jointing with cement mortar 1:1, making holes in wall, making connection to individual toilets and filling the same from both sides, patchwork plastering, testing and removing existing pipes of any material and any diameters, removing clamps and taking out the existing fittings from walls, dismantling joints, stacking & sorting the pipes, scaffoldings etc. complete.
41 Nos.
FITTINGS & FIXTURES IN TOILET
25 Providing & fixing fittings & fixtures including removing existing fittings & depositing to bank.
a Two in one Bib Cock 24 Nos.
b Angle Cock 2 Nos.
c Stop Cock 2 Nos.
d Shower 24 Nos.
e Hot & Cold water mixure 24 Nos. OIL BOUND DISTEMPER
26 Providing and applying Oil Bound Distemper paint of Asian Paints / ICI Dulux/Berger in minimum 2 coats including scrapping, opening of existing cracks, filling up of “V” cracks with epoxy expandable putty to required depth wherever required. Item to include Plaster of Paris, primer, palti and making good existing surface to receive new paint including cleaning on completion of painting work etc. complete in all respects.
39530 Sq.ft.
SYNTHETIC ENAMEL PAINT
27 Providing & supplying all materials and application of one coat of primer paint, two coats synthetic enamel paint of approved colour and manufacturer at various elevations including preparation of surface, scaffolding etc. complete including all materials as per specifications and directions of Architects. Three coats of paint including base coat or redoxide primer for steel, cast iron etc; to give an even shade.
4935 Sq.ft.
36
REPAIRS TO MAIN ENTRANCE DOOR
28 Repairs To Main Entrance Door including fixing 4 mm thk ply on both side, new fittings & fixtures, 1mm thk laminate on both sides, synthetic enamel paint on edges including cutting wooden door frame if required with finishing and painting etc. complete.
4 No.
FRP FINISHED DOOR
29 Providing & fixing 35mm thick FRP finished shutter, FRP thickness shall be 2 mm thick with polyol foams with a recess for hinges, the shutter to be fixed to frames with 3 nos. 100 mm long aluminium hinges and all fittings and fixtures complete as per drawings and directions. The colour of shutters shall be as per instructions. The shutters shall be totally water proofed, resistant to mild acid/ chemicals.
41 Nos.
REPAIRS TO BED ROOM DOOR
30 Repairs To Bed/ Balcony Door including fixing 4 mm thk ply on both side, new fittings & fixtures, 1mm thk laminate on both sides, synthetic enamel paint on edges including cutting wooden door frame if required with finishing and painting etc. complete.
6 Nos.
WOODEN FRAME
31 Removing/ cutting damaged wooden door frame and replacing with the matching wooden member including fixing to wwall etc. complete.
20 R.ft.
SHUTTERS TO KITCHEN PLATFORM
32 Providing & making shutters to Kitchen Platform with 18 mm tk plywood finished with laminate form outside and synthetic enamel paint from inside including necessary fittings and fixtures as directed etc. complete.
713 R.ft.
WINDOW GLASS PANES
33 Providing & fixing 5 mm thk. Bazari glass window panes wherever broken with wooden beading patti etc. complete.
100 Sq.ft
WINDOW REPAIRS
34 Providing & fixing shutters with wooden member of size 4" x 1 1/2 " for styles, middle rail, top rail & bottom rails including 5 mm thick Glass of approved make to be fixed to existing frame with 3 Nos. brass hinges, handle, etc. complete.
223 Sq.ft
NEW WOODEN DOOR
35 Providing and fixing 40 mm thick flush door shutters, non- decorative type, core of block board construction without frame finished with 1 mm laminate of approved shade and make on outside and painting from inside and also fixing leaping with second class teak wood battens 25 mm thick on all edges of shutters including all fixtures and fittings such as brass butt hinges, handles, sliding bolts, tower bolts and eye hole, letter patti, aldrop, tadi, etc. complete as directed.
