time extension: how to request a time extension how to request a time extension
TRANSCRIPT
Time Extension: How to Request a Time Extension How to Request a Time Extension
By Juan Rodriguez
Construction Expert
Cultura RM/Seb Oliver/Collection Mix: Subjects/Getty Images
Contract time extensionsare based on the ability to demonstrate that delays have
occurred in the construction schedule affecting project completion date. All time
extension should be bases on delays beyond the Contractor’s control, many of them as
part of change orderrequests. Time extension requests are normally specified in
contract’s provision and requesting time extensions should be made following all steps
and documentation under the contract guideline.
Time Extension: The Reasons
Time extension requests are normally claimed due to the following circumstances:
1. Legal issues are affecting the project’s completion or the contractor’s performance
2. Long lead items, requested by owner, have not been received
3. The Owner asks for a delayed start
4. New or Extra Work not included in the original scope or contract
5. Unusual or adverse weather conditions
6. Encountering sub-surface conditions differing from the plans
It is also important to highlight that time extensions will be denied by the following
reasons:
When the delays claim are caused by subcontractors
When there is insufficient or inadequate workforce
Underperforming by the contractor, specifically procuring long lead items
When the project is affected by normal weather delays
Time Extension: The Process
When requesting a time extension certain steps must be followed, otherwise the time
extension might not be approved. Normally, the Contractor should notify the Project
Manager, when any issue might affect the project schedule.
A formal letter must be addressed to the Contract Administrator requesting the time
extension and the reasons why those days should be added to the construction
schedule. The Contract Administrator should then, remit the letter to the Project
Manager for evaluation and approval or rejection. If the time extension is granted, then
the Project Manager must answer by written and a change order will be issued. Some
contracts specify that time extension requests should be done within a specific
time frame, if not; the time extension claim will also be rejected.
Time Extension: Documents
The time extension when properly presented must contain the following supporting
documents:
Indicate specific issue causing delays
List of activities from project schedule being affected by the aforementioned issue
Exact amount of time being requested specifying working days or calendar days
Sketches, photographs, or pictures
Recommendations being given to Contract Administrator
Indicate the actions the contractor has taken to avoid or minimize other delays
Alternative solutions presented to Contract Administrator
Time Extension: Important Notes
Time extension request should also consider the following:
Calendar days are not the same as working days
Insurances and other bonds will need to be re-issued to cover extend periods
Winter days are shorter or less productive than summer days
Be sure that the time extension requested is enough to cover all delays including additional
items that might be affected
Be sure to understand the changes being proposed and the ramifications of those changes
No additional time will be granted for the same item once it has been approved
In the case of a continuing delay only one claim is necessary
Time Extension: Sample Letter
The Contractor,
Contractor Address
Contract Name
Contract Number
Extension of time
I refer to your extension of time claim dated (insert date of the Claim).In accordance
with clause (insert the contract clause) of the General Conditions of Contract, the
Principal grants extension/s of time of:
Number of days requested and reasons for the time extension.
The Contractual Completion Date (as previously extended) was (insert contract
completion date including previous time extension approvals). This extension of
(number of days) days makes (insert new completion date) the Contractual
Completion Date
Signed by an Authorized Person
Common Causes for a Change Order
Construction change orders can affect adversely a construction project. By Rutlo
Most common causes for a change order can vary from one project to another, but still they are
additions that need to be quantified in terms of time and money. Change orders, sometimes are
a headache when the complexity and time frame of the requested job are tight. Change order
management is another different process than regular contract documents, and most common
causes for change orders can lead to legal battles, disputes and arbitration.
Drawings Errors and/or Omissions
The most claimed situation for allowing change orders. Inadequate details,
misrepresentation o simply avoidance to prepare a complete set of detailed drawings can lead
to serious change order requests. Sometimes leaving out details andmisrepresenting the
exact environment in which the construction will be held at, can also lead to change order
claims.
Design Changes
Several outer factors can lead us to start a construction project without a completescope of the
project and start the construction without final drawings. This type of error is also common on
design-buildprojects, where the on-going process of design can induce to work stoppage or
produce economic impact in the project.
Specifications
Sometime the drawing asks for one product but the specs calls for another. This situation is very
common on construction projects where the drawings are assigned to different consultants,
each one of them acting on their own, without any kind of direction from a team leader.
This leaves the contractor with the difficult task of assuming and quoting on one article, but
when the installation is going to be made, the owner, requires another article to be installed,
instead of the one that you have already quoted.
Unforeseen Conditions
How many times do you have to complete a soil boring? Soil problems, in particular, are the
most common problems with unforeseen conditions. Soil studies can induce you to expect
some condition based on specific testing. This could be wrong. Your assumptions on the soil
conditions or any other issue regarding the construction of the project can be different from the
actual conditions that you find on the site. Also, if the drawings specify a certain amount of
work, when, in fact, the amount of materials is almost double, and then a change order must be
issued.
Substitutions
This is normally a contractor’s idea to substitute material, when he cannot get the specified
materials or there is a shortage in supplies. This is kind of different because it can lead to
another issue: a credit will be asked if the material cost is less, or sometimes the contractor will
have to absorb the costs’ difference between materials and/or products. Sometimes, the Owner
also asks for some upgrades during the construction process, in this case you must submit a
change order request claiming the economic and time costs associated with the proposed
modifications.
The 8 Things to Know About Change Orders Understand How Remodeling and Construction Change Orders Can Benefit You
By Lee Wallender
Home Renovations Expert
It's no fun dealing with contracts when doing home remodeling or home construction. Most
homeowners just want the thing done--minimizing the paperwork as much as possible.
One inevitable aspect of contracts: change orders. Find out how change orders work within the
purview of home remodeling and construction.
What are change orders?
You and the contractor draw up an initial contract to do some work, likely things like new
home building, putting on an addition, installing a pool, and so on.
Because it is inevitable that changes may occur during the course of the project, change
orders allow the contract to accommodate these changes.
Who requests the changes orders--contractor or homeowner?
Both parties can and do request change orders. Kia Ricchi, in Avoiding the Con in
Construction, states,
"Since change orders typically increase the project cost, they are the curse of every
homeowner. Most change orders result from:
Errors and omissions in contracted work
Work arising from unknown conditions.
Owner-requested additional work."
What specific examples might spur a change order?
The most common event that initiates a change order is when the homeowner decides to
add an element to the project: more windows, better windows, different flooring, higher
ceiling, better-grade appliances, etc. Every change in the contract, even the smallest
change, must be documented in the form of a change order.
Why not just strike out and add language into the original contract instead
of making a change order?
This is a practice that homeowners are accustomed to when purchasing or selling a
property--tweaking a price, condition, or other single data point.
Change orders for remodeling and construction are different because so many data points
are involved.
What kind of information is found in a change order?
Change orders are documents that contain a significant amount of information that cannot
be conveyed via hand-written notes to the contract. For instance, the change order will
contain the date of the original contract; date of the change order; original cost; value of
change; cost after change; and much more. Most importantly, change orders give specifics
about exactly what will be done with the change. The change order will need to be signed
by both you and the contractor.
Is there a form for the change order?
There is no universally-accepted change order form, but the contractor will have a change
order form of her/his own. It is rarely more than one page long, and at the very least will
contain the information stated above.
How can I avoid change orders?
As Kia Ricchi mentioned, it would be very rare to encounter a change order that results in a
lower contract value. Thus, it is imperative to avoid change orders as much as possible--
even if you are the one initiating the changes. Ms. Ricchi advises homeowners to
"...develop a concise, correct, complete, and clear scope of work so that the building plans,
proposals, and contract provide for all the necessary work."
Critical Path Method Scheduling
Schedule sample. Courtesy of jwalker64
Critical Path Methodscheduling was developed in 1957, to address challenges on complex
projects. Being one of the most usedscheduling techniques in the construction industry,the
Critical Path Method is a useful toolthat can lead you to achieve your project results.
The Critical Path Method schedule shall include all work specified in the Contract Documents,
including all expected activities of subcontractors, vendors, suppliers and all other parties
associated with construction of the project.
A critical path method will provide you with a graphical view of the project, will provide you the
time required to complete an activity and determine the activities that will become critical to
the project if not completed within the specified time.
Understanding a Critical Path Method (CPM)
A critical path method (CPM) is a network of events, each one of them linked to the
following activities. Each activity is represented as a node on the network, and connecting
lines are drawn to represent the time schedule to complete that activity. A critical path
method schedule must be completed using the following steps:
1. Identify the activities
2. Determine the sequence of the activities
3. Connect or create a network of the activities
4. Enter the completion time for every activity listed on step 1
5. Identify the critical path or the longest possible path to complete all activities
6. One important and valuable component is the CPM update progress, allowing to track closely the
performance and time used to complete the activities
Identify the Activities
A complete list of activities needed to complete the project must be made. This list can be
prepared from the work breakdown structure or the project scope and details. This will be the
key to later add sequence and duration in subsequent steps. Activities shall be identified by
a name, stationing, and coding, and have a duration.
Determine the Sequence of the Activities
This is one key factor of a critical path method (CPM). A complete and thorough
understanding of the sequence of the activities are needed to prepare and connect the list
of activities prepared in the previous step.Linking activities must be analyzed and
connected properly to achieve the expected result, failing to do so can lead to mistakes
and miss-representation of the project activities, leading to a false time frame or erroneous
project completion date. If one crew is being used to perform similar activities, these
activities must be linked together.
Creating the Network
When all activities have been defined and interdependence of activities has been analyzed,
it is required to create the network of activities. It is of vital importance that all critical work
sequence has been linked withlogical coordination and planning requirements. TheCPM
format shall be based on calendar daysas their main planning unit. Working days should
be avoided when planning or preparing a critical path method schedule.
Estimate Activity Completion Time
Using previous experience, time estimates can be presented, and shall represent the
necessary time to complete the activity for a single resource unit. It is one of the most
important steps when preparing a CPM, because it will help you determine the time needed
or available to perform an activity.
Identify the Critical Path
The critical path is the longest-duration path through the network.What does this mean?
Activities located on this path cannot be delayed without delaying the project. Because of its
impact on the entire project, critical path analysis is an important aspect of project planning.
The critical path can be identified using these parameters:
ES – Early Start: earliest time to start a predetermined activity, given that prior activities must be completed
first
EF – Early Finish: earliest finish time for the activity
LF - Late Finish: latest time the activity must be completed without delaying the entire project
LS – Late Start: latest start date that the activity must be started without delaying the project
The critical path is the path through the project network in which none of the activities have been delayed,
that is, the path for which ES=LS and EF=LF for all activities in the path. A delay in the critical path
delays the project.
Update CPM Diagram
As the project is being developed, a critical path method can be updated. Analyzing a new
critical path may be possible, when entering all the duration times of activities already
completed. A new path might be found and alternative solutions can be presented to
either accelerate the project or continue working as projected. Sometimes it is also
necessary to incorporate changes and extra works that were not part of the original critical path.
What Is a Gantt Chart? Learn to prepare a Gantt Chart
By Juan Rodriguez
Construction Expert
ngkaki/E+/Getty Images
What is a Gantt Chart?
A Gantt chart is a bar chart used to illustrate a project schedule, including start and finish dates
of activities and a summary of activities of a project. These activities form what is usually called
thework breakdown structureof a specific construction project. Gantt charts serve as an
excellent tool to show updated schedule status using actual complete shadings and vertical line
representing the actual date.
Gantt charts sometimes are prepared showing precedence activities and following activities and
their relationships.
Gantt Chart Advantages
Using a Gantt chart offers the following advantages:
Gantt charts can be used to represent phases and activities of a project so they can be understood by
general audience.
It can be useful to indicate the critical points on the chart with bold or colored outlines of the bars.
An updated Gantt chart helps manage the project and head off schedule problems.
Computer software can simplify constructing and updating a Gantt chart.
Drawbacks of Gantt Charts
Gantt charts can also have some setbacks:
A Gantt charts is not recommended to define the work breakdown structure and the schedule activities at
the same time.
It has some limitations for large projects, or projects having more than 30 activities.
Gantt charts are not useful if they are intended to display information.
Gantt charts do not represent the complexity of a project.
Horizontal bars of Gantt charts misrepresent the actual resource requirements of a project.
Ads
Online Project Management
projectmanager.com
Try Project Management Software. For Free!
Gantt chart with percent-complete shading may actually miscommunicate the true schedule
performance status.
Gantt Charts: When to Use It
Gantt charts have a variety of uses among construction professionals. Gantt charts must be
used under the following circumstances:
To communicate plan or status of a construction project.
To monitor tasks within a project.
To express the sequence and duration of specific tasks or process from a construction project,
To demonstrate which tasks depend on completion of previous tasks.
Gantt Chart Basic Procedure
The basic procedure must be followed to build a Gantt chart.
1. Identify the steps or activities needed to complete the project.
2. Identify milestones within the project.
3. Identify the expected time required to complete each task.
4. Identify the sequence of tasks and the order of precedence of tasks.
5. Draw a horizontal time axis on the bottom of a page.
6. Select a proper time scale to represent the length of tasks.
7. Prepare a column on the left side of the paper; write down each activity and milestoneof the project in
their corresponding order of occurrence.
8. Activities or milestones that occur at a specific point in time represent them using a diamond under the time
the activity must happen.
9. Activities that occur over a determined period of time draw horizontal bars, or an empty rectangle starting
from the first day the activity will take place and finishing the day the activity ends. Do not fill inside the
rectangle.
10. Each activity or tasks must be listed in the Gantt chart.
11. Fill up the diamond or the rectangle as each activity is being performed.
12. Use a weight or plumb as vertical marker to illustrate that actual time and progress of the project.
Gantt Chart Considerations
Gantt charts are also modified with additional columns showing details such as the amount of
time estimated to perform each task, how many resources are needed to complete each activity
and/or the person responsible to execute the activity. Specific meetings or reviewing processes
are not recommended to be listed on a Gantt chart because they might occur over a long period
of time. Gantt chart will transmit a clear idea to construction professionals about what must be
done to complete a specific task and can promote a healthy scheduling process.
Contract Documents Construction Contract Must Have Items
By Juan Rodriguez
Construction Expert
The contract documents are one of the most important pieces that will guarantee of a successful
project. This list contains the most common documents that must form part of every
construction contract.
In addition to this list, there are other numerous contract support documents that can be used in
combination with the standards documents. For example:
Instruction Forms
Time Extension Claim
Request for Information
Preliminary Building Agreement
Progress Payment Certificate
Practical Completion Notice
Defects Document
Contract Information Statement
Contract Document.
1. Agreement
The agreement to be used by the contracting officer (owner) and the contractor.The most
essential part of the contract documents.
2. General Conditions
This contract document will define the obligations and rights on how to execute the project.
3. Special Conditions
This is usually an extension of the contract and to the general conditions. This part must specify
specific conditions and clauses to each particular project or job.
4. Bill of Quantities
This is formed by the list of diverse trades, and materials included that form part of the
construction. Sometimes this document is not required by the contracting officer.
5. Drawings
All set of drawings that form part of the job to be performed. These drawings are usually
the latest drawings and must be received by the contractor prior to the date of commencement.
It must include all drawings from consultants, and will constitute the entire project being
contracted.
6. Specifications
The technical requirement to complete, execute and/or perform every little task or material being
incorporated in the construction projects. It will add intelligence to the construction
drawings;specify common standards, deviations accepted, materials accepted and the
required testingfor all materials. Usually, specifications are composed by referencing
construction standards and codes.
Schedule sample. Courtesy of jwalker64
7. Schedules
The construction schedule is an important piece of the document. In this part, the contracting
office will know how and when the project will be completed. Sometimes,construction
contracts will require updated schedules throughout the construction progress, and might form
part of the monthly, or agreed term, application for payments.
8. Pricing Schedules
Breakdown of all items being incorporated in the construction project. This is usually the base of
the application for payment. It can be detailed per item or in a lump sum form, not specifying
individual items.
Performance bond. J Rodriguez
9. Insurances
This part will be an essential part to the contracting officer, since, it will provide the guarantee to
the owner that the contractor has the means and the economic backup to perform the
construction contract. It will include specific types of coverage’s, required bonding, and
all insuranceprotections to the owner, the contractor and third parties.
Work Breakdown Structure (WBS)
By F. John Reh
Management & Leadership Expert
SHARE
PIN
Ads
Projectmanagement
Task Management
Project Planning
Work Breakdown Structure
Performance Management
Project Manager
Sign Up for our Free Newsletters
About MoneySmall BusinessManagement & Leadership
SIGN UP
MANAGEMENT & LEADERSHIP CATEGORIES
Leadership
Management Skills
Manage People
Project Management
Management Careers and Development
Managing Costs and Money
Business Ethics
Women in Management
Work / Life Balance Issues
Organization, Strategy, and Planning
Policies and Procedures
Frequently Asked Questions (FAQ)
Theory and Discussion
Retail Management Tips
Blog
The Basics of Management
Career Advancement
Leadership
Updated Articles and Resources
Expert Videos
Definition:
A Work Breakdown Structure (WBS) is the organized listing of all the tasks in a project. All the
tasks needed to complete a project are listed. The major tasks are listed and then the sub-tasks
of each task are listed below them. Then the sub-tasks of each sub-task are listed below them.
This continues until all the tasks have been listed. This list is the work breakdown sructure.
Also Known As: Project Task List
Examples: After building the work breakdown structure, the project manager assigned
dependencies to each task in order to begin setting the project plan.
Selecting the Best Architect How to Choose the Best Architect
By Juan Rodriguez
Construction Expert
Selecting the Best Architect
The architect plays an important and decisive role in your construction project. The architect
must be hired if you are considering to build a new home or completing a renovation. Hiring the
architect is a process that will help you come up with new ideas and planning spaces, and also
will help you with every step in the construction process. Starting from the planning process and
ending with all the required documentation, the architect is a valuable piece and key process
within the construction industry.
Architects
Green Architecture
Architecture Firm
Design Build Architects
Construction
The selected architect will be able to meet your needs, clarify some doubts and get your
project in compliance with several construction codes and laws. Also the architect will help
you presenting the first realestimate or budget for your new construction project. Your architect,
if decided by agreement, will oversee construction activities and will ensure that your project is
being built in accordance with the construction drawings and specifications.
The Architect in the Construction Process
The architect will design and plan the use of space within your project. He will be acting on your
behalf in every aspect and will be your eyes during the construction process. The architect will
be selecting the materials used in the construction based in your selection and the performance
of the selected materials, using a unique combination of expertise and knowledge. Furthermore,
he will be negotiating with the contractors the time frame to start and finish construction and
help you with all the required permits and compliance with local, state and federal ordinances.
New & Used Parkhomes For Sale. stock available!
The following steps will help you in the selection of the architect:
1. Ask for recommendations from friends, family or business associates.
2. Set up an interview with the architect. Prepare a list of your main concerns and discuss it with
their representative. Remember, not all questions will be answered but in general terms, the
architect can guide you and inform you.
3. Research on his background and expertise area. There are several types of architects, and
not all of them work with the same kind of projects.
4. Ask specific questions about their services and their scope of work.
5. Compare several architects, with the information that you have gathered.
6. When selected, please be aware that the construction process is a process that takes time
and not is a fast paced from the beginning.
Remember the benefits of hiring the architect are numerous and that the relationship between
the Architect and you, needs to feel comfortable, up front and above all honest, they will be your
closest confident while bringing your dream to life.
Whatever stage you are with your building project, at planning, designing, submitting the
development application, or you are actually starting the construction, the architect will help the
process run smoothly and the hard work out of it for you.
How the Eichleay Formula Can Be Used to Recover Overhead Costs Using thie Formula Might Help You on Claiming Home Office Overhead
By Juan Rodriguez
Construction Expert
The Eichleay Formula is one of the most used calculations when computing home office
extended overhead damages in construction delay claims. Construction delay claims regarding
extended overhead are among the most complicated claims and almost always require the
services of an expert to both determine damages and how those costs can be recovered. Home
office overhead costs include salaries of management staff, clerical staff, utilities, supplies,
dues, training and insurances, to name a few.
Since it is so difficult to separate the costs associated with a particular project, then these costs
need to be properly identify by assigning a percentage of the total amount of these costs.
Why Does the Eichleay Formula Is Being Used
Normally, Eichleay formula is used when the project has been completed and costs are
available and accountable. The Eichleay formula was established following a decision of the
Armed Services Board of Contract Appeals in Eichleay Corporation, ASBCA No. 5183, 60-2
BCA 2688 (1960), used to calculate home office overhead. In 1984, the Federal Circuit held that
the Eichleay formula was the most appropriate method of allocating home office overhead.
Steps to Calculate Extended Overhead Through the Use of the Formula
Using the Eichleay formula requires three steps for the calculation process:
For these calculations you must multiply the total home office overhead cost by the ration
between project billing and general company billings.
Is obtained form the rate between allocable overhead (step 1) between the days of contract
performance including delay days.
Getting to this point is easy. Just multiply the total amount obtained from step #2 by the delay
days. That total will be the total claim amount that you will be asking for.
1. Find the Contract Allocable Overhead - To find the contract allocable overhead, start by multiplying the
total overhead cost identify during the total contract period by the proportion of billings from the delayed
contract to total billings of the firm during the contract period.
2. Daily Contract Overhead Rate - To calculate the daily contract overhead ratio, divide contract overhead
by the contract performance time (by days)
3. Home Office Overhead - To get the final amount, multiply the daily overhead rate by the amount of delay
days caused by the project owner.
How the Project Owner Can Challenge the Use of the Eichleay Formula
There are certain instances that a project owner can challenge the contractor when the formula
is being used. Here are some of the most common arguments a contractor needs to be ready to
be challenged:
The formula is considered an estimate and its accuracy can be questioned.
Contractors can shift their overhead costs to other projects concurrent with the contract being challenged.
The contractor must prove that delays decreased the stream of direct costs.
The contractor must show that it was unable from taking on other work
You must provide further evidence that the actual office overhead costs are real, by usingaudited financial
statements, information that many small contractors can’t afford.
Some objects included in home office overhead, as entertainment and ads, can be questioned.
Sometimes the contractor must prove that the bonding capacity has been limited.
Resources such as equipment and labor were only available and are still in the 'limbo' just because the
project has been delayed.
Some of the contracts might have set a fixed fee for the contract profit.
Some courts may not recognize Eichleay formula for calculating extended overhead.
When project has been substantially completed, it is hard to justify claims from office extended overhead.
The reason for this is that it can be argued that expenses have already been paid to the contractor.
Common Office Overhead Costs
Some of the costs that can be included during this claim process are classified as indirect or
direct costs. It is important to understand and how to recognize these costs to accurately include
them in the claim. Here is a list of the most incurred office overhead costs:
Salaries and fringe benefits of management, clerks and security personnel. Be sure to include accountants,
executives, and in some instances outsourced employees.
All rented equipment such as copiers, phones, fax and other equipment.
Internet, alarm systems, and any other monthly or recurrent cost.
Insurances and bonds.
Marketing, advertising and travel costs.
Legal fees and human resources staff.
Temporary and permanent office structures.
Project management and/or engineering team costs
Leases and land acquisition fees/contracts
Job specific rentals: equipment, labor, trailers, security, utilities and vehicles.
Impact Analysis: Time Impact Analysis Time Impact Analysis
By Juan Rodriguez
Construction Expert
Mike Clarke/E+/Getty Images
Impact Analysis: Time Impact Analysis
A Time Impact Analysis is a method used to determine extent of impact from potentialdelay in
construction process. Time Impact Analysis could be one of the preferred methods to promote
negotiation and later agreements on delay claims. Time impact analysis is done using existing
schedules, analyzed with all related input entered into the schedule to demonstrate the reason
or possible effects on schedule.
Time Impact Analysis is usually performed by a project scheduler and can be used on the vast
majority of construction projects.This schedule analysis method involves the insertion or
addition of activities indicating delays or changes into an updated schedule representing
progress up to the point when a delay event occurred to determine the impact of those delay
activities.
Time Impact Analysis Expectations
A Time impact analysis will be applied to forecast the construction process and analyze what is
going on and what the outcome will be. It requires a CPM schedulethat is able to show the pure
CPM calculation differences between a schedule that does not include a delay and one that
does include an activity modeling a delay. A time impact analysis is required to calculate with
a standard method the results to the actual project delay.
The analysis is not the project reality simulation, it is intended to understand the time impact
caused by a single event or series of events, and how they will impact the project schedule.
It is a great tool on projects that are currently ongoing and will present a real-time idea of how
the contract adjustment is required. The final result of the time impact analysis must be
presented shortly after completion to the contractor; otherwise, he might present an
additional time extension claim of constructive acceleration. It is the best technique for
determining the amount of Extension of Time that the Contractor should have been
granted at the time that an excusable risk occurred.
Time Impact Analysis Uses
Time impact analyses are used on these occasions:
1. When the contractor has not been able to provide remediation instructions and it is not able to redeploy his
workforce.
2. . Time impact analysis is an excellent tool to measure actual delays on events that are undergoing
construction activities.
3. The analysis could be used when delays are already being expected due to external or internal
circumstances.
4. Time impact analyses are used to model delays on short or simple construction activities. If delays are
longer than usual additional methods and tools must be used in conjunction with the TIA.
Time Impact Analysis: When to Avoid It
Time impact analysis should not be used or will not present the best results when:
1. It must be avoided if your actual project schedules have not been updated. TIA will not present a real
outcome when data input on the analysis has not been updated with real data from the construction
activities.
2. Work plans based upon resource considerations are more easily adjusted without detriment to the project
completion or planned expenses than those based upon physical constraints.
3. Time impact analysis should be avoided when mitigation work has already been started. If the
constructions schedule has been altered, the less effective the modeling of the delay will be.
Time Impact Analysis Procedure
A time impact analysis requires the following steps:
1. The delay should be described as simply as possible with the fewest number of activities reflecting the
project delay.
2. Select the schedule to impact. The schedule should be latest updated schedule of the project.
3. Add the impact activities and make the necessary adjustments to project schedule.
4. Recompute the CPM and note a change in the project completion date.
5. Determine the amount of project delay.
6. Determine the actual dates of the delay using the original schedule
Time Impact Analysis Checklist
When performing a time impact analysis be sure to:
1. Study and understand the scope of the directed change or analyze the extent of the delay being found.
2. It is important to analyze all documents, field directions, contract clauses, drawings, orders, specifications
and conditions that could exert any kind of influence to the expected delay.
3. Identify and describe the condition encountered before performing the time impact analysis.
4. Identify all related construction activities that are or could be affected under the expected delay.
5. After a complete analysis of the construction schedule, determine all related dates, start, duration and
finish, for all affected activities.
6. Prepare a complete set of documents that define when the delay started, what actions took place at that
moment, and demonstrate the effects of the delay on the actual updated schedule and how the remaining
activities should be altered, if required, to complete the project on time.
7. The time impact analysis could present you with the overall schedule result incorporating drawings,
contract requirements, and any type of document that support final conclusions. It is important to highlight
extraordinary measures required to bring the project back on schedule.
8. Be certain that actual delays are result of the change directive or delay, not from a non-excusable cause.
Bid Tips - Government Projects Construction Bid Tips
By Juan Rodriguez
Construction Expert
Bid Tips on Government Projects
These bid tips will increase your opportunity to be contracted. If your bid proposal doesn’t have
the correct ingredients or is poorly targeted, you will be eliminated from competition, without
being able to bid fairly with other contractors. Avoid these bid errors when making your
proposals for government projects.
1. Bid Language. Remember, being simple will allow you to get benefits, contract and bid doors
will be open for you.
Keep it simple, avoid confusing language, and be straight to the point, present facts not ideas.
The wording that you use will be the key for someone to keep reading your bid or to put it aside.
Don’t use long sentences and paragraphs, it’s distracting and probably the reader will lose all
connection with your idea.
2. Don’t Risk Current Projects. Sometimes you will bid on something that, maybe you can’t
complete or don't have the available personnel to do it. Make sure and convince your reader
using past projects or past experiences that you have the necessary skills to do it. You
will then re-focus on gather resources to the new project while your other projects will be left
unattended from you or your staff.
3. Credit Cards. Actually many government agencies makes transactions using credit cards,
and sometimes is a requirement on the bid proposal, for you to present evidence that you can
be paid using plastic.
4. Using Incorrect Bid Units. The most common mistake. Bid what they ask you in the units
they are requiring to do so.
Sometimes they require you to submit a bid price for linear feet, instead your past experience
has allowed you to quote based on linear meter. Don’t use meters if they ask for feet. It may
appear like a mistake, but it can cost you, and present the image that you are not careful.
5. Clean bids. Imagine, if your bid is a mess, what can they expect from you in a project?
Check every piece of paper not only in the front but also in the back, your papers should be neat
and clean, and remember to number the pages and bind everything. Remember every piece of
paper is justified and has one specific purpose.
6. Agencies need. Don't discard any agency just because of their name. You will get surprised
to know all the requirements needed from some agencies, it might sound strange but don’t close
the doors.
7. Bid your skill. Instead of presenting vague or general ideas of your business, nail the
proposal by answering specific requirement solicitations. Present specific ideas on how to solve
the problem, what would you do and how would you do it.
8. Bid Time. Time is essential. Every bid proposal has a deadline that you must meet. Failing
to do so will let you out of business immediately. Don’t wait until the last moment to send your
bid proposal, sometimes the mail get stuck with lots of letters, specially during the holiday
season.
9. Out-Bid Your Competitors. How you would be highlighted from other competitors? What
can you complete or do different than the others? What benefits are we going to receive from
you?