2 Nos.
FITTINGS & FIXTURES
36 Providing & fixing fittings & fixtures including removing existing fittings & depositing to bank.
a Godrej Night Latch 2 Nos.
b 10” C.P. Brass Tower Bolt 2 Nos.
c Brass Aldrop 2 Nos.
d C.P. Brass Tadi 2 Nos.
e Safety Chain to main door 2 Nos.
f Eye hole 2 Nos.
g Letter box plate 2 Nos.
h Stopper 2 Nos.
i Handle Type Mortise Lock 2 Nos.
j Handle to door 2 Nos.
k Tower bolt to door 2 Nos.
l Decorative Curtain Rod 446 R.ft.
37
37 ELECTRIC WORK I MAIN LT PANEL /DBs
1 S & I of SPN, DB for distribution of input power to switch boards having below mentioned switchgears (Earth bar inside these DB should be insulated from the body)
1 no,40A, DP, Isolator incomer
3 Nos. 40A, DP, MCB, outgoing
Full Set as above 17 SET II WIRING
Supply & Installation of concealed point wiring using 600V grade 2.5 sqmm copper conductor PVC insulated wires (with proper R,Y,B color code ) pulled through heavy gauge PVC conduits laid concealed in ceiling or in wall chases including circuit wires from the relevant swith board and switch board to DB and also including 1.5 Sq.mm Green Colour Copper earth wire and provision of grid plate type ( ROMA) switches and sockets as approved by Bank / Architect. Each circuit feeding not more than 8 points / 800 W as per the following configuration.
1 Primary light points including the cost of 5A switch 479 Pts.
2 5A plug point as primary point 116 Pts.
3 Secondary 5A Plug point on switch board 97 Pts.
4 15A Plug Point directly taken from DB for A.C./geyser / fridge 95 Pts.
5 Bell Point 17 Pts.
6 Regulators 41 Pts.
7 Exhaust fan point consisting of 5A socket near fan and switch on light switch board
58 Pts.
III LIGHT FITTING & FANS
S & I of lighting fixtures as per the details given below including necessary hardware such as clamps,nuts, bolts, nails, screws and suspension chains as required for fixing the fixtures in position as directed by architect / Consultant.
1 4'0" long LED patti 75 Nos.
2 2'0" long LED patti 41 Nos.
3 Supply, Installation, Testing & Commissioning of 150mm dia wall mounted exhaust fan of decorative plastic body and blade with louvers on the outside with all accessories. The rate shall include connection with 3 core 1.5 sq.mm. flexible copper cable from point to the exhaust fan. (Newtek/Cromton/Approved Equivalent)
41 Nos.
4 Supply, Installation, Testing & Commissioning of 250mm dia wall mounted exhaust fan of decorative plastic body and blade with louvers on the outside with all accessories. The rate shall include connection with 3 core 1.5 sq.mm. flexible copper cable from point to the exhaust fan. (Newtek/Cromton/Approved Equivalent)
17 Nos.
5 Providing and fiing Instant Electric Water Heater RACOLD PRONTO NEO 3V-3KW including connectors etc. complete.
41 Nos.
6 Supply, Installation, Testing & Commissioning of 48” ceiling type fans 230V Single phase, electronic fan regulator, S type hook, with all accessories. The rate shall include connection with 3 core 1.5 sq.mm. flexible copper cable from point to the ceiling fan.
41 Nos.
7 Providing & fixing cable for TV 41 Nos.
8 Providing & fixing cable for Internet 16 Nos.
TOTAL Rs.
Add 18% GST Rs.
GRAND TOTAL Rs. NOTE : The above quantities are approximately taken for estimation purpose they may increase or decrease. Contractor will be paid for actual work executes against each item. Brief specifications are given for each item. Minor verification in design and specification for each item are likely for which no extra payment will be given. Any of these items may be cancelled.
NOTE :- Cost inclusive of all taxesother than GST, Transportation, loading, unloading expenses, Excise Duty etc. without any extra charge. The Contractor estimate shall also include MCGM/Local Authorities Permission for smooth functioning the work.