Sometimes winning a bid government is not an easy job, but with these guides you will be so
close to get one, that it is worth a try.
Bids: Common Bidding Errors and Recommendations Bidding errors and how to avoid them
By Juan Rodriguez
Construction Expert
Here are some common errors found when bidding construction projects. There are other
items that you must also consider on a bid like: overhead percentage, mobilization, warranties,
experience, fill-in every line on the bid form, contingencies and allowances. Remember the key
to a successful bid is a mix of experience, performance and remember to follow the
instruction to bidders.
1. Bid Error: Arithmetic
Common bidding errors on calculation and using the wrong scale will lead you to the most
common error when placing a bid. Recommendation: Use bidding software or an electronic
calculator with a recording tape. Remember always to double-check quantities and pricing.
2. Bid Error:Improperly Pricing
Verify the quantities and supplies needed; check if the bid requires a lump sum or a unit
price.Recommendation:Pay special attention when reading the instruction to bidders.
3. Bid Error: Incorrect Allowances
Allowing too much or too little amount to perform a job might send a signal to the owner or the
manager that something on your bid is wrong. Recommendation: Prepare a detailed proposal
for the allowance and prepare a complete take-off for this job. Present the number as requested
in the proposal, fixed price, unit price, lump sum, or per instructed.
4. Bid Error: Incorrect Units
Check theschedule of valuesto verify if they are requiring the bid on a lineal feet, yards or
meter unit.Recommendation:Double Check and prepare a separate list with the requested
units
5. Bid Error: Labor Rates
Labor rates vary widely from jurisdiction to jurisdiction. Some projects require you to comply
with Davis-Bacon Act, local union salary rates, among others.Recommendations: Consult local
business, laws and other reliable resources to get the correct rates and how to incorporate them
to your bid. Special attention must be given to overtime rates.
6. Bid Error: Unfamiliarity With Project Site
Huge mistake! Some contractors present bid by merely completing a take-off from construction
drawings. Recommendation: Complete a Due Diligence assessment and verify that field
conditions are represented on construction drawings.
7. Bid Error: Transportation Costs
That huge piece of steel or that unique material must be transported by train, plane, of
overnight. Request a quotation for the delivery of the material and plan its delivery. Broker costs
or special taxes might add up to unexpected quantities. Recommendation: Prepare a logistic
plan of when and how the material will be transported. Remember to provide specific or realistic
date and stick to that quotation as long as you can.
8. Bid Error: Regulations
Every jurisdiction has a local or state code that must be followed. Sometimes these codes
request for special equipment or additional pieces that were not part of the initial
bid.Recommendation: Hire or consult a local expert that will help you on the assessment of the
construction codes
9. Bid Error: Quality
Sometimes contractors tend to work in certain ways, but specific regulations might require to
bring specialized contractors, even licensed contractors, to perform a job. When bidding be
sure that every requirement is being met, and that the proposed workmanship is
appropriate. Recommendation: Look for high specialized items under the contract and request
a quotation from specialized contractors, this will guarantee that you will be in compliance with
all requested labor quality.
10. Bid Error: Minor Items
Minor items tend to present major costs. Sometimes a bid proposal will not require presenting a
bid number for waste disposal, or even scaffolding; but be aware that adding these little costs
can lead to a significant portion of your bid total. Recommendation: Analyze and list all
necessary equipment to perform a job, no matter how small that equipment can be or how short
its usage will be.
11. Bid Error: Overlapping Items Different subcontractor's can be bidding on the same item if their scope is not precise.Be sure to verify
the extent of the quotation from your subcontractor's and discuss its proposal. Recommendation:
Prepare a scope of work and distribute it to your subcontractor's. On a construction drawing mark the
limits of each contractor and discuss with them what items they are including on their bidand what
items they are leaving unattended.
12. Bid Error: Assumption Many bidders tend to use a rule of thumb quoting price for some items. Regularly, you tend to
analyze your job on a per square price, as you used to, but variance in construction costs or specialties in
the construction project might increase those 'ballpark' estimates.Recommendation:Use specific area
details and a complete analysis of your construction project.
13. Bid Error: Alternate Bid Regularly bid request asks foran alternate bid number. Leaving this area without any information will
disqualify you from the competition.Recommendation:Follow the strict guidelines and the instruction to
bidders as closely as you can.
14. Bid Error: Signing Bid answers and quotations are always prepared against the clock, but you must never forget to sign
the bid bond or the bid proposal. Recommendation: Establish a checklist procedure before sending your
bid proposal.
15. Bid Error: Time-Limit Bid proposal always requires to be delivered on a specific time frame. If you plan to answer a bid
proposal organize your subs and your employees to finish the proposals with at least 24 hours
before the specific deadline. Recommendation: Finishing before the due date will leave you enough
time to review the proposal and to get sure that every instruction or detail is covered.
Lump Sum: What Is A Lump Sum? Lump Sum Construction Contracts
By Juan Rodriguez
Construction Expert
A lump sum contract is normally used in theconstruction industry toreduce design and
contract administration costs. It is called a Lump Sum because the contractor is required
to submit a total and global price instead of bidding on individual items. A lump sum contract
is the most recognized agreement form on simple and small projects, for example, projects
with a well-defined scope orconstruction projects where the risk of different site conditions is
minimal.
Lump Sum Contract Basics
A lump sum contract or a stipulated sum contract will require that the supplier agree to provide
specified services for a stipulated or fixed price.
In a lump sum contract, the owner has essentially assigned all the risk to the contractor, who in
turn can be expected to ask for a higher markup in order to take care of unforeseen
contingencies. A supplierbeing contracted under a lump sum agreement will be responsible for
the proper job execution and will provide its own means and methods to complete the work.
This type of contract usually is developed by estimating labor costs, material costs, and adding
a specific amount that will covercontractor’s overhead and profit margin.
The amount of overhead calculated under a lump sum contract will vary from builder to builder,
but it will be based on their risk assessment study and labor expertise. However, estimating a
very large overhead cost can lead the contractor to presenthigher construction costs to the
project owner. The expertise of the contractor will determine how their estimated profit will
actually be; furthermore, a poor executed and long-delayed job will raise your construction costs
and eventually diminish the contractor's profit.
Lump Sum: When to Use It
A lump sum contract is a great contract agreement to be used if the requested work is well-
defined and construction drawings are completed. The lump sum agreement will reduce owner
risk, and the contractor has greater control over profit expectations. It is also a preferred choice
when stable soil conditions, complete pre-construction studies and assessments are completed
and the contractor has analyzed those documents. The stipulated sum contract might contain,
when agreed-upon parties, certain unit prices for items with indefinite quantities and allowance
to cover any unexpected condition. The time to award this type of contract is also longer;
however, it will minimize change orders during construction.
Lump Sum Contract Advantages
A lump sum contract offers the following advantages:
Low risk to owner.
'Fixed' construction cost.
Minimize change orders.
Owner supervision is reduced when compared to Time and Material Contract.
Contractor will try to complete the project faster.
Accepted widely as a contracting method.
Bidding analysis and selection process is relatively easily.
Contractor will maximize its production and performance.
Lump Sum Contract Disadvantages
This type of contracting has also limitations:
It presents higher risk to contractor.
Changes are difficult to quantify.
The Owner might reject change order requests.
The project needs to be designed completely before the commencement of activities.
The construction progress could take longer than other contracting alternatives.
Contractor will select its own means and methods.
Higher contract prices that could cover unforeseen conditions.
Lump Sum Critical Items
Lump sum contracts are a great tool for smaller jobs and quite simple projects. However, lump
sum contracts could eventually produce large dispute and claims that will arise fromcontract
documents. The most common arguing factors are:
1. Unbalanced Bids
2. Some projects might require to produce an application for payment using unit quantities and unit prices.
Many contractors will produce an unbalanced bid by rising unit prices on items to be completed early in
the project, such as mobilization, insurances andgeneral conditions, and lowering unit prices on items
needed in later stages.
3. Change Orders
If the owner produces or receives a change order proposal from the contractor, the price quotation could be
possibly disputed. The Owner might appeal that the requested change was already covered under contract
provisions. It is important to prepare specific contract clauses specifying how change orders are going to be
managed and to what extent the contractor could claim delay damages.
4. Design Changes
5. A contractor may suggest design changes based on their experience. Contract provisions should be
clear on how those changes will be addressed and how those costs will be divided or who will be
responsible for the economic impact of the proposed changes.
6. Early Completion
7. Lump sum contracts might include an early completion compensation for the contractor. Early
completion might produce higher savings for the project owner; however, those clauses might be explicit in
the construction contract.
Hold Harmless Agreement Three Types of Hold Harmless Agreement
By Juan Rodriguez
Construction Expert
A hold harmless agreementis a contract clause typically found in construction contracts. The Hold
Harmless agreement is commonly provided by the subcontractor to the contractor, builder, or others
related professionals insuring against all work being executed by the subcontractor.The provisions
under a Hold Harmless agreement will minimize the risk of being part of a litigationor allow you to
pursue a claim for indemnity if a subcontractor or any of his employees sustain an injury. A hold harmless agreement clause in a contract document should have a specific language to protect the
contractor or the intended parties.
The agreement must include provisions to neglect any kind of claims, damages, losses, expenses or any
other cause of action to the contractor, if any type of problem or disputearises in the construction project.
The hold harmless agreement protection will vary depending on the jurisdiction that the contract is
being executed. In some cases, the hold harmless agreement will protect the contractor from claims
brought by corporations or companies not forming part to the agreement.
Three Basic Types of Hold Harmless Agreements
There are three basic types of Hold Harmless Agreements in the construction industry:Broad Form,
Limited Form and Intermediate Form. 1. Broad Form
2. The subcontractor being insured, assumes all related liability for accidents, its own negligence, general contractor
negligence and the combined negligence between contractor and subcontractor. This is not the recommended form of
agreement due to its broad responsibility terms, and many jurisdictions prohibit this form of hold harmless
agreement. In some cases to validate this type of agreement, the subcontractor must finance its own liability with an
additional insurance policy.
1. Intermediate Form
2. Under this form of agreements the sub contractor assumes all liability for accidents and negligence. The
subcontractor is responsible for his related actions and will not be held accountable for the general contractor's
accidents or negligence. This is one of the most common used types of hold harmless agreement. It is not dependent
on whether it was subcontractor's fault or not, it only depends on whom was executing the accident or who was acting
in a negligent way. In the case that both parties were negligent, thesubcontractor will be held responsible for his
actions and will be liable for his actions and omissions.
3. Limited-Form
4. In a hold harmless limited-form agreement, the subcontractor will be held accountableonly for the accident or
negligence but on a limited form. The subcontractor will assume liability only to the proportional part of what was
his responsibility. This type of agreement will limit the liability of the subcontractor only to his responsibility, and
will include other, under their respective hold harmless agreements for their corresponding part of the accident or
negligence.
Contract Documents Construction Contract Must Have Items
By Juan Rodriguez
Construction Expert
The contract documents are one of the most important pieces that will guarantee of a successful
project. This list contains the most common documents that must form part of every
construction contract.
In addition to this list, there are other numerous contract support documents that can be used in
combination with the standards documents. For example:
Instruction Forms
Time Extension Claim
Request for Information
Preliminary Building Agreement
Progress Payment Certificate
Practical Completion Notice
Defects Document
Contract Information Statement
1. Agreement
The agreement to be used by the contracting officer (owner) and thecontractor.The most
essential part of the contract documents.
2. General Conditions
This contract document will define the obligations and rights on how to execute the project.
3. Special Conditions
This is usually an extension of the contract and to the general conditions. This part must specify
specific conditions and clauses to each particular project or job.
4. Bill of Quantities
This is formed by the list of diverse trades, and materials included that form part of the
construction. Sometimes this document is not required by the contracting officer.
5. Drawings
All set of drawings that form part of the job to be performed. These drawings are usually
the latest drawings and must be received by the contractor prior to the date of commencement.
It must include all drawings from consultants, and will constitute the entire project being
contracted.
6. Specifications
The technical requirement to complete, execute and/or perform every little task or material being
incorporated in the construction projects. It will add intelligence to the construction
drawings;specify common standards, deviations accepted, materials accepted and the
required testingfor all materials. Usually, specifications are composed by referencing
construction standards and codes.
7. Schedules
The construction schedule is an important piece of the document. In this part, the contracting
office will know how and when the project will be completed. Sometimes,construction
contracts will require updated schedules throughout the construction progress, and might form
part of the monthly, or agreed term, application for payments.
8. Pricing Schedules
Breakdown of all items being incorporated in the construction project. This is usually the base of
the application for payment. It can be detailed per item or in a lump sum form, not specifying
individual items.
9. Insurances
This part will be an essential part to the contracting officer, since, it will provide the guarantee to
the owner that the contractor has the means and the economic backup to perform the
construction contract. It will include specific types of coverage’s, required bonding, and
all insuranceprotections to the owner, the contractor and third parties.
Time and Material: Time and Materials Contract Things to know when using a Time and Materials Contract
By Juan Rodriguez
Construction Expert
Joe Raedle/Getty Images News
Time and materials contractsare used when both parties agree to pay predetermined unit rates.
Time and materials contracts are used when it has been impossible presenting an accurate
estimate or where the schedule cannot be defined. This type of contract presents the highest
risk for the owner and the most secure way for a contractor. Time and materials contracts are
the least desirable contract type for the federal government.
Time and Materials Contracts Items
When using time and materials contracts, the following items could be negotiated:
1. Labor Rate- Specifying a fixed rate for all labor including administrative personnel. If you are using T&M on
large projects, be sure to offer discounted labor rates to reduce total project cost.
2. Material Mark-Up- T&M contracts usually add between a 15 and 35 percent onto material prices.
3. Not-to-Exceed- The Time and Material not to exceed, is a contract in which the contractor can bill the work
being performed but there is a cap that could be used as the maximum amount being charged by the
contractor. This type of variation can be used to increasecontractor’s efficiency and it assumes the
excessive costs. It also provides the owner with a cap that will guarantee that contractor will not exceed
from that cap.
4. Maximum Labor Hours- In addition to the not-to-exceed condition, time and material contracts, a maximum
number of labor hours could be set. When the contractors exceed a specified amount, those additional
hours shall not be billed to the other party. This avoids the “less efficiency = more money” issue of time and
materials contracts.
Time and Material Contracting
Some federal agencies use time and material contract, although not popular among
governmental agencies. Some of the agencies that use T&M Contracts are:
Defense Information Systems Agency (DISA)
Federal Transit Administration (FTA)
U.S. Department of Defense (DOD)
Time and material contracts in the federal government can be used once the contracting officer
determines that it is the most suitable contract that can be issued, and when the contract
includes a not to exceed conditions. The Federal Acquisition Regulations (FAR) explain that this
demonstration may be made by establishing that it is not possible at the time of placing the
contract to estimate accurately the extent or duration of the work or to anticipate costs with any
reasonable degree of confidence (FAR 16.601(c)). When using T&M, the government must also
perform surveillance of contractor performance.
Time and Material Contracts Drawbacks
Time and material contracts has also some disadvantages such as:
Profit Limits- Some savvy customers will try to establish not to exceed conditions, will try to reduce mark-up
on materials and even negotiate reduced billable per hour rates.
Ignored Market Prices- Sometimes companies will set lower prices, based on their internal cost structure,
than actual market rates or even vice-versa.
Reduced Business- Customers are not used to work on time and material contract, so finding new business
opportunities, could be really challenging. Customers will likely preferred fixed price contracts.
Billing- Time and materials contracts should be structured in such way that the company will be able to bill
sufficient amount of money to cover fixed costs. When the billing hours are reduced, fixed costs must also
be reduced at the same rate as the billable hours.
Application For Payment Form Application for payment basic form
By Juan Rodriguez
Construction Expert
An application for payment is a construction document that identifies and presents a method on
how a contractor will be paid. The application for payment contains the services or items that
are being incorporated or jobs being executed under a contract agreement. It is usually
presented as a list with the unit price of each item and the quantities of product/material being
furnished.
Application for Payment Importance:
An application for payment provides both the owner and the contractor, with a method of
controlling what items or materials have been provided by the contractor. It is a great toolto
expedite payment and minimize error possibility.
1. Application for Payment General Form There is some Application for payment standards form widely used:
· AIA Forms - G702 Application and Certificate for Payment,
· ConsensusDOCS 291: Application for Payment (GMP)-Facilitates the calculation and
documentation of progress payments where the basis of payment is a guaranteed maximum
price.
· ConsensusDOCS 292: Application for Payment (Lump Sum)-Facilitates the calculation and
documentation of progress payments where the contract price is a lump sum.
· ConsensusDOCS 293: Schedule of Values-Provides a breakdown of the cost of elements of
the work and should be used with the ConsensusDOCS application for payment forms
(ConsensusDOCS 291 and ConsensusDOCS 292).
2. Application for Payment: Schedule of Values The Schedule of Value, is the sheet were items are listed along with their unit prices, quantities
and summary of what has been paid and what is being certified for payment. It provides a
general overview of the project status.
3. Application for Payment: Schedule #2
The Schedule #2 provide a comprehensive list of subcontractors that took part during the
respective period, performing works under the specified contract. It is require to justify the
amounts being certified under the
4. Application for Payment: Schedule 3 The Schedule #3 under the application for payment is a document that releaes and waivers of
claims and stop notices from all Subcontractors furnishing labor, services, or materials covered
by the certificate for payment.
What is Builder’s Risk Insurance? Information of coverage and exclusion of the Builder's Risk Insurance.
By Juan Rodriguez
Construction Expert
Justin Sullivan/Getty Images News
What is Builder’s RiskInsurance? Builder’s Risk Insurance, people also refer to it asCourse of Construction, is some kind of property
insurance. It's a form of insurance, which covers a building where the building is presently being
constructed. It can cover just the structure, or also the materials on site waiting to be installed or
transported to the job site.
The builder's risk insurance policy will pay for damages up to the coverage limit.
The limit must accurately reflect the total completed value of the structure (all materials and labor costs,
but not including land value). The construction budget is the best source for determining the appropriate
limit of insurance.
Builder’s Risk insurance policies can often be written in terms of three-months, six-months, or 12-
months. If the project is not completed by the end of the initial policy term, it can often be extended, but
usually only one time.
What Does a Builder's Risk Covers?
The builders risk policy will provide coverage for damage done to the insured structure from a wide
variety of events. Damage from the following events will be covered by most policies:
Fire
Wind (may be limited in coastal areas)
Theft
Lightning
Hail
Explosion
Vandalism
Vehicles/Aircraft
You should read your course of builder's risk insurance policy to be familiar with its limitations and
exclusions. Limited coverage is provided for collapse. Standardexclusions include:
Earthquake
Employee theft
Water damage
Weather damage to property in the open
War
Government action
Contract penalty
Voluntary parting
Mechanical breakdown
An important exclusion which should be read in its entirety excludes coverage for damage resulting
from faulty: design, planning, workmanship and materials. Earthquake and flood coverage may be
purchased in some areas.
Extensions of coverage may be provided for certain situations. The coverage for these may be limited.
Common builder's risk insurancecoverage extensions include:
Property in transit A coverage extension to protect your property from loss while being transported to the jobsite.
Scaffolding Coverage is extended to apply to scaffolding, construction forms and temporary structures, but only while they are at
a location you have reported.
Property in temporary storage Property that will be used or installed in the secured location and pertaining to the insured company.
Fire department service charge When the fire department is called to save or protect covered property from a covered cause of loss.
Debris removal The builder's risk insurance policy will pay your expenses to remove debris of covered property. This debris must
result from a loss that is covered under this form.
Sewer and Drain Backup Water damage from the back-up of sewers and drains is usually covered.
Valuable papers (site plans, blueprints, etc)
Important Notes
Some additional information that you should know: The insurance will not cover the property of others.
Sub-contractors are required to have their own insurance.
There is no coverage for tools or equipment.
No coverage for liability.
It does not cover accidents in the job site.
Usually coverage ends when the building is completed, or occupied.
The premium for the annual policy is fully earned.
For specific terms, coverage and exclusions, the original builder's risk insurance policy will
determine the applicable coverage.
Performance Bonds Performance Bonds Basics
By Juan Rodriguez
Construction Expert
Lawrence Sawyer/E+/Getty Images
Performance Bonds guarantee for the satisfactory completion of a project. This will require
having a collateral property or investment to back up the requirements of the surety agency. A
performance bond is usually issued by a bank or aninsurance company, both of which act as a
“surety.”
Performance Bonds: How They Work?
The Government requires performance bonds and payment bonds for projects to protect
the tax payer’s investment.
Construction Bonds
Performance Bond
Surety Bond
Construction Insurance
Construction Contractors
The private sector also requires the issuance of performance bonds. Common performance and
payments bonds for government projects consist of buildingbridges and roads. If the contractor
does not completion the project specified in the contract the surety bonding company will
either pay for the completion of the project or hire a contracting firm to complete the
project.
A performance bond will protect the owner against possible losses in a case a contractor fails to
perform, or is unable to deliver the project as per established and thecontract provisions.
Sometimes the contractor defaults or declares himself in bankruptcy, and then in those
situations the surety is responsible to compensate the owner for the losses. Such
compensation is defined as the amount covered under the performance bond.
Payment from the performance bond is available only to the project/property owner. No one else
can make claims against it. In order for a performance bond to be effective, the contract must be
specific about the work to be done.
A contractor cannot be held accountable for vague descriptions that are open to interpretation.
Performance Bonds Benefits
Performance bonds ensure that:
The owner of a project is assured of the completion of the project.
The owner does not need to incur additional costs.
There are also some drawbacks with the Performance Bonds. The drawbacks of performance
bonds are:
Sometimes, the surety tries to establish that the owner did not comply with the technical conditions of a
bond to avoid paying the compensation.
Sometimes the surety will try to prove, that the owner may have to settle for the least expensive remedy
to the problem.
The owner needs to quantify the losses that might have been suffered when a trader or contractor fails in
their performance.
If the owner underestimates the losses and the future cost of the completion of the project, the owner may
not be able to recover the shortfall from the surety.
Performance Bonds Requirements
Surety and financial institutions have different requirements depending on the capacity of the
contractor, the volume of the project being ensured and the projects challenges. Usually they
ask for the following:
At least two years of CPA prepared financial statements.
Copy of the contract that is being awarded.
Application of the surety.
If you own real estate, it will help you and will accelerate the process.
Florida Contractor License: How to Become a Licensed Contractor Learn How to Get Your Contractor's License
By Juan Rodriguez
Construction Expert
Hero Images/Getty Images
CONSTRUCTION INDUSTRY LICENSING BOARD
Being a licensed contractor in Florida requires documentation and being certified by the
Construction Industry Licensing Board. The Board is responsible for regulating contractors
and their performance in the construction industry. The Construction Industry Licensing
Board meets regularly to review future member’s applications, analyze and recommend
disciplinary sanctions.
It also participates in rulemaking processes and is also on the look to enforce regulations
and standards among contractors.
Florida Contractor License: Types of License
There two major contractor’s license in the state: Registration and Certification. When the
contractor has obtained a local or city license, then he/she must apply for the initial registration
license. When a contractor has been registered by the Board, then it may only practice in the
city or local area where it permission has been granted. Once the contractor completes and
applies the Florida contractor’s license examination, then the Board might allow you to work
through the state. Both applications can be accessed atwww.myfloridalicense.com.
Contractors practicing general, residential, sheet metal, AC, mechanical, swimming pools,
plumbing, solar, building, underground utility, glass and glazing and pollutant storage activities
require a registration or certification permission from the Board.
Florida Contractor License: Swimming Pools Contractors
The state has one of the most per building ratio of swimming pools in the nation, and for
that reason the Board has created new licenses for contractors engaged in that business.
For example, the Board now includes specialties such as: pool layout, structural pool
design, excavation, trim, pool decking, pool piping and finishes. For these contractor
licenses the state requires a practical test and be at least 18 years old. The board is now
finishing technical paperwork required for this processes.
Florida Contractor License: Being a Certified Contractor
In order to be a Florida Certified Contractor, you must be able to pass the contractor’s test,
provide proven record of financial stability, and present evidence of your experience for the
category in which you wish to be licensed. A contractor must have at least four years of field
experience in the category being considered, and one of those years has to be acting under
a supervisory role. This last requirement could be substituted by at least three years of
undergraduate credit hours. When the contractor wishes to be certified as a building or
general contractor, he/she must present evidence of experience in four of these categories:
Foundations/Slabs in excess of 20,000 square feet
Masonry walls
Steel erection
Elevated slabs
Pre-cast concrete structures
Column erection
Formwork for structural reinforced concrete
In addition to these requirements, contractors must present their past criminal history
information, insurance minimum bonding active at all times ($300K liability, $5k property
damage) or any other amount the contractor boards deemed necessary. Finally, the contractor
must also present active workers’ compensation coverage or an exemption.
Florida Contractor License: Uncategorized Trades
The complexity and variety of construction business is changing day to day. If you want to
be considered a certified contractor, but the trade you perform is not listed by the Board,
you must verify with your local county to see if they offer the type of license you are
requesting. In case the trade being performed is not listed and the work you perform
modifies or created a structure, then a residential, building or general contractor’s license
will be issued. However, the following do not require a state contractor’s license:
Cabinets
Countertops
Flooring
Paint
Wallpaper
Window treatments
Florida Contractor License: Reciprocity
The Florida Contractor’s licensing board offers reciprocity. However, you must first
demonstrate that the exam you passed in your local state is similar or equivalent to Florida’s
or that the requirements on which the contractor license was granted are equivalent to
Florida standards.
Selection of the Best Engineering Firm
By Juan Rodriguez
Construction Expert
Selection of the Best Engineering Firm
Selecting the best engineering firm for your project is a hard task to complete and harder to achieve.
Several companies throughout the nation will try to convince you to use their services, but the best one
will be the one that fulfills your requests.
Engineering Firm: Statement of the Project
Prepare a brief detailed summary of the project. This will help Eengineering firms decide whether or not
participate in your project and to know if they can successfully perform the project you are thinking
about.
It will save you time and money and will discard other companies that might not match your desired skills
and scope of work. This preliminary scope should have:
· The name of the project and location.
· Details like proposed use, capacity and other general related information.
· Funding sources or where the money for the investment will come from.
· Prepare or estimate a calendar and targeted dates.
· Special requirements or restrictions.
· Specialties involved in your project, for example, inspection and management services.
Engineering Firm: Request of Qualification
Once your scope has been elaborated using the guidelines from the previous section, engineering firms
must be invited to submit their credentials and qualifications. Public agencies are required to inform
through massive media, that the request for qualification process has begun. The way it will be informed,
depends on the size and complexity of the project. The contract announcement should include:
· The project description.
· Project’s name and contact person.
· Due dates for submission.
· Special requirements.
· Documentation required from the firms.
Each firm then must submit the information requested along with the names of firm owners, number of
years in business, types of services offered, background on key technical personnel, similar projects
designed by the firm, projects underway, etc.
Evaluation of Qualifications
When the deadline for submission of statements for qualifications has expired, the owner should evaluate
the qualifications of those firms that responded, and narrow the field of interested firms to three to five
firms. Then each firm will be evaluated based in their experience on similar projects, key staff, expertise,
facilities and references.
This process is usually done by a committee or in some instances the architect of the project will conduct
the process. This process should be done by competent professionals that are capable of evaluate several
performances.
Frequently, an owner will emphasize on firms having experience in similar projects and solid
performance along their careers. This can be done weighing their experience, staff, economic and finance
stability and past projects using a balanced formula to select the most suitable engineering firm based on
his requirements.
Engineering Firm: Ranking Process
The final process is the more difficult process of all. The Owner’s opinion has huge importance since the
selection will be based using his criteria and evaluation requirement. When conducting the evaluations,
each committee member ranks the firms, highest to lowest, according to their total scores. The firm that is
rated most highly overall should be notified that it has been selected to receive the contract, pending
agreement on the scope of service and the fee for those services.
Understanding Soft Costs Items included in soft costs on a construction project
By Juan Rodriguez
Construction Expert
Soft Costs constitute a big portion of your construction costs. A construction project is possible
due to the soft costs, that when added to the hard cost and land cost, you will have the total cost
amount for your construction project. Soft costs are traditionally non-seen items that composed
the initial part of developing a construction project.
By Brock Builders
1. Architectural and Design Fees
The architectural and design fee includes costs incurred on feasibility studies, master planning,
design costs, and all other cost included from schematic to project completion.
2. Inspection Fees
Cost of inspections, permits and fees paid to local government.
Land. by Neil Ennis
3. Land Costs
Land costs associated withlegal process, appraisal, real estate,land acquisition,
assessments or improvementsto land related issues.
4. Off-Site
Some projects require to improve conditions in their neighborhood or to complete
improvements to local infrastructure.
5. Equipments
Equipments not being incorporated in the final project delivery.
6. Interests
Cost of loan generated interests.
7. Accounting Fees
All accounting expenses and cost incurred during the development of the construction process.
8. Project Management
Staff required to handle all construction related documentation and drawings.
9. Insurances
All required insurances for the completion of the construction project.
10. Taxes
Money required by state and local agencies depending on the amount of money being invested
in the construction.
Construction Schedule Techniques Construction Scheduling Techniques
By Juan Rodriguez
Construction Expert
Construction ScheduleTechniques
There are many ways in the construction industry to represent and createconstruction
schedulestechniques. Which one is the best for you? We will explain briefly four alternatives that
you can use depending on the project requirements and difficulties.
Construction Schedule: Bar Charts
Bar Charts are the most simple and easiest way to produce a scheduling form in the
construction industry.
It is widely used due to its simplicity and multiple adaptations to numerous events. A bar charts
is formed with a list of activities, specifying the start date, duration of the activity and completion
date of each activity, and then plotted into a the project time scale. The detailed level of the bar
chart will depend on your project complexity and the intended use of the schedule.
A variation of the bar chart schedule, is the linked bar chart. Using a linked bar chart, the
activities and subsequent items are linked with arrows and lines, specifying the sequence and
order of preceding activities. The previous activities are linked one to another to demonstrate
that one activity must be completed before the other activity can start.
Bar charts are useful and commonly used todetect the amount of resources needed for one
particular project. Adding the resources vertically will produce what is called the resource
aggregation. The purpose of this aggregation is to estimate the work production and
establishing estimates for man-hour and equipment needed.
Construction Schedule: Critical Path Method
This process is more elaborated and detailed than the previous one. With a large list of
activities, each activity is then linked to previous and subsequent activities, specifying that each
activity has at least another one that must be completed prior to starting the preceding one.
With the Critical Path Method, calendar days are established and activities are assigned with an
early date, first date that an activity can start; late start, specifying the last possible date that this
activity must be started to avoid delays in the overall construction process; early finish, the
earlier date that the proposed activity will be completed; and the late finish, that is the last date
the activity must be completed without affecting the start of the next one, and subsequently
affecting the entire construction schedule. The steps in producing a network are:
- Listing of activities
- Producing a network showing the logical relationship between activities.
- Assessing the duration of each activity, producing a schedule, and determining the start and
finish times of each activity and the available float
- Assessing the required resources.
Construction Schedule: Line of Balance
This process is a planning technique for repetitive work. The essential procedure for this
scheduling technique is to allocate the resources needed for each step or operation, so the
following activities are not delayed and the result can be obtained. The principles employed are
taken from the planning and control of manufacturing processes greatly modified by E. G.
Trimple. This process is usually applied in the construction work and more specific in road
construction.
Construction Schedule: Q Scheduling
Q. Scheduling is quantitative scheduling, in the context that quantities to be executed at
different locations of the construction project form the elements of the schedule. Also Q.
Scheduling is Queue Scheduling in the context that trades pass through the different segments
of the project in a queue sequence. No interference between two activities is allowed at the
same location. It is derived basically from the Line of balance technique with some
modifications to allow for the non repetitive models that are characteristic of the majority of
construction projects.
The Q Scheduling is a new technique, though getting rapid popularity among contracting firms.
It is the only scheduling technique that reveals a relation between the sequence of doing a job
and the cost to be incurred. The Q schedule is similar to the Line of Balance with some
modifications, to allow for a varying volume of repetitive activities at different segments or
locations of the construction project, thus the model produced is closer to reality.
Contract: Construction Contract Basics Construction Contract Basics
By Juan Rodriguez
Construction Expert
Construction contracts can be a very useful tool that every builder must know to perfection.
There are different types of contracts, tips and guidelines that must form part of every
construction contract. Contracting agents are a vital part of the construction industry, but
following these guidelines you can become one great contracting leader.
1. Contract Documents The contract documents are one of the most important pieces that will guarantee of a successful
project. This list contains the most common documents that must form part of every
construction contract.More »
Which contract to use?
2. Contract Types There are a several types of construction contracts used in the industry, but there are certain
types of construction contracts preferred by construction professionals.More »
3. Union Contracts A labor union contract is a powerful agreement between parts to secure your rights in the
workplace. According to labor law, contracts represent the minimum compensation and
benefits for employees. More »
4. Contract: Direct Hire or Sub-Contract Subcontracting can offer you some warranties and hiring someone directly will require
additional efforts from you. But what is the best decision? More »
5. Contract Key Rules When you're ready to negotiate with the company regarding benefits, wages and work
conditions, use the following steps to generate productive talks. More »
6. Contract Negotiation Process The negotiating of a contract is a stressful time, and it will drain you mentally and physically.
Follow these steps to help you reduce the time dedicated to the process.More »
General Scaffold Requirements
By Juan Rodriguez
Construction Expert
List of general scaffold requirements in the construction industry. This list is for informational
purposes only and might not be used as a standard. For more information, regulations and
standard's visit OSHA's website.
Scaffold components must be able to support at least four times their maximum intended load.
The scaffolding platform should be fully planked, with no more than a 1-inch gap between planks and
uprights.
The gap between the last plank and the uprights should be less than 9½ inches.
18 inches is the minimum wide dimension allowed on platforms.
The scaffold should be 14 inches or less from the work face, or 18 inches for plastering and lathing.
12 inches is the maximum extension permitted for planks beyond the frames.
Casters must be locked before work begins.
Platform surfaces should be secured.
The platform should be free from any object that may cause an accident.
Power lines must be at least 10 feet awayfrom scaffolding, material and workers.
Different manufacturers of scaffolding components can be used, but they must fit together without force.
A defective scaffold must be removed from service immediately.
Indemnity Agreements Three common types of indemnity agreements.
By Juan Rodriguez
Construction Expert
Indemnity Agreement in Construction Contracts
An Indemnity agreement can protect you and allow others to bear the costs associated with damages.
An indemnity agreement will reduce your construction risks and can control your total legal expenses. It
is important that the agreement itself can describe the types of losses being covered, including legal
fees. Some states do not favor indemnity agreements and present limitations to indemnity agreements.
It is very important that the agreement properly identifies the scope and extent of the indemnification.
This type of agreement is developed to protect the contractor less active under one particular trade or
series of events.
Types of Indemnity Clauses
Every indemnity agreement should be prepared accordingly to the type of project being executed. The
most common indemnity clauses are:
Type I
Also known as a Broad Form Indemnity. Under this clause the indemnitor is responsible for his own negligence as
well as the negligence of a third party. This means that the indemnitor may be liable for the sole negligence of the
indemnitee. In some states, such as California, the indemnitee cannot transfer damages caused by his sole negligence
or willful misconduct to the indemnitor.
Type II
The type II or intermediate form of agreements will put the indemnitor assuming all the risks associated but not if
the risk is the indemnitee responsibility. It is the preferred clause in the construction industry and could hold the
owner harmless from any and all claims, caused by negligent acts or omissions of the owner. It requires all-or-
nothing indemnification.
Textured Bricks and Blocks.Any Colour or Geometry.Highly Durable.
Type III
A Type III or a comparative form clauserequires a comparison of negligence. Under this clause the indemnitor will
be held responsible for the loss caused by the indemnitor. This Type Three agreement is based upon common law
principalscommonly recognized in the United States. The indemnitor is not liable for direct negligence committed by
the indemnitee.
Other Types of Indemnity Clauses
A work related clause, rarely used, doesn't requires an act of negligence or omission. It only depends on whether the
work was being performed by the subcontractor.
A mutual clause applies the same standard to each party, the indemnitor and the indemnitee.
Indemnity Clause Claims
An indemnity clause can be used for the following purposes:
Breach of Contract
Liability for negligence
Compensation due to injuries or property damages.
Claims for loss.
All types of property infringement.
Legal costs and related expenses.
Loss of profit.
Taxes and interests payable by a default contractor.
Indemnity Clause Contract Forms
The AIA Document A401 'Standard Form of Agreement Between Contractor and Subcontractor' states
and provides for indemnity as follows:
'§ 4.3.4 To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the
Subcontractor, the Subcontractor's Sub-subcontractors, and agents and employees of any of them from
and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out
of or resulting from performance of the Work in the affected area if in fact the material or substance
presents the risk of bodily injury or death as described in Section 4.3.3 and has not been rendered
harmless, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness,
disease or death, or to injury to or destruction of tangible property (other than the Work itself) except to
the extent that such damage, loss or expense is due to the fault or negligence of the party seeking
indemnity.
§ 4.3.5 The Subcontractor shall indemnify the Contractor for the cost and expense the Contractor incurs
(1) for remediation of a material or substance brought to the site and negligently handled by the
Subcontractor or (2) where the Subcontractor fails to perform its obligations under Section 4.3.3, except
to the extent that the cost and expenses are due to the Contractor's fault or negligence.'
If you decide to use ConsensusDOCS 'Standard Form of Agreement Between Contractor and
Subcontractor',ConsensusDocs 750, you will also be covered with an indemnity clause specified under
section 9.1.1 and 9.1.2.
Both of these contract forms limit the subcontractor's obligation to indemnify the contractor. This
last form, imposes additional indemnity obligations not covered under the AIA A401 form. In addition to
these clauses it is very important to consider all other insurance requirements.
9. Construction Planning
9.1 Basic Concepts in the Development of Construction Plans
Construction planning is a fundamental and challenging activity in the management
and execution of construction projects. It involves the choice of technology, the
definition of work tasks, the estimation of the required resources and durations for
individual tasks, and the identification of any interactions among the different work
tasks. A good construction plan is the basis for developing the budget and the
schedule for work. Developing the construction plan is a critical task in the
management of construction, even if the plan is not written or otherwise formally
recorded. In addition to these technical aspects of construction planning, it may also
be necessary to make organizational decisions about the relationships between project
participants and even which organizations to include in a project. For example, the
extent to which sub-contractors will be used on a project is often determined during
construction planning.
Forming a construction plan is a highly challenging task. As Sherlock Holmes noted:
Most people, if you describe a train of events to them, will tell you what the result
would be. They can put those events together in their minds, and argue from them that
something will come to pass. There are few people, however, who, if you told them a
result, would be able to evolve from their own inner consciousness what the steps
were which led up to that result. This power is what I mean when I talk of reasoning
backward. [1]
Like a detective, a planner begins with a result (i.e. a facility design) and must
synthesize the steps required to yield this result. Essential aspects of construction
planning include the generation of required activities, analysis of the implications of
these activities, and choice among the various alternative means of performing
activities. In contrast to a detective discovering a single train of events, however,
construction planners also face the normative problem of choosing the best among
numerous alternative plans. Moreover, a detective is faced with an observable result,
whereas a planner must imagine the final facility as described in the plans and
specifications.
In developing a construction plan, it is common to adopt a primary emphasis on either
cost control or on schedule control as illustrated in Fig. 9-1. Some projects are
primarily divided into expense categories with associated costs. In these cases,
construction planning is cost or expense oriented. Within the categories of
expenditure, a distinction is made between costs incurred directly in the performance
of an activity and indirectly for the accomplishment of the project. For example,
borrowing expenses for project financing and overhead items are commonly treated as
indirect costs. For other projects, scheduling of work activities over time is critical
and is emphasized in the planning process. In this case, the planner insures that the
proper precedences among activities are maintained and that efficient scheduling of
the available resources prevails. Traditional scheduling procedures emphasize the
maintenance of task precedences (resulting in critical path scheduling procedures) or
efficient use of resources over time (resulting in job shop scheduling procedures).
Finally, most complex projects require consideration of both cost and scheduling over
time, so that planning, monitoring and record keeping must consider both dimensions.
In these cases, the integration of schedule and budget information is a major concern.
Figure 9-1 Alternative Emphases in Construction Planning
In this chapter, we shall consider the functional requirements for construction
planning such as technology choice, work breakdown, and budgeting. Construction
planning is not an activity which is restricted to the period after the award of a
contract for construction. It should be an essential activity during the facility design.
Also, if problems arise during construction, re-planning is required.
Back to top
9.2 Choice of Technology and Construction Method
As in the development of appropriate alternatives for facility design, choices of
appropriate technology and methods for construction are often ill-structured yet
critical ingredients in the success of the project. For example, a decision whether to
pump or to transport concrete in buckets will directly affect the cost and duration of
tasks involved in building construction. A decision between these two alternatives
should consider the relative costs, reliabilities, and availability of equipment for the
two transport methods. Unfortunately, the exact implications of different methods
depend upon numerous considerations for which information may be sketchy during
the planning phase, such as the experience and expertise of workers or the particular
underground condition at a site.
In selecting among alternative methods and technologies, it may be necessary to
formulate a number of construction plans based on alternative methods or
assumptions. Once the full plan is available, then the cost, time and reliability impacts
of the alternative approaches can be reviewed. This examination of several
alternatives is often made explicit in bidding competitions in which several alternative
designs may be proposed or value engineering for alternative construction methods
may be permitted. In this case, potential constructors may wish to prepare plans for
each alternative design using the suggested construction method as well as to prepare
plans for alternative construction methods which would be proposed as part of the
value engineering process.
In forming a construction plan, a useful approach is to simulate the construction
process either in the imagination of the planner or with a formal computer based
simulation technique. [2] By observing the result, comparisons among different plans
or problems with the existing plan can be identified. For example, a decision to use a
particular piece of equipment for an operation immediately leads to the question of
whether or not there is sufficient access space for the equipment. Three dimensional
geometric models in a computer aided design (CAD) system may be helpful in
simulating space requirements for operations and for identifying any interferences.
Similarly, problems in resource availability identified during the simulation of the
construction process might be effectively forestalled by providing additional resources
as part of the construction plan.
Example 9-1: A roadway rehabilitation
An example from a roadway rehabilitation project in Pittsburgh, PA can serve to
illustrate the importance of good construction planning and the effect of technology
choice. In this project, the decks on overpass bridges as well as the pavement on the
highway itself were to be replaced. The initial construction plan was to work outward
from each end of the overpass bridges while the highway surface was replaced
below the bridges. As a result, access of equipment and concrete trucks to the
overpass bridges was a considerable problem. However, the highway work could be
staged so that each overpass bridge was accessible from below at prescribed times.
By pumping concrete up to the overpass bridge deck from the highway below, costs
were reduced and the work was accomplished much more quickly.
Example 9-2: Laser Leveling
An example of technology choice is the use of laser leveling equipment to improve
the productivity of excavation and grading. [3] In these systems, laser surveying
equipment is erected on a site so that the relative height of mobile equipment is
known exactly. This height measurement is accomplished by flashing a rotating laser
light on a level plane across the construction site and observing exactly where the
light shines on receptors on mobile equipment such as graders. Since laser light does
not disperse appreciably, the height at which the laser shines anywhere on the
construction site gives an accurate indication of the height of a receptor on a piece
of mobile equipment. In turn, the receptor height can be used to measure the height
of a blade, excavator bucket or other piece of equipment. Combined with electro-
hydraulic control systems mounted on mobile equipment such as bulldozers, graders
and scrapers, the height of excavation and grading blades can be precisely and
automatically controlled in these systems. This automation of blade heights has
reduced costs in some cases by over 80% and improved quality in the finished
product, as measured by the desired amount of excavation or the extent to which a
final grade achieves the desired angle. These systems also permit the use of smaller
machines and less skilled operators. However, the use of these semi-automated
systems require investments in the laser surveying equipment as well as modification
to equipment to permit electronic feedback control units. Still, laser leveling appears
to be an excellent technological choice in many instances.
Back to top
9.3 Defining Work Tasks
At the same time that the choice of technology and general method are considered, a
parallel step in the planning process is to define the various work tasks that must be
accomplished. These work tasks represent the necessary framework to
permit scheduling of construction activities, along with estimating
the resources required by the individual work tasks, and any necessary precedences or
required sequence among the tasks. The terms work "tasks" or "activities" are often
used interchangeably in construction plans to refer to specific, defined items of work.
In job shop or manufacturing terminology, a project would be called a "job" and an
activity called an "operation", but the sense of the terms is
equivalent. [4] The scheduling problem is to determine an appropriate set of activity
start time, resource allocations and completion times that will result in completion of
the project in a timely and efficient fashion. Construction planning is the necessary
fore-runner to scheduling. In this planning, defining work tasks, technology and
construction method is typically done either simultaeously or in a series of iterations.
The definition of appropriate work tasks can be a laborious and tedious process, yet it
represents the necessary information for application of formal scheduling procedures.
Since construction projects can involve thousands of individual work tasks, this
definition phase can also be expensive and time consuming. Fortunately, many tasks
may be repeated in different parts of the facility or past facility construction plans can
be used as general models for new projects. For example, the tasks involved in the
construction of a building floor may be repeated with only minor differences for each
of the floors in the building. Also, standard definitions and nomenclatures for most
tasks exist. As a result, the individual planner defining work tasks does not have to
approach each facet of the project entirely from scratch.
While repetition of activities in different locations or reproduction of activities from
past projects reduces the work involved, there are very few computer aids for the
process of defining activities. Databases and information systems can assist in the
storage and recall of the activities associated with past projects as described in
Chapter 14. For the scheduling process itself, numerous computer programs are
available. But for the important task of defining activities, reliance on the skill,
judgment and experience of the construction planner is likely to continue.
More formally, an activity is any subdivision of project tasks. The set of activities
defined for a project should be comprehensive or completely exhaustive so that all
necessary work tasks are included in one or more activities. Typically, each design
element in the planned facility will have one or more associated project activities.
Execution of an activity requires time and resources, including manpower and
equipment, as described in the next section. The time required to perform an activity
is called the duration of the activity. The beginning and the end of activities are
signposts or milestones, indicating the progress of the project. Occasionally, it is
useful to define activities which have no duration to mark important events. For
example, receipt of equipment on the construction site may be defined as an activity
since other activities would depend upon the equipment availability and the project
manager might appreciate formal notice of the arrival. Similarly, receipt of regulatory
approvals would also be specially marked in the project plan.
The extent of work involved in any one activity can vary tremendously in construction
project plans. Indeed, it is common to begin with fairly coarse definitions of activities
and then to further sub-divide tasks as the plan becomes better defined. As a result,
the definition of activities evolves during the preparation of the plan. A result of this
process is a natural hierarchy of activities with large, abstract functional activities
repeatedly sub-divided into more and more specific sub-tasks. For example, the
problem of placing concrete on site would have sub-activities associated with placing
forms, installing reinforcing steel, pouring concrete, finishing the concrete, removing
forms and others. Even more specifically, sub-tasks such as removal and cleaning of
forms after concrete placement can be defined. Even further, the sub-task "clean
concrete forms" could be subdivided into the various operations:
Transport forms from on-site storage and unload onto the cleaning station. Position forms on the cleaning station. Wash forms with water. Clean concrete debris from the form's surface. Coat the form surface with an oil release agent for the next use. Unload the form from the cleaning station and transport to the storage
location.
This detailed task breakdown of the activity "clean concrete forms" would not
generally be done in standard construction planning, but it is essential in the process
of programming or designing a robot to undertake this activity since the various
specific tasks must be well defined for a robot implementation. [5]
It is generally advantageous to introduce an explicit hierarchy of work activities for
the purpose of simplifying the presentation and development of a schedule. For
example, the initial plan might define a single activity associated with "site
clearance." Later, this single activity might be sub-divided into "re-locating utilities,"
"removing vegetation," "grading", etc. However, these activities could continue to be
identified as sub-activities under the general activity of "site clearance." This
hierarchical structure also facilitates the preparation of summary charts and reports in
which detailed operations are combined into aggregate or "super"-activities.
More formally, a hierarchical approach to work task definition decomposes the work
activity into component parts in the form of a tree. Higher levels in the tree represent
decision nodes or summary activities, while branches in the tree lead to smaller
components and work activities. A variety of constraints among the various nodes
may be defined or imposed, including precedence relationships among different tasks
as defined below. Technology choices may be decomposed to decisions made at
particular nodes in the tree. For example, choices on plumbing technology might be
made without reference to choices for other functional activities.
Of course, numerous different activity hierarchies can be defined for each
construction plan. For example, upper level activities might be related to facility
components such as foundation elements, and then lower level activity divisions into
the required construction operations might be made. Alternatively, upper level
divisions might represent general types of activities such as electrical work, while
lower work divisions represent the application of these operations to specific facility
components. As a third alternative, initial divisions might represent different spatial
locations in the planned facility. The choice of a hierarchy depends upon the desired
scheme for summarizing work information and on the convenience of the planner. In
computerized databases, multiple hierarchies can be stored so that different
aggregations or views of the work breakdown structure can be obtained.
The number and detail of the activities in a construction plan is a matter of judgment
or convention. Construction plans can easily range between less than a hundred to
many thousand defined tasks, depending on the planner's decisions and the scope of
the project. If subdivided activities are too refined, the size of the network becomes
unwieldy and the cost of planning excessive. Sub-division yields no benefit if
reasonably accurate estimates of activity durations and the required resources cannot
be made at the detailed work breakdown level. On the other hand, if the specified
activities are too coarse, it is impossible to develop realistic schedules and details of
resource requirements during the project. More detailed task definitions permit better
control and more realistic scheduling. It is useful to define separate work tasks for:
those activities which involve different resources, or those activities which do not require continuous performance.
For example, the activity "prepare and check shop drawings" should be divided into a
task for preparation and a task for checking since different individuals are involved in
the two tasks and there may be a time lag between preparation and checking.
In practice, the proper level of detail will depend upon the size, importance and
difficulty of the project as well as the specific scheduling and accounting procedures
which are adopted. However, it is generally the case that most schedules are prepared
with too little detail than too much. It is important to keep in mind that task definition
will serve as the basis for scheduling, for communicating the construction plan and for
construction monitoring. Completion of tasks will also often serve as a basis for
progress payments from the owner. Thus, more detailed task definitions can be quite
useful. But more detailed task breakdowns are only valuable to the extent that the
resources required, durations and activity relationships are realistically estimated for
each activity. Providing detailed work task breakdowns is not helpful without a
commensurate effort to provide realistic resource requirement estimates. As more
powerful, computer-based scheduling and monitoring procedures are introduced, the
ease of defining and manipulating tasks will increase, and the number of work tasks
can reasonably be expected to expand.
Example 9-3: Task Definition for a Road Building Project
As an example of construction planning, suppose that we wish to develop a plan for
a road construction project including two culverts. [6] Initially, we divide project
activities into three categories as shown in Figure 9-2: structures, roadway, and
general. This division is based on the major types of design elements to be
constructed. Within the roadway work, a further sub-division is into earthwork and
pavement. Within these subdivisions, we identify clearing, excavation, filling and
finishing (including seeding and sodding) associated with earthwork, and we define
watering, compaction and paving sub-activities associated with pavement. Finally,
we note that the roadway segment is fairly long, and so individual activities can be
defined for different physical segments along the roadway path. In Figure 9-2, we
divide each paving and earthwork activity into activities specific to each of two
roadway segments. For the culvert construction, we define the sub-divisions of
structural excavation, concreting, and reinforcing. Even more specifically, structural
excavation is divided into excavation itself and the required backfill and compaction.
Similarly, concreting is divided into placing concrete forms, pouring concrete,
stripping forms, and curing the concrete. As a final step in the structural planning,
detailed activities are defined for reinforcing each of the two culverts. General work
activities are defined for move in, general supervision, and clean up. As a result of
this planning, over thirty different detailed activities have been defined.
At the option of the planner, additional activities might also be defined for this
project. For example, materials ordering or lane striping might be included as separate
activities. It might also be the case that a planner would define a different hierarchy of
work breakdowns than that shown in Figure 9-2. For example, placing reinforcing
might have been a sub-activity under concreting for culverts. One reason for
separating reinforcement placement might be to emphasize the different material and
resources required for this activity. Also, the division into separate roadway segments
and culverts might have been introduced early in the hierarchy. With all these
potential differences, the important aspect is to insure that all necessary activities are
included somewhere in the final plan.
Figure 9-2 Illustrative Hierarchical Activity Divisions for a Roadway Project
Back to top
9.4 Defining Precedence Relationships Among Activities
Once work activities have been defined, the relationships among the activities can be
specified. Precedence relations between activities signify that the activities must take
place in a particular sequence. Numerous natural sequences exist for construction
activities due to requirements for structural integrity, regulations, and other technical
requirements. For example, design drawings cannot be checked before they are drawn.
Diagramatically, precedence relationships can be illustrated by a network or graph in
which the activities are represented by arrows as in Figure 9-0. The arrows in Figure
9-3 are calledbranches or links in the activity network, while the circles marking the
beginning or end of each arrow are called nodes or events. In this figure, links
represent particular activities, while the nodes represent milestone events.
Figure 9-3 Illustrative Set of Four Activities with Precedences
More complicated precedence relationships can also be specified. For example, one
activity might not be able to start for several days after the completion of another
activity. As a common example, concrete might have to cure (or set) for several days
before formwork is removed. This restriction on the removal of forms activity is
called a lag between the completion of one activity (i.e., pouring concrete in this case)
and the start of another activity (i.e., removing formwork in this case). Many
computer based scheduling programs permit the use of a variety of precedence
relationships.
Three mistakes should be avoided in specifying predecessor relationships for
construction plans. First, a circle of activity precedences will result in an impossible
plan. For example, if activity A precedes activity B, activity B precedes activity C,
and activity C precedes activity A, then the project can never be started or completed!
Figure 9-4 illustrates the resulting activity network. Fortunately, formal scheduling
methods and good computer scheduling programs will find any such errors in the
logic of the construction plan.
Figure 9-4 Example of an Impossible Work Plan
Forgetting a necessary precedence relationship can be more insidious. For example,
suppose that installation of dry wall should be done prior to floor finishing. Ignoring
this precedence relationship may result in both activities being scheduled at the same
time. Corrections on the spot may result in increased costs or problems of quality in
the completed project. Unfortunately, there are few ways in which precedence
omissions can be found other than with checks by knowledgeable managers or by
comparison to comparable projects. One other possible but little used mechanism for
checking precedences is to conduct a physical or computer based simulation of the
construction process and observe any problems.
Finally, it is important to realize that different types of precedence relationships can
be defined and that each has different implications for the schedule of activities:
Some activities have a necessary technical or physical relationship that cannot be superseded. For example, concrete pours cannot proceed before formwork and reinforcement are in place.
Some activities have a necessary precedence relationship over a continuous space rather than as discrete work task relationships. For example, formwork may be placed in the first part of an excavation trench even as the excavation equipment continues to work further along in the trench. Formwork placement cannot proceed further than the excavation, but the two activities can be started and stopped independently within this constraint.
Some "precedence relationships" are not technically necessary but are imposed due to implicit decisions within the construction plan. For example, two activities may require the same piece of equipment so a precedence relationship might be defined between the two to insure that they are not scheduled for the same time period. Which activity is scheduled first is
arbitrary. As a second example, reversing the sequence of two activities may be technically possible but more expensive. In this case, the precedence relationship is not physically necessary but only applied to reduce costs as perceived at the time of scheduling.
In revising schedules as work proceeds, it is important to realize that different types of
precedence relationships have quite different implications for the flexibility and cost
of changing the construction plan. Unfortunately, many formal scheduling systems do
not possess the capability of indicating this type of flexibility. As a result, the burden
is placed upon the manager of making such decisions and insuring realistic and
effective schedules. With all the other responsibilities of a project manager, it is no
surprise that preparing or revising the formal, computer based construction plan is a
low priority to a manager in such cases. Nevertheless, formal construction plans may
be essential for good management of complicated projects.
Example 9-4: Precedence Definition for Site Preparation and Foundation Work
Suppose that a site preparation and concrete slab foundation construction project
consists of nine different activities:
A. Site clearing (of brush and minor debris),
B. Removal of trees,
C. General excavation,
D. Grading general area,
E. Excavation for utility trenches,
F. Placing formwork and reinforcement for concrete,
G. Installing sewer lines,
H. Installing other utilities,
I. Pouring concrete.
Activities A (site clearing) and B (tree removal) do not have preceding activities since
they depend on none of the other activities. We assume that activities C (general
excavation) and D (general grading) are preceded by activity A (site clearing). It
might also be the case that the planner wished to delay any excavation until trees were
removed, so that B (tree removal) would be a precedent activity to C (general
excavation) and D (general grading). Activities E (trench excavation) and F (concrete
preparation) cannot begin until the completion of general excavation and tree removal,
since they involve subsequent excavation and trench preparation. Activities G (install
lines) and H (install utilities) represent installation in the utility trenches and cannot be
attempted until the trenches are prepared, so that activity E (trench excavation) is a
preceding activity. We also assume that the utilities should not be installed until
grading is completed to avoid equipment conflicts, so activity D (general grading) is
also preceding activities G (install sewers) and H (install utilities). Finally, activity I
(pour concrete) cannot begin until the sewer line is installed and formwork and
reinforcement are ready, so activities F and G are preceding. Other utilities may be
routed over the slab foundation, so activity H (install utilities) is not necessarily a
preceding activity for activity I (pour concrete). The result of our planning are the
immediate precedences shown in Table 9-1.
TABLE 9-1 Precedence Relations for a Nine-Activity Project Example
Activity Description Predecessors
A
B
C
D
E
F
G
H
I
Site clearing
Removal of trees
General excavation
Grading general area
Excavation for utility trenches
Placing formwork and reinforcement for concrete
Installing sewer lines
Installing other utilities
Pouring concrete
---
---
A
A
B,C
B,C
D,E
D,E
F,G
With this information, the next problem is to represent the activities in a network
diagram and to determine all the precedence relationships among the activities. One
network representation of these nine activities is shown in Figure 9-5, in which the
activities appear as branches or links between nodes. The nodes represent milestones
of possible beginning and starting times. This representation is called an activity-on-
branch diagram. Note that an initial event beginning activity is defined (Node 0 in
Figure 9-5), while node 5 represents the completion of all activities.
Figure 9-5 Activity-on-Branch Representation of a Nine Activity Project
Alternatively, the nine activities could be represented by nodes and predecessor
relationships by branches or links, as in Figure 9-6. The result is an activity-on-
node diagram. In Figure 9-6, new activity nodes representing the beginning and the
end of construction have been added to mark these important milestones.
These network representations of activities can be very helpful in visualizing the
various activities and their relationships for a project. Whether activities are
represented as branches (as in Figure 9-5) or as nodes (as in Figure 9-5) is largely a
matter of organizational or personal choice. Some considerations in choosing one
form or another are discussed in Chapter 10.
Figure 9-6 Activity-on-Node Representation of a Nine Activity Project
It is also notable that Table 9-1 lists only the immediate predecessor relationships.
Clearly, there are other precedence relationships which involve more than one
activity. For example, "installing sewer lines" (activity G) cannot be undertaken
before "site clearing" (Activity A) is complete since the activity "grading general
area" (Activity D) must precede activity G and must follow activity A. Table 9-1 is
an implicit precedence list since only immediate predecessors are recorded. An
explicit predecessor list would include all of the preceding activities for activity G.
Table 9-2 shows all such predecessor relationships implied by the project plan. This
table can be produced by tracing all paths through the network back from a particular
activity and can be performed algorithmically. [7] For example, inspecting Figure 9-6
reveals that each activity except for activity B depends upon the completion of
activity A.
TABLE 9-2 All Activity Precedence Relationships for a Nine-Activity Project
Predecessor Activity Direct Successor Activities All Successor Activities All Predecessor Activities
A
B
C,D
E,F
E,F,G,H,I
G,H,I
---
---
C
D
E
F
G
H
I
E,F
G,H
G,H
I
I
---
---
G,H,I
I
I
---
---
---
---
A
A
A,B,C
A,B,C
A,B,C,D,E
A,B,C,D,E
A,B,C,D,E,F,G
Back to top
9.5 Estimating Activity Durations
In most scheduling procedures, each work activity has an associated time duration.
These durations are used extensively in preparing a schedule. For example, suppose
that the durations shown in Table 9-3 were estimated for the project diagrammed in
Figure 9-0. The entire set of activities would then require at least 3 days, since the
activities follow one another directly and require a total of 1.0 + 0.5 + 0.5 + 1.0 = 3
days. If another activity proceeded in parallel with this sequence, the 3 day minimum
duration of these four activities is unaffected. More than 3 days would be required for
the sequence if there was a delay or a lag between the completion of one activity and
the start of another.
TABLE 9-3 Durations and Predecessors for a Four Activity Project Illustration
Activity Predecessor Duration (Days)
Excavate trench
Place formwork
Place reinforcing
Pour concrete
---
Excavate trench
Place formwork
Place reinforcing
1.0
0.5
0.5
1.0
All formal scheduling procedures rely upon estimates of the durations of the various
project activities as well as the definitions of the predecessor relationships among
tasks. The variability of an activity's duration may also be considered. Formally,
the probability distribution of an activity's duration as well as the expected or most
likely duration may be used in scheduling. A probability distribution indicates the
chance that a particular activity duration will occur. In advance of actually doing a
particular task, we cannot be certain exactly how long the task will require.
A straightforward approach to the estimation of activity durations is to keep historical
records of particular activities and rely on the average durations from this experience
in making new duration estimates. Since the scope of activities are unlikely to be
identical between different projects, unit productivity rates are typically employed for
this purpose. For example, the duration of an activity Dij such as concrete formwork
assembly might be estimated as:
(9.1)
where Aij is the required formwork area to assemble (in square yards), Pij is the
average productivity of a standard crew in this task (measured in square yards per
hour), and Nij is the number of crews assigned to the task. In some organizations, unit
production time, Tij, is defined as the time required to complete a unit of work by a
standard crew (measured in hours per square yards) is used as a productivity measure
such that Tij is a reciprocal of Pij.
A formula such as Eq. (9.1) can be used for nearly all construction activities.
Typically, the required quantity of work, Aij is determined from detailed examination
of the final facility design. This quantity-take-off to obtain the required amounts of
materials, volumes, and areas is a very common process in bid preparation by
contractors. In some countries, specialized quantity surveyors provide the information
on required quantities for all potential contractors and the owner. The number of
crews working, Nij, is decided by the planner. In many cases, the number or amount of
resources applied to particular activities may be modified in light of the resulting
project plan and schedule. Finally, some estimate of the expected work productivity,
Pij must be provided to apply Equation (9.1). As with cost factors, commercial
services can provide average productivity figures for many standard activities of this
sort. Historical records in a firm can also provide data for estimation of productivities.
The calculation of a duration as in Equation (9.1) is only an approximation to the
actual activity duration for a number of reasons. First, it is usually the case that
peculiarities of the project make the accomplishment of a particular activity more or
less difficult. For example, access to the forms in a particular location may be
difficult; as a result, the productivity of assembling forms may be lower than the
average value for a particular project. Often, adjustments based on engineering
judgment are made to the calculated durations from Equation (9.1) for this reason.
In addition, productivity rates may vary in both systematic and random fashions from
the average. An example of systematic variation is the effect of learning on
productivity. As a crew becomes familiar with an activity and the work habits of the
crew, their productivity will typically improve. Figure 9-7 illustrates the type of
productivity increase that might occur with experience; this curve is called alearning
curve. The result is that productivity Pij is a function of the duration of an activity or
project. A common construction example is that the assembly of floors in a building
might go faster at higher levels due to improved productivity even though the
transportation time up to the active construction area is longer. Again, historical
records or subjective adjustments might be made to represent learning curve
variations in average productivity. [8]
Figure 9-7 Illustration of Productivity Changes Due to Learning
Random factors will also influence productivity rates and make estimation of activity
durations uncertain. For example, a scheduler will typically not know at the time of
making the initial schedule how skillful the crew and manager will be that are
assigned to a particular project. The productivity of a skilled designer may be many
times that of an unskilled engineer. In the absence of specific knowledge, the
estimator can only use average values of productivity.
Weather effects are often very important and thus deserve particular attention in
estimating durations. Weather has both systematic and random influences on activity
durations. Whether or not a rainstorm will come on a particular day is certainly a
random effect that will influence the productivity of many activities. However, the
likelihood of a rainstorm is likely to vary systematically from one month or one site to
the next. Adjustment factors for inclement weather as well as meteorological records
can be used to incorporate the effects of weather on durations. As a simple example,
an activity might require ten days in perfect weather, but the activity could not
proceed in the rain. Furthermore, suppose that rain is expected ten percent of the days
in a particular month. In this case, the expected activity duration is eleven days
including one expected rain day.
Finally, the use of average productivity factors themselves cause problems in the
calculation presented in Equation (9.1). The expected value of the multiplicative
reciprocal of a variable is not exactly equal to the reciprocal of the variable's expected
value. For example, if productivity on an activity is either six in good weather (ie.,
P=6) or two in bad weather (ie., P=2) and good or bad weather is equally likely, then
the expected productivity is P = (6)(0.5) + (2)(0.5) = 4, and the reciprocal of expected
productivity is 1/4. However, the expected reciprocal of productivity is E[1/P] =
(0.5)/6 + (0.5)/2 = 1/3. The reciprocal of expected productivity is 25% less than the
expected value of the reciprocal in this case! By representing only two possible
productivity values, this example represents an extreme case, but it is always true that
the use of average productivity factors in Equation (9.1) will result
in optimistic estimates of activity durations. The use of actual averages for the
reciprocals of productivity or small adjustment factors may be used to correct for this
non-linearity problem.
The simple duration calculation shown in Equation (9.1) also assumes an inverse
linear relationship between the number of crews assigned to an activity and the total
duration of work. While this is a reasonable assumption in situations for which crews
can work independently and require no special coordination, it need not always be
true. For example, design tasks may be divided among numerous architects and
engineers, but delays to insure proper coordination and communication increase as the
number of workers increase. As another example, insuring a smooth flow of material
to all crews on a site may be increasingly difficult as the number of crews increase. In
these latter cases, the relationship between activity duration and the number of crews
is unlikely to be inversely proportional as shown in Equation (9.1). As a result,
adjustments to the estimated productivity from Equation (9.1) must be made.
Alternatively, more complicated functional relationships might be estimated between
duration and resources used in the same way that nonlinear preliminary or conceptual
cost estimate models are prepared.
One mechanism to formalize the estimation of activity durations is to employ a
hierarchical estimation framework. This approach decomposes the estimation problem
into component parts in which the higher levels in the hierarchy represent attributes
which depend upon the details of lower level adjustments and calculations. For
example, Figure 9-8 represents various levels in the estimation of the duration of
masonry construction. [9] At the lowest level, the maximum productivity for the
activity is estimated based upon general work conditions. Table 9-4 illustrates some
possible maximum productivity values that might be employed in this estimation. At
the next higher level, adjustments to these maximum productivities are made to
account for special site conditions and crew compositions; table 9-5 illustrates some
possible adjustment rules. At the highest level, adjustments for overall effects such as
weather are introduced. Also shown in Figure 9-8 are nodes to estimate down or
unproductive time associated with the masonry construction activity. The
formalization of the estimation process illustrated in Figure 9-8 permits the
development of computer aids for the estimation process or can serve as a conceptual
framework for a human estimator.
TABLE 9-4 Maximum Productivity Estimates for Masonry Work
Masonry unit
size Condition(s)
Maximum produstivity
achievable
8 inch block None 400 units/day/mason
6 inch Wall is "long" 430 units/day/mason
6 inch Wall is not "long" 370 units/day/mason
12 inch Labor is nonunion 300 units/day/mason
4 inch Wall is "long"
Weather is "warm and dry"
or high-strength mortar is used
480 units/day/mason
4 inch Wall is not "long"
Weather is "warm and dry"
or high-strength mortar is used
430 units/day/mason
4 inch Wall is "long"
Weather is not "warm and dry"
or high-strength mortar is not
used
370 units/day/mason
4 inch Wall is not "long"
Weather is not "warm and dry"
or high-strength mortar is not
used
320 units/day/mason
8 inch There is support from existing
wall
1,000 units/day/mason
8 inch There is no support from existing 750 units/day/mason
wall
12 inch There is support from existing
wall
700 units/day/mason
12 inch There is no support from existing
wall
550
TABLE 9-5 Possible Adjustments to Maximum Productivities for Masonry
Construction/caption>
Impact Condition(s)
Adjustment
magnitude
(% of maximum)
Crew type Crew type is nonunion
Job is "large"
15%
Crew type Crew type is union
Job is "small"
10%
Supporting
labor
There are less than two laborers per crew 20%
Supporting
labor
There are more than two masons/laborers 10%
Elevation Steel frame building with masonry exterior
wall has "insufficient" support labor
10%
Elevation Solid masonry building with work on exterior
uses nonunion labor
12%
Visibility block is not covered 7%
Temperature Temperature is below 45o F 15%
Temperature Temperature is above 45o F 10%
Brick texture bricks are baked high
Weather is cold or moist
10%
Figure 9-8 A Hierarchical Estimation Framework for Masonry Construction
In addition to the problem of estimating the expected duration of an activity, some
scheduling procedures explicitly consider the uncertainty in activity duration
estimates by using the probabilistic distribution of activity durations. That is, the
duration of a particular activity is assu med to be a random variable that is distributed
in a particular fashion. For example, an activity duration might be assumed to be
distributed as a normal or a beta distributed random variable as illustrated in Figure 9-
9. This figure shows the probability or chance of experiencing a particular activity
duration based on a probabilistic distribution. The beta distribution is often used to
characterize activity durations, since it can have an absolute minimum and an absolute
maximum of possible duration times. The normal distribution is a good approximation
to the beta distribution in the center of the distribution and is easy to work with, so it
is often used as an approximation.
Figure 9-9 Beta and Normally Distributed Activity Durations
If a standard random variable is used to characterize the distribution of activity
durations, then only a few parameters are required to calculate the probability of any
particular duration. Still, the estimation problem is increased considerably since more
than one parameter is required to characterize most of the probabilistic distribution
used to represent activity durations. For the beta distribution, three or four parameters
are required depending on its generality, whereas the normal distribution requires two
parameters.
As an example, the normal distribution is characterized by two parameters, and
representing the average duration and the standard deviation of the duration,
respectively. Alternatively, the variance of the distribution could be used to
describe or characterize the variability of duration times; the variance is the value of
the standard deviation multiplied by itself. From historical data, these two parameters
can be estimated as:
(9.2)
(9.3)
where we assume that n different observations xk of the random variable x are
available. This estimation process might be applied to activity durations directly (so
that xk would be a record of an activity duration Dij on a past project) or to the
estimation of the distribution of productivities (so that xk would be a record of the
productivity in an activity Pi) on a past project) which, in turn, is used to estimate
durations using Equation (9.4). If more accuracy is desired, the estimation equations
for mean and standard deviation, Equations (9.2) and (9.3) would be used to estimate
the mean and standard deviation of the reciprocal of productivity to avoid non-linear
effects. Using estimates of productivities, the standard deviation of activity duration
would be calculated as:
(9.4)
where is the estimated standard deviation of the reciprocal of productivity that
is calculated from Equation (9.3) by substituting 1/P for x.
Back to top
9.6 Estimating Resource Requirements for Work Activities
In addition to precedence relationships and time durations, resource requirements are
usually estimated for each activity. Since the work activities defined for a project are
comprehensive, the total resources required for the project are the sum of the
resources required for the various activities. By making resource requirement
estimates for each activity, the requirements for particular resources during the course
of the project can be identified. Potential bottlenecks can thus be identified, and
schedule, resource allocation or technology changes made to avoid problems.
Many formal scheduling procedures can incorporate constraints imposed by the
availability of particular resources. For example, the unavailability of a specific piece
of equipment or crew may prohibit activities from being undertaken at a particular
time. Another type of resource is space. A planner typically will schedule only one
activity in the same location at the same time. While activities requiring the same
space may have no necessary technical precedence, simultaneous work might not be
possible. Computational procedures for these various scheduling problems will be
described in Chapters 10 and 11. In this section, we shall discuss the estimation of
required resources.
The initial problem in estimating resource requirements is to decide the extent and
number of resources that might be defined. At a very aggregate level, resources
categories might be limited to the amount of labor (measured in man-hours or in
dollars), the amount of materials required for an activity, and the total cost of the
activity. At this aggregate level, the resource estimates may be useful for purposes of
project monitoring and cash flow planning. For example, actual expenditures on an
activity can be compared with the estimated required resources to reveal any problems
that are being encountered during the course of a project. Monitoring procedures of
this sort are described in Chapter 12. However, this aggregate definition of resource
use would not reveal bottlenecks associated with particular types of equipment or
workers.
More detailed definitions of required resources would include the number and type of
both workers and equipment required by an activity as well as the amount and types
of materials. Standard resource requirements for particular activities can be recorded
and adjusted for the special conditions of particular projects. As a result, the resources
types required for particular activities may already be defined. Reliance on historical
or standard activity definitions of this type requires a standard coding system for
activities.
In making adjustments for the resources required by a particular activity, most of the
problems encountered in forming duration estimations described in the previous
section are also present. In particular, resources such as labor requirements will vary
in proportion to the work productivity, Pij, used to estimate activity durations in
Equation (9.1). Mathematically, a typical estimating equation would be:
(9.5)
where Rkij are the resources of type k required by activity ij, Dij is the duration of
activity ij, Nij is the number of standard crews allocated to activity ij, and Ukij is the
amount of resource type k used per standard crew. For example, if an activity required
eight hours with two crews assigned and each crew required three workers, the effort
would be R = 8*2*3 = 48 labor-hours.
From the planning perspective, the important decisions in estimating resource
requirements are to determine the type of technology and equipment to employ and
the number of crews to allocate to each task. Clearly, assigning additional crews
might result in faster completion of a particular activity. However, additional crews
might result in congestion and coordination problems, so that work productivity might
decline. Further, completing a particular activity earlier might not result in earlier
completion of the entire project, as discussed in Chapter 10.
Example 9-5: Resource Requirements for Block Foundations
In placing concrete block foundation walls, a typical crew would consist of three
bricklayers and two bricklayer helpers. If sufficient space was available on the site,
several crews could work on the same job at the same time, thereby speeding up
completion of the activity in proportion to the number of crews. In more restricted
sites, multiple crews might interfere with one another. For special considerations
such as complicated scaffolding or large blocks (such as twelve inch block), a
bricklayer helper for each bricklayer might be required to insure smooth and
productive work. In general, standard crew composition depends upon the specific
construction task and the equipment or technology employed. These standard crews
are then adjusted in response to special characteristics of a particular site.
Example 9-6: Pouring Concrete Slabs
For large concrete pours on horizontal slabs, it is important to plan the activity so
that the slab for a full block can be completed continuously in a single day. Resources
required for pouring the concrete depend upon the technology used. For example, a
standard crew for pumping concrete to the slab might include a foreman, five
laborers, one finisher, and one equipment operator. Related equipment would be
vibrators and the concrete pump itself. For delivering concrete with a chute directly
from the delivery truck, the standard crew might consist of a foreman, four laborers
and a finisher. The number of crews would be chosen to insure that the desired
amount of concrete could be placed in a single day. In addition to the resources
involved in the actual placement, it would also be necessary to insure a sufficient
number of delivery trucks and availability of the concrete itself.
Back to top
9.7 Coding Systems
One objective in many construction planning efforts is to define the plan within the
constraints of a universal coding system for identifying activities. Each activity
defined for a project would be identified by a pre-defined code specific to that
activity. The use of a common nomenclature or identification system is basically
motivated by the desire for better integration of organizational efforts and improved
information flow. In particular, coding systems are adopted to provide a numbering
system to replace verbal descriptions of items. These codes reduce the length or
complexity of the information to be recorded. A common coding system within an
organization also aids consistency in definitions and categories between projects and
among the various parties involved in a project. Common coding systems also aid in
the retrieval of historical records of cost, productivity and duration on particular
activities. Finally, electronic data storage and retrieval operations are much more
efficient with standard coding systems, as described in Chapter 14.
In North America, the most widely used standard coding system for constructed
facilities is the MASTERFORMAT system developed by the Construction
Specifications Institute (CSI) of the United States and Construction Specifications of
Canada. [10] After development of separate systems, this combined system was
originally introduced as the Uniform Construction Index (UCI) in 1972 and was
subsequently adopted for use by numerous firms, information providers, professional
societies and trade organizations. The term MASTERFORMAT was introduced with
the 1978 revision of the UCI codes. MASTERFORMAT provides a standard
identification code for nearly all the elements associated with building construction.
MASTERFORMAT involves a hierarchical coding system with multiple levels plus
keyword text descriptions of each item. In the numerical coding system, the first two
digits represent one of the sixteen divisions for work; a seventeenth division is used to
code conditions of the contract for a constructor. In the latest version of the
MASTERFORMAT, a third digit is added to indicate a subdivision within each
division. Each division is further specified by a three digit extension indicating
another level of subdivisions. In many cases, these subdivisions are further divided
with an additional three digits to identify more specific work items or materials. For
example, the code 16-950-960, "Electrical Equipment Testing" are defined as within
Division 16 (Electrical) and Sub-Division 950 (Testing). The keywords "Electrical
Equipment Testing" is a standard description of the activity. The seventeen major
divisions in the UCI/CSI MASTERFORMAT system are shown in Table 9-6. As an
example, site work second level divisions are shown in Table 9-7.
TABLE 9-6 Major Divisions in the Uniform Construction Index
0 Conditions of the contract
1 General requirements
2 Site work
3 Concrete
4 Masonry
5 Metals
6 Wood and plastics
7 Thermal and moisture prevention
8 Doors and windows
9 Finishes
10 Specialties
11 Equipment
12 Furnishings
13 Special construction
14 Conveying system
15 Mechanical
16 Electrical
While MASTERFORMAT provides a very useful means of organizing and
communicating information, it has some obvious limitations as a complete project
coding system. First, more specific information such as location of work or
responsible organization might be required for project cost control. Code extensions
are then added in addition to the digits in the basic MASTERFORMAT codes. For
example, a typical extended code might have the following elements:
0534.02220.21.A.00.cf34
The first four digits indicate the project for this activity; this code refers to an activity
on project number 0534. The next five digits refer to the MASTERFORMAT
secondary division; referring to Table 9-7, this activity would be 02220 "Excavating,
Backfilling and Compacting." The next two digits refer to specific activities defined
within this MASTERFORMAT code; the digits 21 in this example might refer to
excavation of column footings. The next character refers to the block or general area
on the site that the activity will take place; in this case, block A is indicated. The
digits 00 could be replaced by a code to indicate the responsible organization for the
activity. Finally, the characters cf34 refer to the particular design element number for
which this excavation is intended; in this case, column footing number 34 is intended.
Thus, this activity is to perform the excavation for column footing number 34 in block
A on the site. Note that a number of additional activities would be associated with
column footing 34, including formwork and concreting. Additional fields in the
coding systems might also be added to indicate the responsible crew for this activity
or to identify the specific location of the activity on the site (defined, for example, as
x, y and z coordinates with respect to a base point).
As a second problem, the MASTERFORMAT system was originally designed for
building construction activities, so it is difficult to include various construction
activities for other types of facilities or activities associated with planning or design.
Different coding systems have been provided by other organizations in particular sub-
fields such as power plants or roadways. Nevertheless, MASTERFORMAT provides
a useful starting point for organizing information in different construction domains.
In devising organizational codes for project activities, there is a continual tension
between adopting systems that are convenient or expedient for one project or for one
project manager and systems appropriate for an entire organization. As a general rule,
the record keeping and communication advantages of standard systems are excellent
arguments for their adoption. Even in small projects, however, ad hoc or haphazard
coding systems can lead to problems as the system is revised and extended over time.
TABLE 9-7 Secondary Divisions in MASTERFORMAT for Site Work [11]
02-010
02-012
Subsurface investigation
Standard penetration tests
02-350
02-355
Piles and caissons
Pile driving
02-016 Seismic investigation
02-050
02-060
02-070
02-075
02-080
Demolition
Building demolition
Selective demolition
Concrete removal
Asbestos removal
02-100
02-110
02-115
02-120
Site preparation
Site clearing
Selective clearing
Structure moving
02-140 Dewatering
02-150 Shoring and underpinning
02-160 Excavation supporting system
02-170 Cofferdams
02-200
02-210
02-220
02-230
02-240
02-250
02-270
02-280
02-290
Earthwork
Grading
Excavating, backfilling and compaction
Base course
Soil stabilization
Vibro-floatation
Slope protection
Soil treatment
Earth dams
02-300
02-305
02-310
02-320
02-330
02-340
Tunneling
Tunnel ventilation
Tunnel excavating
Tunnel lining
Tunnel grouting
Tunnel support systems
02-360
02-370
02-380
Driven piles
Bored/augered piles
Caissons
02-450 Railroad work
02-480 Marine work
02-500
02-510
02-515
02-525
02-530
02-540
02-545
02-550
02-560
02-575
02-580
Paving and surfacing
Walk, road and parking paving
Unit pavers
Curbs
Athletic paving and surfacing
Synthetic surfacing
Surfacing
Highway paving
Airfield paving
Pavement repair
Pavement marking
02-600 Piped utility materials
02-660 Water distribution
02-680 Fuel distribution
02-700 Sewage and drainage
02-760 Restoration of underground pipelines
02-770 Ponds and reservoirs
02-800 Power and communications
02-880 Site improvements
02-900 Landscaping
Back to top
9.8 References
1. Baracco-Miller, E., "Planning for Construction," Unpublished MS Thesis, Dept. of Civil Engineering, Carnegie Mellon University, 1987.
2. Construction Specifications Institute, MASTERFORMAT - Master List of Section Titles and Numbers, Releasing Industry Group, Alexandria, VA, 1983.
3. Jackson, M.J. Computers in Construction Planning and Control, Allen & Unwin, London, 1986.
4. Sacerdoti, E.D. A Structure for Plans and Behavior, Elsevier North-Holland, New York, 1977.
5. Zozaya-Gorostiza, C., "An Expert System for Construction Project Planning," Unpublished PhD Dissertation, Dept. of Civil Engineering, Carnegie Mellon University, 1988.
Back to top
9.9 Problems
1. Develop an alternative work breakdown for the activities shown in Figure 9-2 (Example 9-3). Begin first with a spatial division on the site (i.e. by roadway segment and structure number), and then include functional divisions to develop a different hierarchy of activities.
2. Consider a cold weather structure built by inflating a special rubber tent, spraying water on the tent, letting the water freeze, and then de-flating and removing the tent. Develop a work breakdown for this structure, precedence relationships, and estimate the required resources. Assume that the tent is twenty feet by fifteen feet by eight feet tall.
3. Develop a work breakdown and activity network for the project of designing a tower to support a radio transmission antenna.
4. Select a vacant site in your vicinity and define the various activities and precedences among these activities that would be required to prepare the site
for the placement of pre-fabricated residences. Use the coding system for site work shown in Table 9-7 for executing this problem.
5. Develop precedence relationships for the roadway project activities appearing in Figure 9-2 (Example 9-3).
6. Suppose that you have a robot capable of performing two tasks in manipulating blocks on a large tabletop:
o PLACE BLOCK X ON BLOCK Y: This action places the block x on top of the block y. Preconditions for applying this action are that both block x and block y have clear tops (so there is no block on top of x or y). The robot will automatically locate the specified blocks.
o CLEAR BLOCK X: This action removes any block from the top of block x. A necessary precondition for this action is that block x has one and only one block on top. The block removed is placed on the table top.
For this robot, answer the following questions:
3. Using only the two robot actions, specify a sequence of robot actions to take the five blocks shown in Figure 9-10(a) to the position shown in Figure 9-10(b) in five or six robot actions.
4. Specify a sequence of robot actions to move the blocks from position (b) to position (c) in Figure 9-10 in six moves.
5. Develop an activity network for the robot actions in moving from position (b) to position (c) in Figure 9-10. Prepare both activity-on-node and activity-on-link representations. Are there alternative sequences of activities that the robot might perform to accomplish the desired position?
Figure 9-10 Illustrative Block Positions for Robot Motion Planning
7. In the previous problem, suppose that switching from the PLACE BLOCK action to the CLEAR BLOCK action or vice versa requires an extra ten seconds. Movements themselves require 8 seconds. What is the sequence of actions of shortest duration to go from position (b) to position (a) in Figure 9-10?
8. Repeat Problem 6 above for the movement from position (a) to position (c) in Figure 9-10.
9. Repeat Problem 7 above for the movement from position (a) to position (c) in Figure 9-10.
10. Suppose that you have an enhanced robot with two additional commands capabilities:
o CARRY BLOCKS X-Y to BLOCK Z: This action moves blocks X-Y to the top of block Z. Blocks X-Y may involve any number of blocks as long as X is on the bottom and Y is on the top. This move assumes that Z has a clear top.
o CLEAR ALL BLOCK X TO BLOCK Z: This action moves all blocks on top of block X to the top of block Z. If a block Z is not specified, then the blocks are moved to the table top.
How do these capabilities change your answer to Problems 6 and 7?
11. How does the additional capability described in Problem 10 change your answer to Problems 8 and ?
Back to top
9.10 Footnotes
1. A.C. Doyle, "A Study in Scarlet," The Complete Sherlock Holmes, Doubleday &
Co., pg. 83, 1930. Back
2. See, for example, Paulson, B.C., S.A. Douglas, A. Kalk, A. Touran and G.A.
Victor, "Simulation and Analysis of Construction Operations," ASCE Journal of
Technical Topics in Civil Engineering, 109(2), August, 1983, pp. 89, or Carr, R.I.,
"Simulation of Construction Project Duration," ASCE Journal of the Construction
Division, 105(2), June 1979, 117-128. Back
3. For a description of a laser leveling system, see Paulson, B.C., Jr., "Automation and
Robotics for Construction," ASCE Journal of Construction Engineering and
Management, (111)3, pp. 190-207, Sept. 1985. Back
4. See Baker, K.R., Introduction to Sequencing and Scheduling, John-Wiley and Sons,
New York, 1974, for an introduction to scheduling in manufacturing. Back
5. See Skibniewski, M.J. and C.T. Hendrickson, "Evaluation Method for Robotics
Implementation: Application to Concrete Form Cleaning," Proc. Second Intl. Conf. on
Robotics in Construction, Carnegie-Mellon University, Pittsburgh, PA., 1985, for
more detail on the work process design of a concrete form cleaning robot. Back
6. This example is adapted from Aras, R. and J. Surkis, "PERT and CPM Techniques
in Project Management," ASCE Journal of the Construction Division, Vol. 90, No.
CO1, March, 1964. Back
7. For a discussion of network reachability and connectivity computational
algorithms, see Chapters 2 and 7 in N. Christofides, Graph Theory: An Algorithmic
Approach, London: Academic Press, 1975, or any other text on graph theory. Back
8. See H.R. Thomas, C.T. Matthews and J.G. Ward, "Learning Curve Models of
Construction Productivity," ASCE Journal of Construction Engineering and
Management, Vol. 112, No. 2, June 1986, pp. 245-258. Back
9. For a more extension discussion and description of this estimation procedure, see
Hendrickson, C., D. Martinelli, and D. Rehak, "Hierarchical Rule-based Activity
Duration Estimation," ASCE Journal of Construction Engineering and Management,
Vol 113, No. 2, 1987,pp. 288-301. Back
10. Information on the MASTERFORMAT coding system can be obtained from: The
Construction Specifications Institute, 601 Madison St., Alexandria VA 22314. Back
11. Source: MASTERFORMAT: Master List of Section Titles and Numbers, 1983 Edition, The construction Speculations Institute, Alexandria, VA, 1983. Back
Previous Chapter | Table of Contents | Next Chapter